Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
2022-4097
CONTRACT #2022-4097 AGREEMENT BETWEEN OWNER AND CONTRACTOR FOR CONSTRUCTION CONTRACT (STIPULATED PRICE) This Agreement is by and between City of Columbia Heights, Minnesota ("Owner") and Century Fence Company_ ("Contractor") Terms used in this Agreement have the meanings stated in the General Conditions and the Supplementary Conditions. Owner and Contractor hereby agree as follows: ARTICLE 1—WORK 1.01 Contractor shall complete all Work as specified or indicated in the Contract Documents. The work is generally described as follows: 2022 COLUMBIA HEIGHTS PUBLIC SAFETY FENCE IMPROVEMENTS — PROJECT 2207 ARTICLE 2—THE PROJECT 2.01 The project, of which the work under the contract documents is a part, is generally described as follows: CITY PROJECT NO. 2207 • FENCE REMOVALS AND INSTALLATION • GATE REMOVALS AND INSTALLATION • MISCELLANIOUS CONSTRUCTION ARTICLE 3—ENGINEER 3.01 The ENGINEER is to act as Owner's representative, assume all duties and responsibilities of Engineer, and have the rights and authority assigned to Engineer in the Contract. 3.02 The part of the Project that pertains to the Work has been designed by CITY OF COLUMBIA HEIGHTS' ENGINEERING DEPARTMENT (ENGINEER). ARTICLE 4—CONTRACT TIMES 4.01 Time is of the Essence A. All time limits for Milestones, if any, Substantial Completion, and completion and readiness for final payment as stated in the Contract Documents are of the essence of the Contract. 4.02 Contract Times: Dotes A. The Work will be substantially complete on or before October 30, 2022, and completed and ready for final payment in accordance with Paragraph 15.06 of the General Conditions on or before November 20, 2022. B. Once the work is initiated (removals) the Contractor shall complete the project and restoration within 75 calendar days. EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 of 6 4.03 Liquidated Damages A. Contractor and Owner recognize that time is of the essence as stated in Paragraph 4.01 above and that Owner will suffer financial and other losses if the Work is not completed and Milestones not achieved within the Contract Times, as duly modified. The parties also recognize the delays, expense, and difficulties involved in proving, in a legal or arbitration proceeding, the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty): 1. Substantial Completion: Contractor shall pay Owner $1,500.00 for each day that expires after the time (as duly adjusted pursuant to the Contract) specified above for Substantial Completion, until the Work is substantially complete. 2. Completion of Remaining Work: After Substantial Completion, if Contractor shall neglect, refuse, or fail to complete the remaining Work within the Contract Times (as duly adjusted pursuant to the Contract) for completion and readiness for final payment, Contractor shall pay Owner $1,500.00 for each day that expires after such time until the Work is completed and ready for final payment. 3. Liquidated damages for failing to timely attain Substantial Completion, and final completion are not additive, and will not be imposed concurrently. B. If Owner recovers liquidated damages for a delay in completion by Contractor, then such liquidated damages are Owner's sole and exclusive remedy for such delay, and Owner is precluded from recovering any other damages, whether actual, direct, excess, or consequential, for such delay, except for special damages (if any) specified in this Agreement. ARTICLE 5—CONTRACT PRICE 5.01 Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents, the amounts that follow, subject to adjustment under the Contract: A. For all Work, at the prices stated in Contractor's Bid, attached hereto as an exhibit. B. The extended prices for Unit Price Work set forth as of the Effective Date of the Contract are based on estimated quantities. As provided in Paragraph 13.03 of the General Conditions, estimated quantities are not guaranteed, and determinations of actual quantities and classifications are to be made by Engineer. ARTICLE 6—PAYMENT PROCEDURES 6.01 Submittal and Processing of Payments A. Contractor shall submit Applications for Payment in accordance with Article 15 of the General Conditions. Applications for Payment will be processed by Engineer as provided in the General Conditions. 6.02 Progress Payments, Retainage A. Owner shall make progress payments on the basis of Contractor's Applications for Payment on or about the 15" day of each month during performance of the Work as provided in EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 of 6 Paragraph 6.02.A.1 below, provided that such Applications for Payment have been submitted in a timely manner and otherwise meet the requirements of the Contract. All such payments will be measured by the Schedule of Values established as provided in the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no Schedule of Values, as provided elsewhere in the Contract. 1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below but, in each case, less the aggregate of payments previously made and less such amounts as Owner may withhold, including but not limited to liquidated damages, in accordance with the Contract. a. 95 percent of the value of the Work completed (with the balance being retainage). b. 95 percent of cost of materials and equipment not incorporated in the Work (with the balance being retainage). B. After Substantial Completion, Owner shall pay an amount sufficient to increase total payments to Contractor in accordance with Minnesota Statute 15.72. 6.03 Final Payment A. Upon final completion and acceptance of the Work, Owner shall pay the remainder of the Contract Price in accordance with Paragraph 15.06 of the General Conditions. 6.04 Consent of Surety A. Owner will not make final payment, or return or release retainage at Substantial Completion or any other time, unless Contractor submits written consent of the surety to such payment, return, or release. 6.05 Interest A. All amounts not paid when due will bear interest at the rate stipulated in Minnesota Statue 161.322. ARTICLE 7—CONTRACT DOCUMENTS 7.01 Contents A. The Contract Documents consist of all of the following: 1. This Agreement. 2. General Conditions. 3. Supplementary Conditions. 4. Specifications as listed in the table of contents of the project manual. 5. Drawings 7. Addenda (numbers to , inclusive). 8. Exhibits to this Agreement (enumerated as follows): a. Contractor's Bid (pages 11 to 16, inclusive). EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 3 of 6 9. The following which may be delivered or issued on or after the Effective Date of the Contract and are not attached hereto: a. Notice to Proceed. b. Work Change Directives. c. Change Orders. B. The Contract Documents listed in Paragraph 7.01.A are attached to this Agreement (except as expressly noted otherwise above). C. There are no Contract Documents other than those listed above in this Article 7. D. The Contract Documents may only be amended, modified, or supplemented as provided in the Contract. ARTICLE 8—REPRESENTATIONS, CERTIFICATIONS, AND STIPULATIONS 8.01 Contractor's Representations A. In order to induce Owner to enter into this Contract, Contractor makes the following representations: 1. Contractor has examined and carefully studied the Contract Documents, including Addenda. 2. Contractor has visited the Site, conducted a thorough visual examination of the Site and adjacent areas, and become familiar with the general, local, and Site conditions that may affect cost, progress, and performance of the Work. 3. Contractor is familiar with all Laws and Regulations that may affect cost, progress, and performance of the Work. 4. Contractor has carefully studied the reports of explorations and tests of subsurface conditions at or adjacent to the Site and the drawings of physical conditions relating to existing surface or subsurface structures at the Site that have been identified in the Supplementary Conditions, with respect to the Technical Data in such reports and drawings. 5. Contractor has carefully studied the reports and drawings relating to Hazardous Environmental Conditions, if any, at or adjacent to the Site that have been identified in the Supplementary Conditions, with respect to Technical Data in such reports and drawings. 6. Contractor has considered the information known to Contractor itself; information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Contract Documents; and the Technical Data identified in the Supplementary Conditions or by definition, with respect to the effect of such information, observations, and Technical Data on (a) the cost, progress, and performance of the Work; (b) the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor; and (c) Contractor's safety precautions and programs. 7. Based on the information and observations referred to in the preceding paragraph, Contractor agrees that no further examinations, investigations, explorations, tests, EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 4 of 6 studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract. 8. Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Contract Documents. 9. Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and of discrepancies between Site conditions and the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor. 10. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. 11. Contractor's entry into this Contract constitutes an incontrovertible representation by Contractor that without exception all prices in the Agreement are premised upon performing and furnishing the Work required by the Contract Documents. 8.02 Contractor's Certifications A. Contractor certifies that it has not engaged in corrupt, fraudulent, collusive, or coercive practices in competing for or in executing the Contract. For the purposes of this Paragraph 8.02: 1. "corrupt practice" means the offering, giving, receiving, or soliciting of anything of value likely to influence the action of a public official in the bidding process or in the Contract execution; 2. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the bidding process or the execution of the Contract to the detriment of Owner, (b) to establish Bid or Contract prices at artificial non-competitive levels, or (c) to deprive Owner of the benefits of free and open competition; 3. "collusive practice" means a scheme or arrangement between two or more Bidders, with or without the knowledge of Owner, a purpose of which is to establish Bid prices at artificial, non-competitive levels; and 4. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the bidding process or affect the execution of the Contract. 8.03 Standard General Conditions A. Owner stipulates that if the General Conditions that are made a part of this Contract are EJCDC® C-700, Standard General Conditions for the Construction Contract (2018), published by the Engineers Joint Contract Documents Committee, and if Owner is the party that has furnished said General Conditions, then Owner has plainly shown all modifications to the standard wording of such published document to the Contractor, through a process such as highlighting or "track changes" (redline/strikeout), or in the Supplementary Conditions. EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 5 of 6 IN WITNESS WHEREOF, Owner and Contractor have signed this Agreement. This Agreement will be effective on July 25, 2022 (which is the Effective Date of the Contract). Owner: City of Columbia Heights, Minnesota By: Kelli B u eois, City Manager By: 44 m6cla Marquez Simula, Mayor Attest: Title: Address for giving notices: 637 38th Avenue NE Columbia Heights, MN 55421 Designated Representative: Name: Jim Hauth Title: Utilities Superintendent Address: City of Columbia Heights 637 38th Avenue NE Columbia Heights, MN 55421 Contractor: (typed or pfinted name of organiratio ) By: (i vidual's signature) Date: �aDlz_ T� (date signed) Name: r,� (typedlor printed) Title: rm qa � (typed or printed) a� Attest: e f (individual's '4aatunV ` Title: (typed printed) Address forgiving notices: Po &x Z77 /1 Y'83 9 f..� Dr F&a� LArk, M m Ala s Designated Representative: Name: �ASahr-Scxl (typed or printed) Title:c,� % > (typed or print ) Address: _ PO Zgx z73 9_ D� rire o-f AA(S o2.S Phone: 763-706-3711 Email: jhauth@columbiaheightsmn.gov Phone: 4s l - 46 4.73 73 Email: j tS4h I� C���IPxttGca License No.: (where applicable) State: P'/ M E1CDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 6 of 6 CONTRACTOR (name and address): Century Fence Company PO Box 277 Forest Lake, MN 55025 PERFORMANCE BOND SURETY (name and address of principal place of business): Great American Insurance Company 301 E. 4th Street Cincinnati, OH 45202 OWNER (name and address): City Of Columbia Heights 637 38th Avenue NE, Columbia Heights, MN 55421 CONSTRUCTION CONTRACT Effective Date of the Agreement: JUIy 25, 2022 Amount: $357,534.86 Description (name and location): 2022 Columbia Heights Public Safety Fence Improvements - Project 2207 BOND Bond Number: CA3854047 Date (not earlier than the Effective Date of the Agreement of the Construction Contract): August 11, 2022 Amount: $357,534.86 Modifications to this Bond Form: i X ii None ❑ See Paragraph 16 Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause this Performance Bond to be duly executed by an authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL Century Fence Company Contractor's Name and Corporge Seal By: Print Name (f ffv Title Attest: - i inature Tit , SURETY (Sear Great American Insurance CorTlpc^t-'-1y(Seal) Surety's Nam rporate eai By: _ Sig re (attach pa r of attorney) v Jonathan Lucas Print Name Attorney -in -Fact Title �o Attest: - �•i.+<-- S4gnature 1 Witness Title Notes: (1) Provide supplemental execution by any additional parties, such as joint venturers. (2) Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. EJCDCm C-610, Performance Bond Copyright ® 2013 National society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 1 of 3 1. The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. 2. If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Paragraph 3. 3. If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after: 3.1 The Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor, and Surety to discuss the Contractors performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Paragraph 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owners notice. If the Owner, the Contractor, and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owners right, if any, subsequently to declare a Contractor Default; 3.2 The Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and 3.3 The Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. 4. Failure on the part of the Owner to comply with the notice requirement in Paragraph 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. 5. When the Owner has satisfied the conditions of Paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following actions: 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owners concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor, and with reasonable promptness under the circumstances: 5.4.1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or 5.4.2 Deny liability In whole or In part and notify the Owner, citing the reasons for denial, 6. If the Surety does not proceed as provided in Paragraph 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Paragraph 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 7. If the Surety elects to act under Paragraph 5.1, 5.2, or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication for: 7.1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; 7.2 additional legal, design professional, and delay costs resulting from the Contractors Default, and resulting from the actions or failure to act of the Surety under Paragraph 5; and 7.3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. B. If the Surety elects to act under Paragraph 5.1, 5.3, or 5,4, the Surety's liability is limited to the amount of this Bond. 9. The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors, and assigns. EICDCv C-610, Performance Bond Copyright 6) 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 2 of 3 10. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations. 11. Any proceeding, legal or equitable, under this Bond may be Instituted in any court of competent jurisdiction in the location In which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minimum periods of limitations available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to the Surety, the Owner, or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. 13. When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent Is that this Bond shall be construed as a statutory bond and not as a common law bond. 14. Definitions 14.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made including allowance for the Contractor for any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. 14.2 Construction Contract: The agreement between the Owner and Contractor identified on the cover page, Including all Contract Documents and changes made to the agreement and the Contract Documents. 14.3 Contractor Default: Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract, 14.4 Owner Default: Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 14.5 Contract Documents: All the documents that comprise the agreement between the Owner and Contractor. 15. If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 16. Modifications to this Bond areas follows: EJCDC° C-610, Performance Bond Copyright ® 2013 National society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 3 of 3 I� 1 C 1.) C, ' 0.'1r:11[IEr;rii f ;luU.' III CONTRACTOR (name and address): Century Fence Company PO Box 277 Forest Lake, MN 55025 PAYMENT BOND SURETY (name and address of principal place of business): Great American Insurance Company 301 E. 4th Street Cincinnati, OH 45202 OWNER (name and address): City of Columbia Heights 637 38th Avenue NE, Columbia Heights, MN 55421 CONSTRUCTION CONTRACT Effective Date of the Agreement: July 25, 2022 Amount:$357,534.86 Description (name and location): 2022 Columbia Heights Public Safety Fence Improvements - Project 2207 BOND Bond Number: CA3854047 Date (not earlier than the Effective Date of the Agreement of the Construction Contract): August 11, 2022 Amount: $357, 534.86 Modifications to this Bond Form: ❑X None ❑ See Paragraph 18 Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause this Payment Bond to be duly executed by an authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL SURETY Century Fence Company (seal) Great American Insurance Compa??y(seal) Contractor's Name and Corpor a Seal Surety's Na n Co orat Seal By: By: Signature Si u (attach po r of attorney) , Jonathan Lucas Print Name C11 Title Atte Signature Print Name Attorney -in -Fact Title Title Attest: ign atu re Witness Notes. (1) Provide supplemental execution by any additional parties, such as joint venturers. (2) Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. EICDCO C-615, Payment Bond Copyright ® 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of civil Engineers. All rights reserved. 1 of 3 1. The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to the Owner to pay for labor, materials, and equipment furnished for use in the performance of the Construction Contract, whlch is incorporated herein by reference, subject to the following terms. If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies, and holds harmless the Owner from claims, demands, liens, or suits by any person or entity seeking payment for labor, materials, or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. 3. If there is no Owner Default under the Construction 6. if a notice of non-payment required by Paragraph 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Paragraph 5.1.1. 7. When a Claimant has satisfied the conditions of Paragraph 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and 7.2 Pay or arrange for payment of any undisputed amounts. Contract, the Surety's obligation to the Owner under this 7.3 The Surety's failure to discharge its obligations Bond shall arise after the Owner has promptly notified the under Paragraph 7.1 or 7.2 shall not be deemed to Contractor and the Surety (at the address described in constitute a waiver of defenses the Surety or Paragraph 13) of clalms, demands, liens, or suits against Contractor may have or acquire as to a Claim, the Owner or the Owner's property by any person or except as to undisputed amounts for which the entity seeking payment for labor, materials, or equipment Surety and Claimant have reached agreement. If, furnished for use in the performance of the Construction however, the Surety fails to discharge its Contract, and tendered defense of such claims, demands, obligations under Paragraph 7.1 or 7.2, the Surety liens, or suits to the Contractor and the Surety. shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to 4. When the Owner has satisfied the conditions in Paragraph recover any sums found to be due and owing to 3, the Surety shall promptly and at the Surety's expense the Claimant. defend, indemnify, and hold harmless the Owner against a duly tendered claim, demand, lien, or suit. 8. The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's S. The Surety's obligations to a Claimant under this Bond fees provided under Paragraph 7.3, and the amount of this shall arise after the following: Bond shall be credited for any payments made in good faith by the Surety. 5.1 Claimants who do not have a direct contract with the Contractor, 9. Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance 5.1.1 have furnished a written notice of non- of the Construction Contract and to satisfy claims, if any, payment to the Contractor, stating with under any construction performance bond. By the substantial accuracy the amount claimed Contractor furnishing and the Owner accepting this Bond, and the name of the party to whom the they agree that all funds earned by the Contractor in the materials were, or equipment was, performance of the Construction Contract are dedicated furnished or supplied or for whom the to satisfy obligations of the Contractor and Surety under labor was done or performed, within this Bond, subject to the Owners priority to use the funds ninety (90) days after having last for the completion of the work. performed labor or last furnished materials or equipment included in the 10. The Surety shall not be liable to the Owner, Claimants, or Claim; and others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be 5.1.2 have sent a Claim to the Surety (at the liable for the payment of any costs or expenses of any address described in Paragraph 13). Claimant under this Bond, and shall have under this Bond no obligation to make payments to or give notice on 5.2 Claimants who are employed by or have a direct behalf of Claimants, or otherwise have any obligations to contract with the Contractor have sent a Claim to Claimants under this Bond. the Surety (at the address described in Paragraph 13). 11. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations. EJCDC• C-615, Payment Bond Copyright 0 2023 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 2 of 3 12. No suit or action shall be commenced by a Claimant under 8. The total amount due and unpaid to the this Bond other than in a court of competent jurisdiction in Claimant for labor, materials, or equipment the state in which the project that is the subject of the furnished as of the date of the Claim. Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a 16.2 Claimant: An individual or entity having a direct Claim to the Surety pursuant to Paragraph 5.1.2 or 5.2, or contract with the Contractor or with a (2) on which the last labor or service was performed by subcontractor of the Contractor to furnish labor, anyone or the last materials or equipment were furnished materials, or equipment for use in the performance by anyone under the Construction Contract, whichever of of the Construction Contract. The term Claimant (1) or (2) first occurs. If the provisions of this paragraph also includes any individual or entity that has are void or prohibited by law, the minimum period of rightfully asserted a claim under an applicable limitation available to sureties as a defense in the mechanic's lien or similar statute against the real jurisdiction of the suit shall be applicable, property upon which the Project is located. The intent of this Bond shall be to include without 13. Notice and Claims to the Surety, the Owner, or the limitation in the terms of "labor, materials, or Contractor shall be mailed or delivered to the address equipment" that part of the water, gas, power, shown on the page on which their signature appears. light, heat, oil, gasoline, telephone service, or Actual receipt of notice or Claims, however accomplished, rental equipment used in the Construction shall be sufficient compliance as of the date received. Contract, architectural and engineering services required for performance of the work of the 14. When this Bond has been furnished to comply with a Contractor and the Contractor's subcontractors, statutory or other legal requirement in the location where and all other items for which a mechanic's lien may the construction was to be performed, any provision in be asserted in the jurisdiction where the labor, this Bond conflicting with said statutory or legal materials, or equipment were furnished. requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal 16.3 Construction Contract: The agreement between requirement shall be deemed incorporated herein. When the Owner and Contractor identified on the cover so furnished, the intent is that this Bond shall be construed page, including all Contract Documents and all as a statutory bond and not as a common law bond. changes made to the agreement and the Contract Documents. 15. Upon requests by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and 16.4 Owner Default; Failure of the Owner, which has Owner shall promptly furnish a copy of this Bond or shall not been remedied or waived, to pay the permit a copy to be made, Contractor as required under the Construction Contract or to perform and complete or comply 16. Definitions with the other material terms of the Construction Contract. 16.1 Claim: A written statement by the Claimant including at a minimum: 1. The name of the Claimant; 2. The name of the person for whom the labor was done, or materials or equipment furnished; 3. A copy of the agreement or purchase order pursuant to which labor, materials, or equipment was furnished for use in the performance of the Construction Contract; 4. A brief description of the labor, materials, or equipment furnished; 5. The date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; 6. The total amount earned by the Claimant for labor, materials, or equipment furnished as of the date of the Claim; 7. The total amount of previous payments received by the Claimant; and 16.5 Contract Documents: All the documents that comprise the agreement between the Owner and Contractor. 17. If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 18. Modifications to this Bond are as follows; EICDC' C-615, Payment Bond Copyright (D 2023 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 3 of 3 GREAT AMERICAN INSURANCE COMPANY® Administrative Office: 301 E 4TH STREET • CINCINNATI, OHIO 45202 • 513-369-5000 0 FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than FOUR POWER OF ATTORNEY No.o 20850 KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY, a corporation organized and existing under and by virtue of the laws of the State of Ohio, does hereby nominate, constitute and appoint the person or persons named below, each individually if more than one is named, its true and lawful attorney -in -fact, for it and in its name, place and stead to execute on behalf of the said Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof; provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below. Name ROBERT E. FLATH TODDLOOKER GARY BURTON JONATHANLUCAS Address ALL OF MILWAUKEE, WISCONSIN Limit of Power ALL $100, 000,000 This Power of Attorney revokes all previous powers issued on behalf of the attomey(s)-in-fact named above. IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its appropriate officers and its corporate seal hereunto affixed this 4TH day of OCTOBER 2021 Attest GREAT AMERICAN INSU ANCE COMPAIV Assistant Secretary Divisional Senior Vice President STATE OF OHIO, COUNTY OF HAMILTON - ss: MARK vicARiO (e77-377-2405) On this 4TH day of OCTOBER 2021 , before me personally appeared MARK VICARIO, tome known, being duly sworn, deposes and says that he resides in Cincinnati, Ohio, that he is a Divisional Senior Vice President of the Bond Division of Great American Insurance Company, the Company described in and which executed the above instrument; that he knows the seal of the said Company; that the seal affixed to the said instrument is such corporate seal; that it was so affixed by authority of his office tinder the By -Laws of said Company, and that he signed his name thereto by like authority. SUSAN A KOHORST Notary public % a� State of Ohio My Comm. Expires Tway i 8, 2025 This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company by unanimous written consent dated June 9, 2008. RESOLVED: That the Divisional President, the several Divisional Senior Vice Presidents, Divisional rice Presidents and Divisonal Assistant Vice Presidents, or any one of'them, be and hereby is authorized, from time to time, to appoint one or more Attorneys -in -Fuel to execute on behalf of the Company, as surety, any and all bonds, undertakings and contracts ofsuretyship, or other written obligations in the nature thamg4- to prrscrihe their respective duties and the respective limits of their authority; and to revoke any such appointment at any time. RESOLVED FURTHER: That the Company seal and Nee Agnatrirr .of any gf the gforrsaid officers and any Secretary or A-wstarit Secretary of rile' Company Wray be ay4red by fcresimile to any power of attorney or certtfecate of either givet) for rile execution of any holed, undertakng, contract of srrreryship, or Other L$9•rt101 obfigation in the nalare thereof such .signotutc and seal when sa used hang het*, adapted by the Company ess the ofigitral signature Rf Stich weer and the: original Seal of the Company, to be Valid and hinding upon the Company with the same force and effect as though manually affixed. CERTIFICATION I, STEPHEN C. BERAHA, Assistant Secretary of Great American Insurance Company, do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of June 9, 2008 have not been revoked and are now in full force and effect. Signed and sealed this 11 day of August , 4e'. 2022 P,r e . 3 Assistant Secretary S1029AH (03/20) CERTIFICATE OF LIABILITY INSURANCE DATE[MMzo22m) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT CSDZ, LLC NAME: Rob n HenSlin _ 1600 Aspen Commons Suite 990 PHONE 608 242-2555 FAX Middleton WI 53562 ADDRESS: rhenslin(dcsdz.com INSURERS AFFORDING COVERAGE NAIC# INSURER A: Zurich American Insurance Company 16535 INSURED CENFENPC INSURER B : The Continental Insurance Company 35289 Century Fence Company 14839 Lake Drive INSURER C : Travelers Property CasuaU Co. America 25674 Forest Lake, MN 55025 INSURERD: Navigators Specialty. Insurance Company 36056 COVFRAGFS rFRTIFIr ATF NI IMRFR• 1;7nR11o'4) DG\/ICIn KI N11110mr-D• THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL IK§k SUER WVD POLICY NUMBER POLICYEFF MM/➢D/YYYY POLICY EXP MM/DD/YYYY LIMITS A X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE FX_1 OCCUR GLOO11030304 4/1/2022 4/1/2023 EACH OCCURRENCE $2,000,000 PREMISES iEa occurrence $ 300,000 X MED EXP (Any oneperson) $ 10.000 XCU not excluded X Contractual Liab PERSONAL & ADV INJURY $ 2.000.000 GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PE LOC GEN ERAL AGGREGATE $4,000.000 PRODUCTS - COMP/OPAGG $4,000,000 $ OTHER: A AUTOMOBILE LIABILITY BAP011030404 4/1/2022 4/1/2023 COM51NEDIINGLEUMIT Ea accWent $2,000.000 BODILY INJURY (Per person) X ANY AUTO $ OWNED SCHEDULED AUTOS ONLY AUTOS $ tid Per accident) BODILY INJURY ( ) HIRED NON -OWNED AUTOS ONLY AUTOS ONLY L $ PROPERTY DAMAGE Par ccddenl $ B X UMBRELLA LIAB N OCCUR 6075583410 4/1/2022 4/1/2023 EACH OCCURRENCE $ 10,000,000 AGGREGATE EXCESS LIAB CLAIMS -MADE $ 10.000,000 DED I X I RETENTION $ in nnn $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN WC011030204 4/1/2022 4/1/2023 X PER OTH- STATUTE ER E.L.EACH ACCIDENT $ 1,000,000 ANYPROPRIETOR/PARTNER/EXECUTIVE [E OFFICER/MEMBER EXCLUDED? NIA E.L. DISEASE - EA EMPLOYEE $ 1.000.000 (Mandatory in NH) If yes, describe under E.L. DISEASE - POLICY LIMIT $ 1.000,000 DESCRIPTION OF OPERATIONS hetow C D Installation Floater Operations Pollution Liability 66011\1379158 MP22ECPZ0570HIC 4/1/2022 4/1/2022 4/1/2023 4/1/2024 Limit: Ea Incident: Aggregate: $150,000 $1,000,000 $2,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) 2022 Columbia Heights Public Safety Fence Improvements - Project 2207 Additional Insured only If required by written contract with respect to General Liability, Automobile Liability and Umbrella/Excess Liability applies on a primary basis and the insurance of the additional insured shall be non-contributory: City of Columbia Heights as required by written contract CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Columbia Heights 637 38th Avenue NE AUT RIZEDREPRESENTATIVE Columbia Heights MN 55421 �n ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the controlling Laws and Regulations. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared By ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE ACEC AMERICAN COUNCIL OF ]✓"NGINEERING COMPANIES -ASCE AMERICAN SOCIETY OF CIVIL ENGINEERS ® NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS Endorsed By Ircsi, U [mob Building Knowledge��� Improving Project Delivery E1CDC° C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT TABLE OF CONTENTS Page Article 1—Definitions and Terminology........................................................................................................1 1.01 Defined Terms...............................................................................................................................1 1.02 Terminology..................................................................................................................................6 Article2—Preliminary Matters.....................................................................................................................7 2.01 Delivery of Performance and Payment Bonds; Evidence of Insurance.........................................7 2.02 Copies of Documents....................................................................................................................7 2.03 Before Starting Construction........................................................................................................7 2.04 Preconstruction Conference; Designation of Authorized Representatives..................................8 2.05 Acceptance of Schedules..............................................................................................................8 2.06 Electronic Transmittals.................................................................................................................8 Article 3—Contract Documents: Intent, Requirements, Reuse....................................................................9 3.01 Intent............................................................................................................................................. 9 3.02 Reference Standards.....................................................................................................................9 3.03 Reporting and Resolving Discrepancies......................................................................................10 3.04 Requirements of the Contract Documents.................................................................................10 3.05 Reuse of Documents...................................................................................................................11 Article 4—Commencement and Progress of the Work..............................................................................11 4.01 Commencement of Contract Times; Notice to Proceed.............................................................11 4.02 Starting the Work........................................................................................................................11 4.03 Reference Points.........................................................................................................................11 4.04 Progress Schedule.......................................................................................................................12 4.05 Delays in Contractor's Progress..................................................................................................12 Article 5—Site; Subsurface and Physical Conditions; Hazardous Environmental Conditions ....................13 5.01 Availability of Lands....................................................................................................................13 5.02 Use of Site and Other Areas........................................................................................................14 5.03 Subsurface and Physical Conditions............................................................................................15 5.04 Differing Subsurface or Physical Conditions...............................................................................16 E1CDC° C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. TOC Page 1 of 5 5.05 Underground Facilities................................................................................................................17 5.06 Hazardous Environmental Conditions at Site.............................................................................19 Article 6—Bonds and Insurance..................................................................................................................21 6.01 Performance, Payment, and Other Bonds..................................................................................21 6.02 Insurance —General Provisions...................................................................................................22 6.03 Contractor's Insurance................................................................................................................24 6.04 Builder's Risk and Other Property Insurance..............................................................................25 6.05 Property Losses; Subrogation.....................................................................................................25 6.06 Receipt and Application of Property Insurance Proceeds..........................................................27 Article 7—Contractor's Responsibilities.....................................................................................................27 7.01 Contractor's Means and Methods of Construction....................................................................27 7.02 Supervision and Superintendence..............................................................................................27 7.03 Labor; Working Hours.................................................................................................................27 7.04 Services, Materials, and Equipment...........................................................................................28 7.05 "Or Equals"..................................................................................................................................28 7.06 Substitutes..................................................................................................................................29 7.07 Concerning Subcontractors and Suppliers..................................................................................31 7.08 Patent Fees and Royalties...........................................................................................................32 7.09 Permits........................................................................................................................................33 7.10 Taxes........................................................................................................................................... 33 7.11 Laws and Regulations..................................................................................................................33 7.12 Record Documents......................................................................................................................33 7.13 Safety and Protection.................................................................................................................34 7.14 Hazard Communication Programs..............................................................................................35 7.15 Emergencies................................................................................................................................35 7.16 Submittals...................................................................................................................................35 7.17 Contractor's General Warranty and Guarantee.........................................................................38 7.18 Indemnification........................................................................................................................... 39 7.19 Delegation of Professional Design Services................................................................................39 Article 8—Other Work at the Site...............................................................................................................40 8.01 Other Work.................................................................................................................................40 8.02 Coordination...............................................................................................................................41 8.03 Legal Relationships......................................................................................................................41 E1CDC° C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. TOC Page 2 of 5 Article 9—Owner's Responsibilities............................................................................................................42 9.01 Communications to Contractor..................................................................................................42 9.02 Replacement of Engineer............................................................................................................42 9.03 Furnish Data................................................................................................................................42 9.04 Pay When Due.............................................................................................................................42 9.05 Lands and Easements; Reports, Tests, and Drawings.................................................................43 9.06 Insurance..................................................................................................................................... 43 9.07 Change Orders............................................................................................................................43 9.08 Inspections, Tests, and Approvals...............................................................................................43 9.09 Limitations on Owner's Responsibilities.....................................................................................43 9.10 Undisclosed Hazardous Environmental Condition......................................................................43 9.11 Evidence of Financial Arrangements...........................................................................................43 9.12 Safety Programs..........................................................................................................................43 Article 10—Engineer's Status During Construction....................................................................................44 10.01 Owner's Representative..........................................................................................................44 10.02 Visits to Site.............................................................................................................................44 10.03 Resident Project Representative.............................................................................................44 10.04 Engineer's Authority...............................................................................................................44 10.05 Determinations for Unit Price Work.......................................................................................45 10.06 Decisions on Requirements of Contract Documents and Acceptability of Work...................45 10.07 Limitations on Engineer's Authority and Responsibilities......................................................45 10.08 Compliance with Safety Program............................................................................................45 Article 11—Changes to the Contract..........................................................................................................46 11.01 Amending and Supplementing the Contract..........................................................................46 11.02 Change Orders........................................................................................................................46 11.03 Work Change Directives..........................................................................................................46 11.04 Field Orders.............................................................................................................................47 11.05 Owner -Authorized Changes in the Work................................................................................47 11.06 Unauthorized Changes in the Work........................................................................................47 11.07 Change of Contract Price........................................................................................................47 11.08 Change of Contract Times.......................................................................................................49 11.09 Change Proposals....................................................................................................................49 11.10 Notification to Surety..............................................................................................................50 E1CDC° C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. TOC Page 3 of 5 Article12—Claims .......................................................................................................................................50 12.01 Claims......................................................................................................................................SO Article 13—Cost of the Work; Allowances; Unit Price Work...................................................................... 51 13.01 Cost of the Work.....................................................................................................................51 13.02 Allowances.............................................................................................................................. 55 13.03 Unit Price Work.......................................................................................................................55 Article 14—Tests and Inspections; Correction, Removal, or Acceptance of Defective Work ....................56 14.01 Access to Work........................................................................................................................ 56 14.02 Tests, Inspections, and Approvals...........................................................................................56 14.03 Defective Work....................................................................................................................... 57 14.04 Acceptance of Defective Work................................................................................................58 14.05 Uncovering Work....................................................................................................................58 14.06 Owner May Stop the Work..................................................................................................... 58 14.07 Owner May Correct Defective Work.......................................................................................59 Article 15—Payments to Contractor; Set -Offs; Completion; Correction Period........................................59 15.01 Progress Payments..................................................................................................................59 15.02 Contractor's Warranty of Title................................................................................................62 15.03 Substantial Completion...........................................................................................................62 15.04 Partial Use or Occupancy........................................................................................................63 15.05 Final Inspection.......................................................................................................................64 15.06 Final Payment..........................................................................................................................64 15.07 Waiver of Claims.....................................................................................................................65 15.08 Correction Period.................................................................................................................... 66 Article 16—Suspension of Work and Termination.....................................................................................67 16.01 Owner May Suspend Work.....................................................................................................67 16.02 Owner May Terminate for Cause............................................................................................67 16.03 Owner May Terminate for Convenience.................................................................................68 16.04 Contractor May Stop Work or Terminate...............................................................................68 Article 17—Final Resolution of Disputes....................................................................................................69 17.01 Methods and Procedures........................................................................................................69 Article18—Miscellaneous ..........................................................................................................................69 18.01 Giving Notice...........................................................................................................................69 18.02 Computation of Times.............................................................................................................69 E1CDC° C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. TOC Page 4 of 5 18.03 Cumulative Remedies.............................................................................................................70 18.04 Limitation of Damages............................................................................................................70 18.05 No Waiver...............................................................................................................................70 18.06 Survival of Obligations............................................................................................................70 18.07 Controlling Law.......................................................................................................................70 18.08 Assignment of Contract...........................................................................................................70 18.09 Successors and Assigns........................................................................................................... 70 18.10 Headings..................................................................................................................................70 E1CDC° C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. TOC Page 5 of 5 STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT ARTICLE 1—DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms A. Wherever used in the Bidding Requirements or Contract Documents, a term printed with initial capital letters, including the term's singular and plural forms, will have the meaning indicated in the definitions below. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Addenda —Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the proposed Contract Documents. 2. Agreement —The written instrument, executed by Owner and Contractor, that sets forth the Contract Price and Contract Times, identifies the parties and the Engineer, and designates the specific items that are Contract Documents. 3. Application for Payment —The document prepared by Contractor, in a form acceptable to Engineer, to request progress or final payments, and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4. Bid —The offer of a Bidder submitted on the prescribed form setting forth the prices for the Work to be performed. 5. Bidder —An individual or entity that submits a Bid to Owner. 6. Bidding Documents —The Bidding Requirements, the proposed Contract Documents, and all Addenda. 7. , Bid Bend A_.r ethe.r Bid Security, Of any, the Bid FeFm, and the Bid with any attaC_-h.M.P_.Atr_. 8. Change Order —A document which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, or other revision to the Contract, issued on or after the Effective Date of the Contract. 9. Change Proposal —A written request by Contractor, duly submitted in compliance with the procedural requirements set forth herein, seeking an adjustment in Contract Price or Contract Times; contesting an initial decision by Engineer concerning the requirements of the Contract Documents or the acceptability of Work under the Contract Documents; challenging a set-off against payments due; or seeking other relief with respect to the terms of the Contract. 10. Claim a. A demand or assertion by Owner directly to Contractor, duly submitted in compliance with the procedural requirements set forth herein, seeking an adjustment of Contract Price or Contract Times; contesting an initial decision by Engineer concerning the EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 of 70 requirements of the Contract Documents or the acceptability of Work under the Contract Documents; contesting Engineer's decision regarding a Change Proposal; seeking resolution of a contractual issue that Engineer has declined to address; or seeking other relief with respect to the terms of the Contract. b. A demand or assertion by Contractor directly to Owner, duly submitted in compliance with the procedural requirements set forth herein, contesting Engineer's decision regarding a Change Proposal, or seeking resolution of a contractual issue that Engineer has declined to address. c. A demand or assertion by Owner or Contractor, duly submitted in compliance with the procedural requirements set forth herein, made pursuant to Paragraph 12.01.A.4, concerning disputes arising after Engineer has issued a recommendation of final payment. d. A demand for money or services by a third party is not a Claim. 11. Constituent of Concern —Asbestos, petroleum, radioactive materials, polychlorinated biphenyls (PCBs), lead -based paint (as defined by the HUD/EPA standard), hazardous waste, and any substance, product, waste, or other material of any nature whatsoever that is or becomes listed, regulated, or addressed pursuant to Laws and Regulations regulating, relating to, or imposing liability or standards of conduct concerning, any hazardous, toxic, or dangerous waste, substance, or material. 12. Contract —The entire and integrated written contract between Owner and Contractor concerning the Work. 13. Contract Documents —Those items so designated in the Agreement, and which together comprise the Contract. 14. Contract Price —The money that Owner has agreed to pay Contractor for completion of the Work in accordance with the Contract Documents. 15. Contract Times —The number of days or the dates by which Contractor shall: (a) achieve Milestones, if any; (b) achieve Substantial Completion; and (c) complete the Work. 16. Contractor —The individual or entity with which Owner has contracted for performance of the Work. 17. Cost of the Work —See Paragraph 13.01 for definition. 18. Drawings —The part of the Contract that graphically shows the scope, extent, and character of the Work to be performed by Contractor. 19. Effective Date of the Contract —The date, indicated in the Agreement, on which the Contract becomes effective. 20. Electronic Document —Any Project -related correspondence, attachments to correspondence, data, documents, drawings, information, or graphics, including but not limited to Shop Drawings and other Submittals, that are in an electronic or digital format. 21. Electronic Means —Electronic mail (email), upload/download from a secure Project website, or other communications methods that allow: (a) the transmission or communication of Electronic Documents; (b) the documentation of transmissions, including sending and receipt; (c) printing of the transmitted Electronic Document by the EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 of 70 recipient; (d) the storage and archiving of the Electronic Document by sender and recipient; and (e) the use by recipient of the Electronic Document for purposes permitted by this Contract. Electronic Means does not include the use of text messaging, or of Facebook, Twitter, Instagram, or similar social media services for transmission of Electronic Documents. 22. Engineer —The individual or entity named as such in the Agreement. 23. Field Order —A written order issued by Engineer which requires minor changes in the Work but does not change the Contract Price or the Contract Times. 24. Hazardous Environmental Condition —The presence at the Site of Constituents of Concern in such quantities or circumstances that may present a danger to persons or property exposed thereto. a. The presence at the Site of materials that are necessary for the execution of the Work, or that are to be incorporated into the Work, and that are controlled and contained pursuant to industry practices, Laws and Regulations, and the requirements of the Contract, is not a Hazardous Environmental Condition. b. The presence of Constituents of Concern that are to be removed or remediated as part of the Work is not a Hazardous Environmental Condition. c. The presence of Constituents of Concern as part of the routine, anticipated, and obvious working conditions at the Site, is not a Hazardous Environmental Condition. 25. Laws and Regulations; Laws or Regulations —Any and all applicable laws, statutes, rules, regulations, ordinances, codes, and binding decrees, resolutions, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 26. Liens —Charges, security interests, or encumbrances upon Contract -related funds, real property, or personal property. 27. Milestone —A principal event in the performance of the Work that the Contract requires Contractor to achieve by an intermediate completion date, or by a time prior to Substantial Completion of all the Work. 28. Notice of Award —The written notice by Owner to a Bidder of Owner's acceptance of the Bid. 29. Notice to Proceed —A written notice by Owner to Contractor fixing the date on which the Contract Times will commence to run and on which Contractor shall start to perform the Work. 30. Owner —The individual or entity with which Contractor has contracted regarding the Work, and which has agreed to pay Contractor for the performance of the Work, pursuant to the terms of the Contract. 31. Progress Schedule —A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising Contractor's plan to accomplish the Work within the Contract Times. 32. Project —The total undertaking to be accomplished for Owner by engineers, contractors, and others, including planning, study, design, construction, testing, commissioning, and start-up, and of which the Work to be performed under the Contract Documents is a part. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 3 of 70 33. Resident Project Representative —The authorized representative of Engineer assigned to assist Engineer at the Site. As used herein, the term Resident Project Representative (RPR) includes any assistants or field staff of Resident Project Representative. 34. Samples —Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and that establish the standards by which such portion of the Work will be judged. 35. Schedule of Submittals —A schedule, prepared and maintained by Contractor, of required submittals and the time requirements for Engineer's review of the submittals. 36. Schedule of Values —A schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor's Applications for Payment. 37. Shop Drawings —All drawings, diagrams, illustrations, schedules, and other data or information that are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. Shop Drawings, whether approved or not, are not Drawings and are not Contract Documents. 38. Site —Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights -of -way and easements, and such other lands or areas furnished by Owner which are designated for the use of Contractor. 39. Specifications —The part of the Contract that consists of written requirements for materials, equipment, systems, standards, and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable to the Work. 40. Subcontractor —An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work. 41. Submittal —A written or graphic document, prepared by or for Contractor, which the Contract Documents require Contractor to submit to Engineer, or that is indicated as a Submittal in the Schedule of Submittals accepted by Engineer. Submittals may include Shop Drawings and Samples; schedules; product data; Owner -delegated designs; sustainable design information; information on special procedures; testing plans; results of tests and evaluations, source quality -control testing and inspections, and field or Site quality -control testing and inspections; warranties and certifications; Suppliers' instructions and reports; records of delivery of spare parts and tools; operations and maintenance data; Project photographic documentation; record documents; and other such documents required by the Contract Documents. Submittals, whether or not approved or accepted by Engineer, are not Contract Documents. Change Proposals, Change Orders, Claims, notices, Applications for Payment, and requests for interpretation or clarification are not Submittals. 42. Substantial Completion —The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion of such Work. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 4 of 70 43. Successful Bidder —The Bidder to which the Owner makes an award of contract. 44. Supplementary Conditions —The part of the Contract that amends or supplements these General Conditions. 45. Supplier —A manufacturer, fabricator, supplier, distributor, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or a Subcontractor. 46. Technical Data a. Those items expressly identified as Technical Data in the Supplementary Conditions, with respect to either (1) existing subsurface conditions at or adjacent to the Site, or existing physical conditions at or adjacent to the Site including existing surface or subsurface structures (except Underground Facilities) or (2) Hazardous Environmental Conditions at the Site. b. If no such express identifications of Technical Data have been made with respect to conditions at the Site, then Technical Data is defined, with respect to conditions at the Site under Paragraphs 5.03, 5.04, and 5.06, as the data contained in boring logs, recorded measurements of subsurface water levels, assessments of the condition of subsurface facilities, laboratory test results, and other factual, objective information regarding conditions at the Site that are set forth in any geotechnical, environmental, or other Site or facilities conditions report prepared for the Project and made available to Contractor. c. Information and data regarding the presence or location of Underground Facilities are not intended to be categorized, identified, or defined as Technical Data, and instead Underground Facilities are shown or indicated on the Drawings. 47. Underground Facilities —All active or not -in-service underground lines, pipelines, conduits, ducts, encasements, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or systems at the Site, including but not limited to those facilities or systems that produce, transmit, distribute, or convey telephone or other communications, cable television, fiber optic transmissions, power, electricity, light, heat, gases, oil, crude oil products, liquid petroleum products, water, steam, waste, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. An abandoned facility or system is not an Underground Facility. 48. Unit Price Work —Work to be paid for on the basis of unit prices. 49. Work —The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction; furnishing, installing, and incorporating all materials and equipment into such construction; and may include related services such as testing, start-up, and commissioning, all as required by the Contract Documents. 50. Work Change Directive —A written directive to Contractor issued on or after the Effective Date of the Contract, signed by Owner and recommended by Engineer, ordering an addition, deletion, or revision in the Work. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 5 of 70 1.02 Terminology A. The words and terms discussed in Paragraphs 1.02.13, C, D, and E are not defined terms that require initial capital letters, but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning. B. Intent of Certain Terms orAdjectives: The Contract Documents include the terms "as allowed," "as approved," "as ordered," "as directed" or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action, or determination will be solely to evaluate, in general, the Work for compliance with the information in the Contract Documents and with the design concept of the Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake responsibility contrary to the provisions of Article 10 or any other provision of the Contract Documents. C. Day: The word "day" means a calendar day of 24 hours measured from midnight to the next midnight. D. Defective: The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it: 1. does not conform to the Contract Documents; 2. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or 3. has been damaged prior to Engineer's recommendation of final payment (unless responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 15.03 or Paragraph 15.04). E. Furnish, Install, Perform, Provide 1. The word "furnish," when used in connection with services, materials, or equipment, means to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, means to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide," when used in connection with services, materials, or equipment, means to furnish and install said services, materials, or equipment complete and ready for intended use. 4. If the Contract Documents establish an obligation of Contractor with respect to specific services, materials, or equipment, but do not expressly use any of the four words "furnish," "install," "perform," or "provide," then Contractor shall furnish and install said services, materials, or equipment complete and ready for intended use. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 6 of 70 F. Contract Price or Contract Times: References to a change in "Contract Price or Contract Times" or "Contract Times or Contract Price" or similar, indicate that such change applies to (1) Contract Price, (2) Contract Times, or (3) both Contract Price and Contract Times, as warranted, even if the term "or both" is not expressed. G. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2—PRELIMINARY MATTERS 2.01 Delivery of Performance and Payment Bonds; Evidence of Insurance A. Performance and Payment Bonds: When Contractor delivers the signed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner the performance bond and payment bond (if the Contract requires Contractor to furnish such bonds). B. Evidence of Contractor's Insurance: When Contractor delivers the signed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner, with copies to each additional insured (as identified in the Contract), the certificates, endorsements, and other evidence of insurance required to be provided by Contractor in accordance with Article 6, except to the extent the Supplementary Conditions expressly establish other dates for delivery of specific insurance policies. C. Evidence of Owner's Insurance: After receipt of the signed counterparts of the Agreement and all required bonds and insurance documentation, Owner shall promptly deliver to Contractor, with copies to each additional insured (as identified in the Contract), the certificates and other evidence of insurance required to be provided by Owner under Article 6. 2.02 Copies of Documents A. Owner shall furnish to Contractor four printed copies of the Contract (including one fully signed counterpart of the Agreement), and one copy in electronic portable document format (PDF). Additional printed copies will be furnished upon request at the cost of reproduction. B. Owner shall maintain and safeguard at least one original printed record version of the Contract, including Drawings and Specifications signed and sealed by Engineer and other design professionals. Owner shall make such original printed record version of the Contract available to Contractor for review. Owner may delegate the responsibilities under this provision to Engineer. 2.03 Before Starting Construction A. Preliminary Schedules: Within 10 days after the Effective Date of the Contract (or as otherwise required by the Contract Documents), Contractor shall submit to Engineer for timely review: 1. a preliminary Progress Schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract; 2. a preliminary Schedule of Submittals; and 3. a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdivides the Work EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 7 of 70 into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.04 Preconstruction Conference; Designation of Authorized Representatives A. Before any Work at the Site is started, a conference attended by Owner, Contractor, Engineer, and others as appropriate will be held to establish a working understanding among the parties as to the Work, and to discuss the schedules referred to in Paragraph 2.03.A, procedures for handling Shop Drawings, Samples, and other Submittals, processing Applications for Payment, electronic or digital transmittals, and maintaining required records. B. At this conference Owner and Contractor each shall designate, in writing, a specific individual to act as its authorized representative with respect to the services and responsibilities under the Contract. Such individuals shall have the authority to transmit and receive information, render decisions relative to the Contract, and otherwise act on behalf of each respective party. 2.05 Acceptance of Schedules A. At least 10 days before submission of the first Application for Payment a conference, attended by Contractor, Engineer, and others as appropriate, will be held to review the schedules submitted in accordance with Paragraph 2.03.A. No progress payment will be made to Contractor until acceptable schedules are submitted to Engineer. 1. The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of the Work, nor interfere with or relieve Contractor from Contractor's full responsibility therefor. 2. Contractor's Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals. 3. Contractor's Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to the component parts of the Work. 4. If a schedule is not acceptable, Contractor will have an additional 10 days to revise and resubmit the schedule. 2.06 Electronic Transmittals A. Except as otherwise stated elsewhere in the Contract, the Owner, Engineer, and Contractor may send, and shall accept, Electronic Documents transmitted by Electronic Means. B. If the Contract does not establish protocols for Electronic Means, then Owner, Engineer, and Contractor shall jointly develop such protocols. C. Subject to any governing protocols for Electronic Means, when transmitting Electronic Documents by Electronic Means, the transmitting party makes no representations as to long- term compatibility, usability, or readability of the Electronic Documents resulting from the recipient's use of software application packages, operating systems, or computer hardware differing from those used in the drafting or transmittal of the Electronic Documents. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 8 of 70 ARTICLE 3—CONTRACT DOCUMENTS: INTENT, REQUIREMENTS, REUSE 3.01 Intent A. The Contract Documents are complementary; what is required by one Contract Document is as binding as if required by all. B. It is the intent of the Contract Documents to describe a functionally complete Project (or part thereof) to be constructed in accordance with the Contract Documents. C. Unless otherwise stated in the Contract Documents, if there is a discrepancy between the electronic versions of the Contract Documents (including any printed copies derived from such electronic versions) and the printed record version, the printed record version will govern. D. The Contract supersedes prior negotiations, representations, and agreements, whether written or oral. E. Engineer will issue clarifications and interpretations of the Contract Documents as provided herein. F. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation will be deemed stricken, and all remaining provisions will continue to be valid and binding upon Owner and Contractor, which agree that the Contract Documents will be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. G. Nothing in the Contract Documents creates: 1. any contractual relationship between Owner or Engineer and any Subcontractor, Supplier, or other individual or entity performing or furnishing any of the Work, for the benefit of such Subcontractor, Supplier, or other individual or entity; or 2. any obligation on the part of Owner or Engineer to pay or to see to the payment of any money due any such Subcontractor, Supplier, or other individual or entity, except as may otherwise be required by Laws and Regulations. 3.02 Reference Standards A. Standards Specifications, Codes, Laws and Regulations 1. Reference in the Contract Documents to standard specifications, manuals, reference standards, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, means the standard specification, manual, reference standard, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Contract if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2. No provision of any such standard specification, manual, reference standard, or code, and no instruction of a Supplier, will be effective to change the duties or responsibilities of Owner, Contractor, or Engineer from those set forth in the part of the Contract Documents prepared by or for Engineer. No such provision or instruction shall be effective to assign to Owner or Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake responsibility EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 9 of 70 inconsistent with the provisions of the part of the Contract Documents prepared by or for Engineer. 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies Contractor's Verification of Figures and Field Measurements: Before undertaking each part of the Work, Contractor shall carefully study the Contract Documents, and check and verify pertinent figures and dimensions therein, particularly with respect to applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy that Contractor discovers, or has actual knowledge of, and shall not proceed with any Work affected thereby until the conflict, error, ambiguity, or discrepancy is resolved by a clarification or interpretation by Engineer, or by an amendment or supplement to the Contract issued pursuant to Paragraph 11.01. 2. Contractor's Review of Contract Documents: If, before or during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents, or between the Contract Documents and (a) any applicable Law or Regulation, (b) actual field conditions, (c) any standard specification, manual, reference standard, or code, or (d) any instruction of any Supplier, then Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 7.15) until the conflict, error, ambiguity, or discrepancy is resolved, by a clarification or interpretation by Engineer, or by an amendment or supplement to the Contract issued pursuant to Paragraph 11.01. Contractor shall not be liable to Owner or Engineer for failure to report any conflict, error, ambiguity, or discrepancy in the Contract Documents unless Contractor had actual knowledge thereof. B. Resolving Discrepancies Except as may be otherwise specifically stated in the Contract Documents, the provisions of the part of the Contract Documents prepared by or for Engineer take precedence in resolving any conflict, error, ambiguity, or discrepancy between such provisions of the Contract Documents and: a. the provisions of any standard specification, manual, reference standard, or code, or the instruction of any Supplier (whether or not specifically incorporated by reference as a Contract Document); or the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Law or Regulation). 3.04 Requirements of the Contract Documents A. During the performance of the Work and until final payment, Contractor and Owner shall submit to the Engineer in writing all matters in question concerning the requirements of the Contract Documents (sometimes referred to as requests for information or interpretation— RFls), or relating to the acceptability of the Work under the Contract Documents, as soon as possible after such matters arise. Engineer will be the initial interpreter of the requirements of the Contract Documents, and judge of the acceptability of the Work. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 10 of 70 B. Engineer will, with reasonable promptness, render a written clarification, interpretation, or decision on the issue submitted, or initiate an amendment or supplement to the Contract Documents. Engineer's written clarification, interpretation, or decision will be final and binding on Contractor, unless it appeals by submitting a Change Proposal, and on Owner, unless it appeals by filing a Claim. C. If a submitted matter in question concerns terms and conditions of the Contract Documents that do not involve (1) the performance or acceptability of the Work under the Contract Documents, (2) the design (as set forth in the Drawings, Specifications, or otherwise), or (3) other engineering or technical matters, then Engineer will promptly notify Owner and Contractor in writing that Engineer is unable to provide a decision or interpretation. If Owner and Contractor are unable to agree on resolution of such a matter in question, either party may pursue resolution as provided in Article 12. 3.05 Reuse of Documents A. Contractor and its Subcontractors and Suppliers shall not: 1. have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or its consultants, including electronic media versions, or reuse any such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaptation by Engineer; or 2. have or acquire any title or ownership rights in any other Contract Documents, reuse any such Contract Documents for any purpose without Owner's express written consent, or violate any copyrights pertaining to such Contract Documents. B. The prohibitions of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein precludes Contractor from retaining copies of the Contract Documents for record purposes. ARTICLE 4—COMMENCEMENT AND PROGRESS OF THE WORK 4.01 Commencement of Contract Times; Notice to Proceed A. The Contract Times will commence to run on the 30th day after the Effective Date of the Contract or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Contract. In no event will the Contract Times commence to run later than the 60th day after the day of Bid opening or the 30th day after the Effective Date of the Contract, whichever date is earlier. 4.02 Starting the Work A. Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work may be done at the Site prior to such date. 4.03 Reference Points A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 11 of 70 established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.04 Progress Schedule A. Contractor shall adhere to the Progress Schedule established in accordance with Paragraph 2.05 as it may be adjusted from time to time as provided below. 1. Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.05) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times. 2. Proposed adjustments in the Progress Schedule that will change the Contract Times must be submitted in accordance with the requirements of Article 11. B. Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with Owner. No Work will be delayed or postponed pending resolution of any disputes or disagreements, or during any appeal process, except as permitted by Paragraph 16.04, or as Owner and Contractor may otherwise agree in writing. 4.05 Deloys in Contractor's Progress A. If Owner, Engineer, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in Contract Price or Contract Times. B. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delay, disruption, or interference caused by or within the control of Contractor. Delay, disruption, and interference attributable to and within the control of a Subcontractor or Supplier shall be deemed to be within the control of Contractor. C. If Contractor's performance or progress is delayed, disrupted, or interfered with by unanticipated causes not the fault of and beyond the control of Owner, Contractor, and those for which they are responsible, then Contractor shall be entitled to an equitable adjustment in Contract Times. Such an adjustment will be Contractor's sole and exclusive remedy for the delays, disruption, and interference described in this paragraph. Causes of delay, disruption, or interference that may give rise to an adjustment in Contract Times under this paragraph include but are not limited to the following: 1. Severe and unavoidable natural catastrophes such as fires, floods, epidemics, and earthquakes; 2. Abnormal weather conditions; 3. Acts or failures to act of third -party utility owners or other third -party entities (other than those third -party utility owners or other third -party entities performing other work at or adjacent to the Site as arranged by or under contract with Owner, as contemplated in Article 8); and 4. Acts of war or terrorism. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 12 of 70 D. Contractor's entitlement to an adjustment of Contract Times or Contract Price is limited as follows: 1. Contractor's entitlement to an adjustment of the Contract Times is conditioned on the delay, disruption, or interference adversely affecting an activity on the critical path to completion of the Work, as of the time of the delay, disruption, or interference. 2. Contractor shall not be entitled to an adjustment in Contract Price for any delay, disruption, or interference if such delay is concurrent with a delay, disruption, or interference caused by or within the control of Contractor. Such a concurrent delay by Contractor shall not preclude an adjustment of Contract Times to which Contractor is otherwise entitled. 3. Adjustments of Contract Times or Contract Price are subject to the provisions of Article 11. E. Each Contractor request or Change Proposal seeking an increase in Contract Times or Contract Price must be supplemented by supporting data that sets forth in detail the following: 1. The circumstances that form the basis for the requested adjustment; 2. The date upon which each cause of delay, disruption, or interference began to affect the progress of the Work; 3. The date upon which each cause of delay, disruption, or interference ceased to affect the progress of the Work; 4. The number of days' increase in Contract Times claimed as a consequence of each such cause of delay, disruption, or interference; and 5. The impact on Contract Price, in accordance with the provisions of Paragraph 11.07. Contractor shall also furnish such additional supporting documentation as Owner or Engineer may require including, where appropriate, a revised progress schedule indicating all the activities affected by the delay, disruption, or interference, and an explanation of the effect of the delay, disruption, or interference on the critical path to completion of the Work. F. Delays, disruption, and interference to the performance or progress of the Work resulting from the existence of a differing subsurface or physical condition, an Underground Facility that was not shown or indicated by the Contract Documents, or not shown or indicated with reasonable accuracy, and those resulting from Hazardous Environmental Conditions, are governed by Article 5, together with the provisions of Paragraphs 4.05.1) and 4.05.E. G. Paragraph 8.03 addresses delays, disruption, and interference to the performance or progress of the Work resulting from the performance of certain other work at or adjacent to the Site. ARTICLE 5—SITE; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONMENTAL CONDITIONS 5.01 Availability of Lands A. Owner shall furnish the Site. Owner shall notify Contractor in writing of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 13 of 70 B. Upon reasonable written request, Owner shall furnish Contractor with a current statement of record legal title and legal description of the lands upon which permanent improvements are to be made and Owner's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. C. Contractor shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 5.02 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas Contractor shall confine construction equipment, temporary construction facilities, the storage of materials and equipment, and the operations of workers to the Site, adjacent areas that Contractor has arranged to use through construction easements or otherwise, and other adjacent areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and such other adjacent areas with construction equipment or other materials or equipment. Contractor shall assume full responsibility for (a) damage to the Site; (b) damage to any such other adjacent areas used for Contractor's operations; (c) damage to any other adjacent land or areas, or to improvements, structures, utilities, or similar facilities located at such adjacent lands or areas; and (d) for injuries and losses sustained by the owners or occupants of any such land or areas; provided that such damage or injuries result from the performance of the Work or from other actions or conduct of the Contractor or those for which Contractor is responsible. 2. If a damage or injury claim is made by the owner or occupant of any such land or area because of the performance of the Work, or because of other actions or conduct of the Contractor or those for which Contractor is responsible, Contractor shall (a) take immediate corrective or remedial action as required by Paragraph 7.13, or otherwise; (b) promptly attempt to settle the claim as to all parties through negotiations with such owner or occupant, or otherwise resolve the claim by arbitration or other dispute resolution proceeding, or in a court of competent jurisdiction; and (c) to the fullest extent permitted by Laws and Regulations, indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them, from and against any such claim, and against all costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused directly or indirectly, in whole or in part by, or based upon, Contractor's performance of the Work, or because of other actions or conduct of the Contractor or those for which Contractor is responsible. B. Removal of Debris During Performance of the Work: During the progress of the Work the Contractor shall keep the Site and other adjacent areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris will conform to applicable Laws and Regulations. C. Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the completion of the Work Contractor shall remove from the Site and adjacent areas all tools, appliances, construction equipment EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 14 of 70 and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading of Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent structures or land to stresses or pressures that will endanger them. 5.03 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: 1. Those reports of explorations and tests of subsurface conditions at or adjacent to the Site that contain Technical Data; 2. Those drawings of existing physical conditions at or adjacent to the Site, including those drawings depicting existing surface or subsurface structures at or adjacent to the Site (except Underground Facilities), that contain Technical Data; and 3. Technical Data contained in such reports and drawings. B. Underground Facilities: Underground Facilities are shown or indicated on the Drawings, pursuant to Paragraph 5.05, and not in the drawings referred to in Paragraph 5.03.A. Information and data regarding the presence or location of Underground Facilities are not intended to be categorized, identified, or defined as Technical Data. C. Reliance by Contractor on Technical Data: Contractor may rely upon the accuracy of the Technical Data expressly identified in the Supplementary Conditions with respect to such reports and drawings, but such reports and drawings are not Contract Documents. If no such express identification has been made, then Contractor may rely upon the accuracy of the Technical Data as defined in Paragraph 1.01.A.46.b. D. Limitations of Other Data and Documents: Except for such reliance on Technical Data, Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; 3. the contents of other Site -related documents made available to Contractor, such as record drawings from other projects at or adjacent to the Site, or Owner's archival documents concerning the Site; or 4. any Contractor interpretation of or conclusion drawn from any Technical Data or any such other data, interpretations, opinions, or information. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 15 of 70 5.04 Differing Subsurface or Physical Conditions A. Notice by Contractor: If Contractor believes that any subsurface or physical condition that is uncovered or revealed at the Site: 1. is of such a nature as to establish that any Technical Data on which Contractor is entitled to rely as provided in Paragraph 5.03 is materially inaccurate; 2. is of such a nature as to require a change in the Drawings or Specifications; 3. differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connection therewith (except in an emergency as required by Paragraph 7.15), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except with respect to an emergency) until receipt of a written statement permitting Contractor to do so. B. Engineer's Review: After receipt of written notice as required by the preceding paragraph, Engineer will promptly review the subsurface or physical condition in question; determine whether it is necessary for Owner to obtain additional exploration or tests with respect to the condition; conclude whether the condition falls within any one or more of the differing site condition categories in Paragraph 5.04.A; obtain any pertinent cost or schedule information from Contractor; prepare recommendations to Owner regarding the Contractor's resumption of Work in connection with the subsurface or physical condition in question and the need for any change in the Drawings or Specifications; and advise Owner in writing of Engineer's findings, conclusions, and recommendations. C. Owner's Statement to Contractor Regarding Site Condition: After receipt of Engineer's written findings, conclusions, and recommendations, Owner shall issue a written statement to Contractor (with a copy to Engineer) regarding the subsurface or physical condition in question, addressing the resumption of Work in connection with such condition, indicating whether any change in the Drawings or Specifications will be made, and adopting or rejecting Engineer's written findings, conclusions, and recommendations, in whole or in part. D. Early Resumption of Work: If at any time Engineer determines that Work in connection with the subsurface or physical condition in question may resume priorto completion of Engineer's review or Owner's issuance of its statement to Contractor, because the condition in question has been adequately documented, and analyzed on a preliminary basis, then the Engineer may at its discretion instruct Contractor to resume such Work. E. Possible Price and Times Adjustments 1. Contractor shall be entitled to an equitable adjustment in Contract Price or Contract Times, to the extent that the existence of a differing subsurface or physical condition, or any related delay, disruption, or interference, causes an increase or decrease in EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 16 of 70 Contractor's cost of, or time required for, performance of the Work; subject, however, to the following: a. Such condition must fall within any one or more of the categories described in Paragraph 5.04.A; b. With respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraph 13.03; and, c. Contractor's entitlement to an adjustment of the Contract Times is subject to the provisions of Paragraphs 4.05.1) and 4.05.E. 2. Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times with respect to a subsurface or physical condition if: a. Contractor knew of the existence of such condition at the time Contractor made a commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract, or otherwise; b. The existence of such condition reasonably could have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and contiguous areas expressly required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor's making such commitment; or c. Contractor failed to give the written notice required by Paragraph 5.04.A. 3. If Owner and Contractor agree regarding Contractor's entitlement to and the amount or extent of any adjustment in the Contract Price or Contract Times, then any such adjustment will be set forth in a Change Order. 4. Contractor may submit a Change Proposal regarding its entitlement to or the amount or extent of any adjustment in the Contract Price or Contract Times, no later than 30 days after Owner's issuance of the Owner's written statement to Contractor regarding the subsurface or physical condition in question. F. Underground Facilities; Hazardous Environmental Conditions: Paragraph 5.05 governs rights and responsibilities regarding the presence or location of Underground Facilities. Paragraph 5.06 governs rights and responsibilities regarding Hazardous Environmental Conditions. The provisions of Paragraphs 5.03 and 5.04 are not applicable to the presence or location of Underground Facilities, or to Hazardous Environmental Conditions. 5.05 Underground Facilities A. Contractor's Responsibilities: Unless it is otherwise expressly provided in the Supplementary Conditions, the cost of all of the following are included in the Contract Price, and Contractor shall have full responsibility for: 1. reviewing and checking all information and data regarding existing Underground Facilities at the Site; 2. complying with applicable state and local utility damage prevention Laws and Regulations; EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 17 of 70 3. verifying the actual location of those Underground Facilities shown or indicated in the Contract Documents as being within the area affected by the Work, by exposing such Underground Facilities during the course of construction; 4. coordination of the Work with the owners (including Owner) of such Underground Facilities, during construction; and 5. the safety and protection of all existing Underground Facilities at the Site, and repairing any damage thereto resulting from the Work. B. Notice by Contractor: If Contractor believes that an Underground Facility that is uncovered or revealed at the Site was not shown or indicated on the Drawings, or was not shown or indicated on the Drawings with reasonable accuracy, then Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 7.15), notify Owner and Engineer in writing regarding such Underground Facility. C. Engineer's Review: Engineer will: 1. promptly review the Underground Facility and conclude whether such Underground Facility was not shown or indicated on the Drawings, or was not shown or indicated with reasonable accuracy; 2. identify and communicate with the owner of the Underground Facility; prepare recommendations to Owner (and if necessary issue any preliminary instructions to Contractor) regarding the Contractor's resumption of Work in connection with the Underground Facility in question; 3. obtain any pertinent cost or schedule information from Contractor; determine the extent, if any, to which a change is required in the Drawings or Specifications to reflect and document the consequences of the existence or location of the Underground Facility; and 4. advise Owner in writing of Engineer's findings, conclusions, and recommendations. During such time, Contractor shall be responsible for the safety and protection of such Underground Facility. D. Owner's Statement to Contractor Regarding Underground Facility: After receipt of Engineer's written findings, conclusions, and recommendations, Owner shall issue a written statement to Contractor (with a copy to Engineer) regarding the Underground Facility in question addressing the resumption of Work in connection with such Underground Facility, indicating whether any change in the Drawings or Specifications will be made, and adopting or rejecting Engineer's written findings, conclusions, and recommendations in whole or in part. E. Early Resumption of Work: If at any time Engineer determines that Work in connection with the Underground Facility may resume prior to completion of Engineer's review or Owner's issuance of its statement to Contractor, because the Underground Facility in question and conditions affected by its presence have been adequately documented, and analyzed on a preliminary basis, then the Engineer may at its discretion instruct Contractor to resume such Work. F. Possible Price and Times Adjustments 1. Contractor shall be entitled to an equitable adjustment in the Contract Price or Contract Times, to the extent that any existing Underground Facility at the Site that was not shown EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 18 of 70 or indicated on the Drawings, or was not shown or indicated with reasonable accuracy, or any related delay, disruption, or interference, causes an increase or decrease in Contractor's cost of, or time required for, performance of the Work; subject, however, to the following: a. With respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraph 13.03; b. Contractor's entitlement to an adjustment of the Contract Times is subject to the provisions of Paragraphs 4.05.D and 4.05.E; and c. Contractor gave the notice required in Paragraph 5.05.B. 2. If Owner and Contractor agree regarding Contractor's entitlement to and the amount or extent of any adjustment in the Contract Price or Contract Times, then any such adjustment will be set forth in a Change Order. 3. Contractor may submit a Change Proposal regarding its entitlement to or the amount or extent of any adjustment in the Contract Price or Contract Times, no later than 30 days after Owner's issuance of the Owner's written statement to Contractor regarding the Underground Facility in question. 4. The information and data shown or indicated on the Drawings with respect to existing Underground Facilities at the Site is based on information and data (a) furnished by the owners of such Underground Facilities, or by others, (b) obtained from available records, or (c) gathered in an investigation conducted in accordance with the current edition of ASCE 38, Standard Guideline for the Collection and Depiction of Existing Subsurface Utility Data, by the American Society of Civil Engineers. If such information or data is incorrect or incomplete, Contractor's remedies are limited to those set forth in this Paragraph 5.05.F. 5.06 Hazardous Environmental Conditions at Site A. Reports and Drawings: The Supplementary Conditions identify: 1. those reports known to Owner relating to Hazardous Environmental Conditions that have been identified at or adjacent to the Site; 2. drawings known to Owner relating to Hazardous Environmental Conditions that have been identified at or adjacent to the Site; and 3. Technical Data contained in such reports and drawings. B. Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the accuracy of the Technical Data expressly identified in the Supplementary Conditions with respect to such reports and drawings, but such reports and drawings are not Contract Documents. If no such express identification has been made, then Contractor may rely on the accuracy of the Technical Data as defined in Paragraph 1.01.A.46.b. Except for such reliance on Technical Data, Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 19 of 70 of construction to be employed by Contractor, and safety precautions and programs incident thereto; 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any Technical Data or any such other data, interpretations, opinions or information. C. Contractor shall not be responsible for removing or remediating any Hazardous Environmental Condition encountered, uncovered, or revealed at the Site unless such removal or remediation is expressly identified in the Contract Documents to be within the scope of the Work. D. Contractor shall be responsible for controlling, containing, and duly removing all Constituents of Concern brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible, and for any associated costs; and for the costs of removing and remediating any Hazardous Environmental Condition created by the presence of any such Constituents of Concern. E. If Contractor encounters, uncovers, or reveals a Hazardous Environmental Condition whose removal or remediation is not expressly identified in the Contract Documents as being within the scope of the Work, or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, then Contractor shall immediately: (1) secure or otherwise isolate such condition; (2) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by Paragraph 7.15); and (3) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. Promptly after consulting with Engineer, Owner shall take such actions as are necessary to permit Owner to timely obtain required permits and provide Contractor the written notice required by Paragraph 5.06.F. If Contractor or anyone for whom Contractor is responsible created the Hazardous Environmental Condition in question, then Owner may remove and remediate the Hazardous Environmental Condition, and impose a set-off against payments to account for the associated costs. F. Contractor shall not resume Work in connection with such Hazardous Environmental Condition or in any affected area until after Owner has obtained any required permits related thereto, and delivered written notice to Contractor either (1) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work, or (2) specifying any special conditions under which such Work may be resumed safely. G. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, as a result of such Work stoppage, such special conditions under which Work is agreed to be resumed by Contractor, or any costs or expenses incurred in response to the Hazardous Environmental Condition, then within 30 days of Owner's written notice regarding the resumption of Work, Contractor may submit a Change Proposal, or Owner may impose a set-off. Entitlement to any such adjustment is subject to the provisions of Paragraphs 4.05.D, 4.05.E, 11.07, and 11.08. H. If, after receipt of such written notice, Contractor does not agree to resume such Work based on a reasonable belief it is unsafe, or does not agree to resume such Work under such special EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 20 of 70 conditions, then Owner may order the portion of the Work that is in the area affected by such condition to be deleted from the Work, following the contractual change procedures in Article 11. Owner may have such deleted portion of the Work performed by Owner's own forces or others in accordance with Article 8. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court, arbitration, or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition (1) was not shown or indicated in the Drawings, Specifications, or other Contract Documents, identified as Technical Data entitled to limited reliance pursuant to Paragraph 5.06.B, or identified in the Contract Documents to be included within the scope of the Work, and (2) was not created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 5.06.1 obligates Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. J. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to the failure to control, contain, or remove a Constituent of Concern brought to the Site by Contractor or by anyone for whom Contractor is responsible, or to a Hazardous Environmental Condition created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 5.06.J obligates Contractor to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. K. The provisions of Paragraphs 5.03, 5.04, and 5.05 do not apply to the presence of Constituents of Concern or to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 6—BONDS AND INSURANCE 6.01 Performance, Payment, and Other Bonds A. Contractor shall furnish a performance bond and a payment bond, each in an amount at least equal to the Contract Price, as security for the faithful performance and payment of Contractor's obligations under the Contract. These bonds must remain in effect until one year after the date when final payment becomes due or until completion of the correction period specified in Paragraph 15.08, whichever is later, except as provided otherwise by Laws or Regulations, the terms of a prescribed bond form, the Supplementary Conditions, or other provisions of the Contract. B. Contractor shall also furnish such other bonds (if any) as are required by the Supplementary Conditions or other provisions of the Contract. C. All bonds must be in the form included in the Bidding Documents or otherwise specified by Owner prior to execution of the Contract, except as provided otherwise by Laws or EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 21 of 70 Regulations, and must be issued and signed by a surety named in "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Department Circular 570 (as amended and supplemented) by the Bureau of the Fiscal Service, U.S. Department of the Treasury. A bond signed by an agent or attorney -in -fact must be accompanied by a certified copy of that individual's authority to bind the surety. The evidence of authority must show that it is effective on the date the agent or attorney -in -fact signed the accompanying bond. D. Contractor shall obtain the required bonds from surety companies that are duly licensed or authorized, in the state or jurisdiction in which the Project is located, to issue bonds in the required amounts. E. If the surety on a bond furnished by Contractor is declared bankrupt or becomes insolvent, or the surety ceases to meet the requirements above, then Contractor shall promptly notify Owner and Engineer in writing and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of which must comply with the bond and surety requirements above. F. If Contractor has failed to obtain a required bond, Owner may exclude the Contractor from the Site and exercise Owner's termination rights under Article 16. G. Upon request to Owner from any Subcontractor, Supplier, or other person or entity claiming to have furnished labor, services, materials, or equipment used in the performance of the Work, Owner shall provide a copy of the payment bond to such person or entity. H. Upon request to Contractor from any Subcontractor, Supplier, or other person or entity claiming to have furnished labor, services, materials, or equipment used in the performance of the Work, Contractor shall provide a copy of the payment bond to such person or entity. 6.02 Insurance —General Provisions A. Owner and Contractor shall obtain and maintain insurance as required in this article and in the Supplementary Conditions. B. All insurance required by the Contract to be purchased and maintained by Owner or Contractor shall be obtained from insurance companies that are duly licensed or authorized in the state or jurisdiction in which the Project is located to issue insurance policies for the required limits and coverages. Unless a different standard is indicated in the Supplementary Conditions, all companies that provide insurance policies required under this Contract shall have an A.M. Best rating of A-VII or better. C. Alternative forms of insurance coverage, including but not limited to self-insurance and "Occupational Accident and Excess Employer's Indemnity Policies," are not sufficient to meet the insurance requirements of this Contract, unless expressly allowed in the Supplementary Conditions. D. Contractor shall deliver to Owner, with copies to each additional insured identified in the Contract, certificates of insurance and endorsements establishing that Contractor has obtained and is maintaining the policies and coverages required by the Contract. Upon request by Owner or any other insured, Contractor shall also furnish other evidence of such required insurance, including but not limited to copies of policies, documentation of applicable self -insured retentions (if allowed) and deductibles, full disclosure of all relevant exclusions, and evidence of insurance required to be purchased and maintained by EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 22 of 70 Subcontractors or Suppliers. In any documentation furnished under this provision, Contractor, Subcontractors, and Suppliers may block out (redact) (1) any confidential premium or pricing information and (2) any wording specific to a project or jurisdiction other than those applicable to this Contract. E. Owner shall deliver to Contractor, with copies to each additional insured identified in the Contract, certificates of insurance and endorsements establishing that Owner has obtained and is maintaining the policies and coverages required of Owner by the Contract (if any). Upon request by Contractor or any other insured, Owner shall also provide other evidence of such required insurance (if any), including but not limited to copies of policies, documentation of applicable self -insured retentions (if allowed) and deductibles, and full disclosure of all relevant exclusions. In any documentation furnished under this provision, Owner may block out (redact) (1) any confidential premium or pricing information and (2) any wording specific to a project or jurisdiction other than those relevant to this Contract. F. Failure of Owner or Contractor to demand such certificates or other evidence of the other party's full compliance with these insurance requirements, or failure of Owner or Contractor to identify a deficiency in compliance from the evidence provided, will not be construed as a waiver of the other party's obligation to obtain and maintain such insurance. G. In addition to the liability insurance required to be provided by Contractor, the Owner, at Owner's option, may purchase and maintain Owner's own liability insurance. Owner's liability policies, if any, operate separately and independently from policies required to be provided by Contractor, and Contractor cannot rely upon Owner's liability policies for any of Contractor's obligations to the Owner, Engineer, or third parties. H. Contractor shall require: 1. Subcontractors to purchase and maintain worker's compensation, commercial general liability, and other insurance that is appropriate for their participation in the Project, and to name as additional insureds Owner and Engineer (and any other individuals or entities identified in the Supplementary Conditions as additional insureds on Contractor's liability policies) on each Subcontractor's commercial general liability insurance policy; and 2. Suppliers to purchase and maintain insurance that is appropriate for their participation in the Project. If either party does not purchase or maintain the insurance required of such party by the Contract, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. If Contractor has failed to obtain and maintain required insurance, Contractor's entitlement to enter or remain at the Site will end immediately, and Owner may impose an appropriate set-off against payment for any associated costs (including but not limited to the cost of purchasing necessary insurance coverage), and exercise Owner's termination rights under Article 16. K. Without prejudice to any other right or remedy, if a party has failed to obtain required insurance, the other party may elect (but is in no way obligated) to obtain equivalent insurance to protect such other party's interests at the expense of the party who was required to provide such coverage, and the Contract Price will be adjusted accordingly. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 23 of 70 L. Owner does not represent that insurance coverage and limits established in this Contract necessarily will be adequate to protect Contractor or Contractor's interests. Contractor is responsible for determining whether such coverage and limits are adequate to protect its interests, and for obtaining and maintaining any additional insurance that Contractor deems necessary. M. The insurance and insurance limits required herein will not be deemed as a limitation on Contractor's liability, or that of its Subcontractors or Suppliers, under the indemnities granted to Owner and other individuals and entities in the Contract or otherwise. N. All the policies of insurance required to be purchased and maintained under this Contract will contain a provision or endorsement that the coverage afforded will not be canceled, or renewal refused, until at least 10 days prior written notice has been given to the purchasing policyholder. Within three days of receipt of any such written notice, the purchasing policyholder shall provide a copy of the notice to each other insured and Engineer. 6.03 Contractor's Insurance A. Required Insurance: Contractor shall purchase and maintain Worker's Compensation, Commercial General Liability, and other insurance pursuant to the specific requirements of the Supplementary Conditions. B. General Provisions: The policies of insurance required by this Paragraph 6.03 as supplemented must: 1. include at least the specific coverages required; 2. be written for not less than the limits provided, or those required by Laws or Regulations, whichever is greater; 3. remain in effect at least until the Work is complete (as set forth in Paragraph 15.06.1)), and longer if expressly required elsewhere in this Contract, and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work as a warranty or correction obligation, or otherwise, or returning to the Site to conduct other tasks arising from the Contract; 4. apply with respect to the performance of the Work, whether such performance is by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable; and 5. include all necessary endorsements to support the stated requirements. C. Additional Insureds: The Contractor's commercial general liability, automobile liability, employer's liability, umbrella or excess, pollution liability, and unmanned aerial vehicle liability policies, if required by this Contract, must: 1. include and list as additional insureds Owner and Engineer, and any individuals or entities identified as additional insureds in the Supplementary Conditions; 2. include coverage for the respective officers, directors, members, partners, employees, and consultants of all such additional insureds; 3. afford primary coverage to these additional insureds for all claims covered thereby (including as applicable those arising from both ongoing and completed operations); EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 24 of 70 4. not seek contribution from insurance maintained by the additional insured; and as to commercial general liability insurance, apply to additional insureds with respect to liability caused in whole or in part by Contractor's acts or omissions, or the acts and omissions of those working on Contractor's behalf, in the performance of Contractor's operations. 6.04 Builder's Risk and Other Property Insurance A. Builder's Risk: Unless otherwise provided in the Supplementary Conditions, Contractor shall purchase and maintain builder's risk insurance upon the Work on a completed value basis, in the amount of the Work's full insurable replacement cost (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). The specific requirements applicable to the builder's risk insurance are set forth in the Supplementary Conditions. B. Property Insurance for Facilities of Owner Where Work Will Occur: Owner is responsible for obtaining and maintaining property insurance covering each existing structure, building, or facility in which any part of the Work will occur, or to which any part of the Work will attach or be adjoined. Such property insurance will be written on a special perils (all-risk) form, on a replacement cost basis, providing coverage consistent with that required for the builder's risk insurance, and will be maintained until the Work is complete, as set forth in Paragraph 15.06.D. C. Property Insurance for Substantially Complete Facilities: Promptly after Substantial Completion, and before actual occupancy or use of the substantially completed Work, Owner will obtain property insurance for such substantially completed Work, and maintain such property insurance at least until the Work is complete, as set forth in Paragraph 15.06.D. Such property insurance will be written on a special perils (all-risk) form, on a replacement cost basis, and provide coverage consistent with that required for the builder's risk insurance. The builder's risk insurance may terminate upon written confirmation of Owner's procurement of such property insurance. D. Partial Occupancy or Use by Owner: If Owner will occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work, as provided in Paragraph 15.04, then Owner (directly, if it is the purchaser of the builder's risk policy, or through Contractor) will provide advance notice of such occupancy or use to the builder's risk insurer, and obtain an endorsement consenting to the continuation of coverage prior to commencing such partial occupancy or use. E. Insurance of Other Property; Additional Insurance: If the express insurance provisions of the Contract do not require or address the insurance of a property item or interest, then the entity or individual owning such property item will be responsible for insuring it. If Contractor elects to obtain other special insurance to be included in or supplement the builder's risk or property insurance policies provided under this Paragraph 6.04, it may do so at Contractor's expense. 6.05 Property Losses, Subrogation A. The builder's risk insurance policy purchased and maintained in accordance with Paragraph 6.04 (or an installation floater policy if authorized by the Supplementary Conditions), will contain provisions to the effect that in the event of payment of any loss or damage the insurer will have no rights of recovery against any insureds thereunder, or against EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 25 of 70 Engineer or its consultants, or their officers, directors, members, partners, employees, agents, consultants, or subcontractors. 1. Owner and Contractor waive all rights against each other and the respective officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, for all losses and damages caused by, arising out of, or resulting from any of the perils, risks, or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Engineer, its consultants, all individuals or entities identified in the Supplementary Conditions as builder's risk or installation floater insureds, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, under such policies for losses and damages so caused. 2. None of the above waivers extends to the rights that any party making such waiver may have to the proceeds of insurance held by Owner or Contractor as trustee or fiduciary, or otherwise payable under any policy so issued. B. Any property insurance policy maintained by Owner covering any loss, damage, or consequential loss to Owner's existing structures, buildings, or facilities in which any part of the Work will occur, or to which any part of the Work will attach or adjoin; to adjacent structures, buildings, or facilities of Owner; or to part or all of the completed or substantially completed Work, during partial occupancy or use pursuant to Paragraph 15.04, after Substantial Completion pursuant to Paragraph 15.03, or after final payment pursuant to Paragraph 15.06, will contain provisions to the effect that in the event of payment of any loss or damage the insurer will have no rights of recovery against any insureds thereunder, or against Contractor, Subcontractors, or Engineer, or the officers, directors, members, partners, employees, agents, consultants, or subcontractors of each and any of them, and that the insured is allowed to waive the insurer's rights of subrogation in a written contract executed prior to the loss, damage, or consequential loss. 1. Owner waives all rights against Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them, for all losses and damages caused by, arising out of, or resulting from fire or any of the perils, risks, or causes of loss covered by such policies. C. The waivers in this Paragraph 6.05 include the waiver of rights due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner's property or the Work caused by, arising out of, or resulting from fire or other insured peril, risk, or cause of loss. D. Contractor shall be responsible for assuring that each Subcontract contains provisions whereby the Subcontractor waives all rights against Owner, Contractor, all individuals or entities identified in the Supplementary Conditions as insureds, the Engineer and its consultants, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, for all losses and damages caused by, arising out of, relating to, or resulting from fire or other peril, risk, or cause of loss covered by builder's risk insurance, installation floater, and any other property insurance applicable to the Work. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 26 of 70 6.06 Receipt and Application of Property Insurance Proceeds A. Any insured loss under the builder's risk and other policies of property insurance required by Paragraph 6.04 will be adjusted and settled with the named insured that purchased the policy. Such named insured shall act as fiduciary for the other insureds, and give notice to such other insureds that adjustment and settlement of a claim is in progress. Any other insured may state its position regarding a claim for insured loss in writing within 15 days after notice of such claim. B. Proceeds for such insured losses may be made payable by the insurer eitherjointly to multiple insureds, or to the named insured that purchased the policy in its own right and as fiduciary for other insureds, subject to the requirements of any applicable mortgage clause. A named insured receiving insurance proceeds under the builder's risk and other policies of insurance required by Paragraph 6.04 shall maintain such proceeds in a segregated account, and distribute such proceeds in accordance with such agreement as the parties in interest may reach, or as otherwise required under the dispute resolution provisions of this Contract or applicable Laws and Regulations. C. If no other special agreement is reached, Contractor shall repair or replace the damaged Work, using allocated insurance proceeds. ARTICLE 7—CONTRACTOR'S RESPONSIBILITIES 7.01 Contractor's Means and Methods of Construction A. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. B. If the Contract Documents note, or Contractor determines, that professional engineering or other design services are needed to carry out Contractor's responsibilities for construction means, methods, techniques, sequences, and procedures, or for Site safety, then Contractor shall cause such services to be provided by a properly licensed design professional, at Contractor's expense. Such services are not Owner -delegated professional design services under this Contract, and neither Owner nor Engineer has any responsibility with respect to (1) Contractor's determination of the need for such services, (2) the qualifications or licensing of the design professionals retained or employed by Contractor, (3) the performance of such services, or (4) any errors, omissions, or defects in such services. 7.02 Supervision and Superintendence A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. B. At all times during the progress of the Work, Contractor shall assign a competent resident superintendent who will not be replaced without written notice to Owner and Engineer except under extraordinary circumstances. 7.03 Labor, Working Hours A. Contractor shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Documents. Contractor shall maintain good discipline and order at the Site. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 27 of 70 B. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of Contractor's employees; of Suppliers and Subcontractors, and their employees; and of any other individuals or entities performing or furnishing any of the Work, just as Contractor is responsible for Contractor's own acts and omissions. C. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site will be performed during regular working hours, Monday through Friday. Contractor will not perform Work on a Saturday, Sunday, or any legal holiday. Contractor may perform Work outside regular working hours or on Saturdays, Sundays, or legal holidays only with Owner's written consent, which will not be unreasonably withheld. 7.04 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start up, and completion of the Work, whether or not such items are specifically called for in the Contract Documents. B. All materials and equipment incorporated into the Work must be new and of good quality, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications will expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment must be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 7.05 "Or Equals" A. Contractor's Request; Governing Criteria: Whenever an item of equipment or material is specified or described in the Contract Documents by using the names of one or more proprietary items or specific Suppliers, the Contract Price has been based upon Contractor furnishing such item as specified. The specification or description of such an item is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or equal" item is permitted, Contractor may request that Engineer authorize the use of other items of equipment or material, or items from other proposed Suppliers, under the circumstances described below. 1. If Engineer in its sole discretion determines that an item of equipment or material proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, Engineer will deem it an "or equal" item. For the purposes of this paragraph, a proposed item of equipment or material will be considered functionally equal to an item so named if: a. in the exercise of reasonable judgment Engineer determines that the proposed item: 1) is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 28 of 70 2) will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole; 3) has a proven record of performance and availability of responsive service; and 4) is not objectionable to Owner. b. Contractor certifies that, if the proposed item is approved and incorporated into the Work: 1) there will be no increase in cost to the Owner or increase in Contract Times; and 2) the item will conform substantially to the detailed requirements of the item named in the Contract Documents. B. Contractor's Expense: Contractor shall provide all data in support of any proposed "or equal" item at Contractor's expense. C. Engineer's Evaluation and Determination: Engineer will be allowed a reasonable time to evaluate each "or -equal" request. Engineer may require Contractor to furnish additional data about the proposed "or -equal" item. Engineer will be the sole judge of acceptability. No "or - equal" item will be ordered, furnished, installed, or utilized until Engineer's review is complete and Engineer determines that the proposed item is an "or -equal," which will be evidenced by an approved Shop Drawing or other written communication. Engineer will advise Contractor in writing of any negative determination. D. Effect of Engineer's Determination: Neither approval nor denial of an "or -equal" request will result in any change in Contract Price. The Engineer's denial of an "or -equal" request will be final and binding, and may not be reversed through an appeal under any provision of the Contract. E. Treatment as a Substitution Request: If Engineer determines that an item of equipment or material proposed by Contractor does not qualify as an "or -equal" item, Contractor may request that Engineer consider the item a proposed substitute pursuant to Paragraph 7.06. 7.06 Substitutes A. Contractor's Request; Governing Criteria: Unless the specification or description of an item of equipment or material required to be furnished under the Contract Documents contains or is followed by words reading that no substitution is permitted, Contractor may request that Engineer authorize the use of other items of equipment or material under the circumstances described below. To the extent possible such requests must be made before commencement of related construction at the Site. 1. Contractor shall submit sufficient information as provided below to allow Engineer to determine if the item of material or equipment proposed is functionally equivalent to that named and an acceptable substitute therefor. Engineer will not accept requests for review of proposed substitute items of equipment or material from anyone other than Contractor. 2. The requirements for review by Engineer will be as set forth in Paragraph 7.06.13, as supplemented by the Specifications, and as Engineer may decide is appropriate under the circumstances. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 29 of 70 3. Contractor shall make written application to Engineer for review of a proposed substitute item of equipment or material that Contractor seeks to furnish or use. The application: a. will certify that the proposed substitute item will: 1) perform adequately the functions and achieve the results called for by the general design; 2) be similar in substance to the item specified; and 3) be suited to the same use as the item specified. b. will state: 1) the extent, if any, to which the use of the proposed substitute item will necessitate a change in Contract Times; 2) whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item; and 3) whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty. c. will identify: 1) all variations of the proposed substitute item from the item specified; and 2) available engineering, sales, maintenance, repair, and replacement services. d. will contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including but not limited to changes in Contract Price, shared savings, costs of redesign, and claims of other contractors affected by any resulting change. B. Engineer's Evaluation and Determination: Engineer will be allowed a reasonable time to evaluate each substitute request, and to obtain comments and direction from Owner. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No substitute will be ordered, furnished, installed, or utilized until Engineer's review is complete and Engineer determines that the proposed item is an acceptable substitute. Engineer's determination will be evidenced by a Field Order or a proposed Change Order accounting for the substitution itself and all related impacts, including changes in Contract Price or Contract Times. Engineer will advise Contractor in writing of any negative determination. C. Special Guarantee: Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. D. Reimbursement of Engineer's Cost: Engineer will record Engineer's costs in evaluating a substitute proposed or submitted by Contractor. Whether or not Engineer approves a substitute so proposed or submitted by Contractor, Contractor shall reimburse Owner for the reasonable charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the reasonable charges of Engineer for making changes in the Contract Documents (or in the provisions of any other direct contract with Owner) resulting from the acceptance of each proposed substitute. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 30 of 70 E. Contractor's Expense: Contractor shall provide all data in support of any proposed substitute at Contractor's expense. F. Effect of Engineer's Determination: If Engineer approves the substitution request, Contractor shall execute the proposed Change Order and proceed with the substitution. The Engineer's denial of a substitution request will be final and binding, and may not be reversed through an appeal under any provision of the Contract. Contractor may challenge the scope of reimbursement costs imposed under Paragraph 7.06.D, by timely submittal of a Change Proposal. 7.07 Concerning Subcontractors and Suppliers A. Contractor may retain Subcontractors and Suppliers for the performance of parts of the Work. Such Subcontractors and Suppliers must be acceptable to Owner. The Contractor's retention of a Subcontractor or Supplier for the performance of parts of the Work will not relieve Contractor's obligation to Owner to perform and complete the Work in accordance with the Contract Documents. B. Contractor shall retain specific Subcontractors and Suppliers for the performance of designated parts of the Work if required by the Contract to do so. C. Subsequent to the submittal of Contractor's Bid or final negotiation of the terms of the Contract, Owner may not require Contractor to retain any Subcontractor or Supplier to furnish or perform any of the Work against which Contractor has reasonable objection. D. Prior to entry into any binding subcontract or purchase order, Contractor shall submit to Owner the identity of the proposed Subcontractor or Supplier (unless Owner has already deemed such proposed Subcontractor or Supplier acceptable during the bidding process or otherwise). Such proposed Subcontractor or Supplier shall be deemed acceptable to Owner unless Owner raises a substantive, reasonable objection within 5 days. E. Owner may require the replacement of any Subcontractor or Supplier. Owner also may require Contractor to retain specific replacements; provided, however, that Owner may not require a replacement to which Contractor has a reasonable objection. If Contractor has submitted the identity of certain Subcontractors or Suppliers for acceptance by Owner, and Owner has accepted it (either in writing or by failing to make written objection thereto), then Owner may subsequently revoke the acceptance of any such Subcontractor or Supplier so identified solely on the basis of substantive, reasonable objection after due investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor or Supplier. F. If Owner requires the replacement of any Subcontractor or Supplier retained by Contractor to perform any part of the Work, then Contractor shall be entitled to an adjustment in Contract Price or Contract Times, with respect to the replacement; and Contractor shall initiate a Change Proposal for such adjustment within 30 days of Owner's requirement of replacement. G. No acceptance by Owner of any such Subcontractor or Supplier, whether initially or as a replacement, will constitute a waiver of the right of Owner to the completion of the Work in accordance with the Contract Documents. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 31 of 70 H. On a monthly basis, Contractor shall submit to Engineer a complete list of all Subcontractors and Suppliers having a direct contract with Contractor, and of all other Subcontractors and Suppliers known to Contractor at the time of submittal. Contractor shall be solely responsible for scheduling and coordinating the work of Subcontractors and Suppliers. J. The divisions and sections of the Specifications and the identifications of any Drawings do not control Contractor in dividing the Work among Subcontractors or Suppliers, or in delineating the Work to be performed by any specific trade. K. All Work performed for Contractor by a Subcontractor or Supplier must be pursuant to an appropriate contractual agreement that specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract for the benefit of Owner and Engineer. L. Owner may furnish to any Subcontractor or Supplier, to the extent practicable, information about amounts paid to Contractor for Work performed for Contractor by the Subcontractor or Supplier. M. Contractor shall restrict all Subcontractors and Suppliers from communicating with Engineer or Owner, except through Contractor or in case of an emergency, or as otherwise expressly allowed in this Contract. 7.08 Patent Fees and Royalties A. Contractor shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If an invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if, to the actual knowledge of Owner or Engineer, its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights will be disclosed in the Contract Documents. B. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, and its officers, directors, members, partners, employees, agents, consultants, and subcontractors, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device specified in the Contract Documents, but not identified as being subject to payment of any license fee or royalty to others required by patent rights or copyrights. C. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 32 of 70 7.09 Permits A. Unless otherwise provided in the Contract Documents, Contractor shall obtain and pay for all construction permits, licenses, and certificates of occupancy. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of the submission of Contractor's Bid (or when Contractor became bound under a negotiated contract). Owner shall pay all charges of utility owners for connections for providing permanent service to the Work. 7.10 Taxes A. Contractor shall pay all sales, consumer, use, and other similar taxes required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work. 7.11 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Neither Owner nor Engineer shall be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work or takes any other action knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all resulting costs and losses, and shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work or other action. It is not Contractor's responsibility to make certain that the Work described in the Contract Documents is in accordance with Laws and Regulations, but this does not relieve Contractor of its obligations under Paragraph 3.03. C. Owner or Contractor may give written notice to the other party of any changes after the submission of Contractor's Bid (or after the date when Contractor became bound under a negotiated contract) in Laws or Regulations having an effect on the cost or time of performance of the Work, including but not limited to changes in Laws or Regulations having an effect on procuring permits and on sales, use, value-added, consumption, and other similar taxes. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times resulting from such changes, then within 30 days of such written notice Contractor may submit a Change Proposal, or Owner may initiate a Claim. 7.12 Record Documents A. Contractor shall maintain in a safe place at the Site one printed record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, written interpretations and clarifications, and approved Shop Drawings. Contractor shall keep such record documents in good order and annotate them to show changes made during construction. These record documents, together with all approved Samples, will be available to Engineer for reference. Upon completion of the Work, Contractor shall deliver these record documents to Engineer. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 33 of 70 7.13 Safety and Protection A. Contractor shall be solely responsible for initiating, maintaining, and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. B. Contractor shall designate a qualified and experienced safety representative whose duties and responsibilities are the prevention of Work -related accidents and the maintenance and supervision of safety precautions and programs. C. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury, or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, other work in progress, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. D. All damage, injury, or loss to any property referred to in Paragraph 7.13.C.2 or 7.13.C.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor at its expense (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of Owner or Engineer or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). E. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. F. Contractor shall notify Owner; the owners of adjacent property; the owners of Underground Facilities and other utilities (if the identity of such owners is known to Contractor); and other contractors and utility owners performing work at or adjacent to the Site, in writing, when Contractor knows that prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property or work in progress. G. Contractor shall comply with the applicable requirements of Owner's safety programs, if any. Any Owner's safety programs that are applicable to the Work are identified or included in the Supplementary Conditions or Specifications. H. Contractor shall inform Owner and Engineer of the specific requirements of Contractor's safety program with which Owner's and Engineer's employees and representatives must comply while at the Site. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 34 of 70 I. Contractor's duties and responsibilities for safety and protection will continue until all the Work is completed, Engineer has issued a written notice to Owner and Contractor in accordance with Paragraph 15.06.0 that the Work is acceptable, and Contractor has left the Site (except as otherwise expressly provided in connection with Substantial Completion). J. Contractor's duties and responsibilities for safety and protection will resume whenever Contractor or any Subcontractor or Supplier returns to the Site to fulfill warranty or correction obligations, or to conduct other tasks arising from the Contract Documents. 7.14 Hazard Communication Programs A. Contractor shall be responsible for coordinating any exchange of safety data sheets (formerly known as material safety data sheets) or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 7.15 Emergencies A. In emergencies affecting the safety or protection of persons or the Work or property at the Site or adjacent thereto, Contractor is obligated to act to prevent damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused by an emergency, or are required as a result of Contractor's response to an emergency. If Engineer determines that a change in the Contract Documents is required because of an emergency or Contractor's response, a Work Change Directive or Change Order will be issued. 7.16 Submittals A. Shop Drawing and Sample Requirements 1. Before submitting a Shop Drawing or Sample, Contractor shall: a. review and coordinate the Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents; b. determine and verify: 1) all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect to the Submittal; 2) the suitability of all materials and equipment offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and 3) all information relative to Contractor's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto; c. confirm that the Submittal is complete with respect to all related data included in the Submittal. 2. Each Shop Drawing or Sample must bear a stamp or specific written certification that Contractor has satisfied Contractor's obligations under the Contract Documents with respect to Contractor's review of that Submittal, and that Contractor approves the Submittal. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 35 of 70 3. With each Shop Drawing or Sample, Contractor shall give Engineer specific written notice of any variations that the Submittal may have from the requirements of the Contract Documents. This notice must be set forth in a written communication separate from the Submittal; and, in addition, in the case of a Shop Drawing by a specific notation made on the Shop Drawing itself. B. Submittal Procedures forShop Drawings and Samples: Contractor shall label and submit Shop Drawings and Samples to Engineer for review and approval in accordance with the accepted Schedule of Submittals. 1. Shop Drawings a. Contractor shall submit the number of copies required in the Specifications. Data shown on the Shop Drawings must be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide, and to enable Engineer to review the information for the limited purposes required by Paragraph 7.16.C. 2. Samples a. Contractor shall submit the number of Samples required in the Specifications. b. Contractor shall clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the Submittal for the limited purposes required by Paragraph 7.16.C. Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals, any related Work performed prior to Engineer's review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor. C. Engineer's Review of Shop Drawings and Samples Engineer will provide timely review of Shop Drawings and Samples in accordance with the accepted Schedule of Submittals. Engineer's review and approval will be only to determine if the items covered by the Submittals will, after installation or incorporation in the Work, comply with the requirements of the Contract Documents, and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Engineer's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction, or to safety precautions or programs incident thereto. Engineer's review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 4. Engineer's review and approval of a Shop Drawing or Sample will not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 7.16.A.3 and Engineer has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample. Engineer will EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 36 of 70 document any such approved variation from the requirements of the Contract Documents in a Field Order or other appropriate Contract modification. 5. Engineer's review and approval of a Shop Drawing or Sample will not relieve Contractor from responsibility for complying with the requirements of Paragraphs 7.16.A and B. 6. Engineer's review and approval of a Shop Drawing or Sample, or of a variation from the requirements of the Contract Documents, will not, under any circumstances, change the Contract Times or Contract Price, unless such changes are included in a Change Order. 7. Neither Engineer's receipt, review, acceptance, or approval of a Shop Drawing or Sample will result in such item becoming a Contract Document. 8. Contractor shall perform the Work in compliance with the requirements and commitments set forth in approved Shop Drawings and Samples, subject to the provisions of Paragraph 7.16.C.4. D. Resubmittal Procedures for Shop Drawings and Samples 1. Contractor shall make corrections required by Engineer and shall return the required number of corrected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous Submittals. 2. Contractor shall furnish required Shop Drawing and Sample submittals with sufficient information and accuracy to obtain required approval of an item with no more than two resubmittals. Engineer will record Engineer's time for reviewing a third or subsequent resubmittal of a Shop Drawing or Sample, and Contractor shall be responsible for Engineer's charges to Owner for such time. Owner may impose a set-off against payments due Contractor to secure reimbursement for such charges. 3. If Contractor requests a change of a previously approved Shop Drawing or Sample, Contractor shall be responsible for Engineer's charges to Owner for its review time, and Owner may impose a set-off against payments due Contractor to secure reimbursement for such charges, unless the need for such change is beyond the control of Contractor. E. Submittals Other than Shop Drawings, Samples, and Owner -Delegated Designs 1. The following provisions apply to all Submittals other than Shop Drawings, Samples, and Owner -delegated designs: a. Contractor shall submit all such Submittals to the Engineer in accordance with the Schedule of Submittals and pursuant to the applicable terms of the Contract Documents. b. Engineer will provide timely review of all such Submittals in accordance with the Schedule of Submittals and return such Submittals with a notation of either Accepted or Not Accepted. Any such Submittal that is not returned within the time established in the Schedule of Submittals will be deemed accepted. c. Engineer's review will be only to determine if the Submittal is acceptable under the requirements of the Contract Documents as to general form and content of the Submittal. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 37 of 70 d. If any such Submittal is not accepted, Contractor shall confer with Engineer regarding the reason for the non -acceptance, and resubmit an acceptable document. 2. Procedures for the submittal and acceptance of the Progress Schedule, the Schedule of Submittals, and the Schedule of Values are set forth in Paragraphs 2.03. 2.04, and 2.05. F. Owner -delegated Designs: Submittals pursuant to Owner -delegated designs are governed by the provisions of Paragraph 7.19. 7.17 Contractor's General Warranty and Guarantee A. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer is entitled to rely on Contractor's warranty and guarantee. B. Owner's rights under this warranty and guarantee are in addition to, and are not limited by, Owner's rights under the correction period provisions of Paragraph 15.08. The time in which Owner may enforce its warranty and guarantee rights under this Paragraph 7.17 is limited only by applicable Laws and Regulations restricting actions to enforce such rights; provided, however, that after the end of the correction period under Paragraph 15.08: 1. Owner shall give Contractor written notice of any defective Work within 60 days of the discovery that such Work is defective; and 2. Such notice will be deemed the start of an event giving rise to a Claim under Paragraph 12.01.13, such that any related Claim must be brought within 30 days of the notice. C. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, or improper modification, maintenance, or operation, by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2. normal wear and tear under normal usage. D. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents is absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents, a release of Contractor's obligation to perform the Work in accordance with the Contract Documents, or a release of Owner's warranty and guarantee rights under this Paragraph 7.17: 1. Observations by Engineer; 2. Recommendation by Engineer or payment by Owner of any progress or final payment; 3. The issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner; 4. Use or occupancy of the Work or any part thereof by Owner; 5. Any review and approval of a Shop Drawing or Sample submittal; 6. The issuance of a notice of acceptability by Engineer; 7. The end of the correction period established in Paragraph 15.08; 8. Any inspection, test, or approval by others; or EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 38 of 70 9. Any correction of defective Work by Owner. E. If the Contract requires the Contractor to accept the assignment of a contract entered into by Owner, then the specific warranties, guarantees, and correction obligations contained in the assigned contract will govern with respect to Contractor's performance obligations to Owner for the Work described in the assigned contract. 7.18 Indemnification A. To the fullest extent permitted by Laws and Regulations, and in addition to any other obligations of Contractor under the Contract or otherwise, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them, from losses, damages, costs, and judgments (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court or arbitration or other dispute resolution costs) arising from third -party claims or actions relating to or resulting from the performance or furnishing of the Work, provided that any such claim, action, loss, cost, judgment or damage is attributable to bodily injury, sickness, disease, or death, or to damage to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable. B. In any and all claims against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, by any employee (orthe survivor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 7.18.A will not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, Supplier, or other individual or entity under workers' compensation acts, disability benefit acts, or other employee benefit acts. 7.19 Delegation of Professional Design Services A. Owner may require Contractor to provide professional design services for a portion of the Work by express delegation in the Contract Documents. Such delegation will specify the performance and design criteria that such services must satisfy, and the Submittals that Contractor must furnish to Engineer with respect to the Owner -delegated design. B. Contractor shall cause such Owner -delegated professional design services to be provided pursuant to the professional standard of care by a properly licensed design professional, whose signature and seal must appear on all drawings, calculations, specifications, certifications, and Submittals prepared by such design professional. Such design professional must issue all certifications of design required by Laws and Regulations. C. If a Shop Drawing or other Submittal related to the Owner -delegated design is prepared by Contractor, a Subcontractor, or others for submittal to Engineer, then such Shop Drawing or other Submittal must bear the written approval of Contractor's design professional when submitted by Contractor to Engineer. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 39 of 70 D. Owner and Engineer shall be entitled to rely upon the adequacy, accuracy, and completeness of the services, certifications, and approvals performed or provided by the design professionals retained or employed by Contractor under an Owner -delegated design, subject to the professional standard of care and the performance and design criteria stated in the Contract Documents. E. Pursuant to this Paragraph 7.19, Engineer's review, approval, and other determinations regarding design drawings, calculations, specifications, certifications, and other Submittals furnished by Contractor pursuant to an Owner -delegated design will be only for the following limited purposes: 1. Checking for conformance with the requirements of this Paragraph 7.19; 2. Confirming that Contractor (through its design professionals) has used the performance and design criteria specified in the Contract Documents; and 3. Establishing that the design furnished by Contractor is consistent with the design concept expressed in the Contract Documents. F. Contractor shall not be responsible for the adequacy of performance or design criteria specified by Owner or Engineer. G. Contractor is not required to provide professional services in violation of applicable Laws and Regulations. ARTICLE 8—OTHER WORK AT THE SITE 8.01 Other Work A. In addition to and apart from the Work under the Contract Documents, the Owner may perform other work at or adjacent to the Site. Such other work may be performed by Owner's employees, or through contracts between the Owner and third parties. Owner may also arrange to have third -party utility owners perform work on their utilities and facilities at or adjacent to the Site. B. If Owner performs other work at or adjacent to the Site with Owner's employees, or through contracts for such other work, then Owner shall give Contractor written notice thereof prior to starting any such other work. If Owner has advance information regarding the start of any third -party utility work that Owner has arranged to take place at or adjacent to the Site, Owner shall provide such information to Contractor. C. Contractor shall afford proper and safe access to the Site to each contractor that performs such other work, each utility owner performing other work, and Owner, if Owner is performing other work with Owner's employees, and provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work. D. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of Engineer and the others whose work will be affected. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 40 of 70 E. If the proper execution or results of any part of Contractor's Work depends upon work performed by others, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects and deficiencies in such other work. F. The provisions of this article are not applicable to work that is performed by third -party utilities or other third -party entities without a contract with Owner, or that is performed without having been arranged by Owner. If such work occurs, then any related delay, disruption, or interference incurred by Contractor is governed by the provisions of Paragraph 4.05.C.3. 8.02 Coordination A. If Owner intends to contract with others for the performance of other work at or adjacent to the Site, to perform other work at or adjacent to the Site with Owner's employees, or to arrange to have utility owners perform work at or adjacent to the Site, the following will be set forth in the Supplementary Conditions or provided to Contractor prior to the start of any such other work: 1. The identity of the individual or entity that will have authority and responsibility for coordination of the activities among the various contractors; 2. An itemization of the specific matters to be covered by such authority and responsibility; and 3. The extent of such authority and responsibilities. B. Unless otherwise provided in the Supplementary Conditions, Owner shall have sole authority and responsibility for such coordination. 8.03 Legal Relationships A. If, in the course of performing other work for Owner at or adjacent to the Site, the Owner's employees, any other contractor working for Owner, or any utility owner that Owner has arranged to perform work, causes damage to the Work or to the property of Contractor or its Subcontractors, or delays, disrupts, interferes with, or increases the scope or cost of the performance of the Work, through actions or inaction, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times. Contractor must submit any Change Proposal seeking an equitable adjustment in the Contract Price or the Contract Times under this paragraph within 30 days of the damaging, delaying, disrupting, or interfering event. The entitlement to, and extent of, any such equitable adjustment will take into account information (if any) regarding such other work that was provided to Contractor in the Contract Documents prior to the submittal of the Bid or the final negotiation of the terms of the Contract, and any remedies available to Contractor under Laws or Regulations concerning utility action or inaction. When applicable, any such equitable adjustment in Contract Price will be conditioned on Contractor assigning to Owner all Contractor's rights against such other contractor or utility owner with respect to the damage, delay, disruption, or interference that is the subject of the adjustment. Contractor's entitlement to an adjustment of the Contract Times or Contract Price is subject to the provisions of Paragraphs 4.05.D and 4.05.E. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 41 of 70 B. Contractor shall take reasonable and customary measures to avoid damaging, delaying, disrupting, or interfering with the work of Owner, any other contractor, or any utility owner performing other work at or adjacent to the Site. 1. If Contractor fails to take such measures and as a result damages, delays, disrupts, or interferes with the work of any such other contractor or utility owner, then Owner may impose a set-off against payments due Contractor, and assign to such other contractor or utility owner the Owner's contractual rights against Contractor with respect to the breach of the obligations set forth in this Paragraph 8.03.6. When Owner is performing other work at or adjacent to the Site with Owner's employees, Contractor shall be liable to Owner for damage to such other work, and for the reasonable direct delay, disruption, and interference costs incurred by Owner as a result of Contractor's failure to take reasonable and customary measures with respect to Owner's other work. In response to such damage, delay, disruption, or interference, Owner may impose a set-off against payments due Contractor. C. If Contractor damages, delays, disrupts, or interferes with the work of any other contractor, or any utility owner performing other work at or adjacent to the Site, through Contractor's failure to take reasonable and customary measures to avoid such impacts, or if any claim arising out of Contractor's actions, inactions, or negligence in performance of the Work at or adjacent to the Site is made by any such other contractor or utility owner against Contractor, Owner, or Engineer, then Contractor shall (1) promptly attempt to settle the claim as to all parties through negotiations with such other contractor or utility owner, or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law, and (2) indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against any such claims, and against all costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such damage, delay, disruption, or interference. ARTICLE 9—OWNER'S RESPONSIBILITIES 9.01 Communications to Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. 9.02 Replacement of Engineer A. Owner may at its discretion appoint an engineer to replace Engineer, provided Contractor makes no reasonable objection to the replacement engineer. The replacement engineer's status under the Contract Documents will be that of the former Engineer. 9.03 Furnish Data A. Owner shall promptly furnish the data required of Owner under the Contract Documents. 9.04 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in the Agreement. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 42 of 70 9.05 Lands and Easements; Reports, Tests, and Drawings A. Owner's duties with respect to providing lands and easements are set forth in Paragraph 5.01. B. Owner's duties with respect to providing engineering surveys to establish reference points are set forth in Paragraph 4.03. C. Article 5 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of conditions at the Site, and drawings of physical conditions relating to existing surface or subsurface structures at the Site. 9.06 Insurance A. Owner's responsibilities, if any, with respect to purchasing and maintaining liability and property insurance are set forth in Article 6. 9.07 Change Orders A. Owner's responsibilities with respect to Change Orders are set forth in Article 11. 9.08 Inspections, Tests, and Approvals A. Owner's responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 14.02.6. 9.09 Limitations on Owner's Responsibilities A. The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. 9.10 Undisclosed Hazardous Environmental Condition A. Owner's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in Paragraph 5.06. 9.11 Evidence of Financial Arrangements A. Upon request of Contractor, Owner shall furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner's obligations under the Contract (including obligations under proposed changes in the Work). 9.12 Safety Programs A. While at the Site, Owner's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Owner has been informed. B. Owner shall furnish copies of any applicable Owner safety programs to Contractor. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 43 of 70 ARTICLE 10—ENGINEER'S STATUS DURING CONSTRUCTION 10.01 Owner's Representative A. Engineer will be Owner's representative during the construction period. The duties and responsibilities and the limitations of authority of Engineer as Owner's representative during construction are set forth in the Contract. 10.02 Visits to Site A. Engineer will make visits to the Site at intervals appropriate to the various stages of construction as Engineer deems necessary in order to observe, as an experienced and qualified design professional, the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. Engineer's efforts will be directed toward providing for Owner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor to guard Owner against defective Work. B. Engineer's visits and observations are subject to all the limitations on Engineer's authority and responsibility set forth in Paragraph 10.07. Particularly, but without limitation, during or as a result of Engineer's visits or observations of Contractor's Work, Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. 10.03 Resident Project Representative A. If Owner and Engineer have agreed that Engineer will furnish a Resident Project Representative to represent Engineer at the Site and assist Engineer in observing the progress and quality of the Work, then the authority and responsibilities of any such Resident Project Representative will be as provided in the Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in the Supplementary Conditions and in Paragraph 10.07. B. If Owner designates an individual or entity who is not Engineer's consultant, agent, or employee to represent Owner at the Site, then the responsibilities and authority of such individual or entity will be as provided in the Supplementary Conditions. 10.04 Engineer's Authority A. Engineer has the authority to reject Work in accordance with Article 14. B. Engineer's authority as to Submittals is set forth in Paragraph 7.16. C. Engineer's authority as to design drawings, calculations, specifications, certifications and other Submittals from Contractor in response to Owner's delegation (if any) to Contractor of professional design services, is set forth in Paragraph 7.19. D. Engineer's authority as to changes in the Work is set forth in Article 11. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 44 of 70 E. Engineer's authority as to Applications for Payment is set forth in Article 15. 10.05 Determinations for Unit Price Work A. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor as set forth in Paragraph 13.03. 10.06 Decisions on Requirements of Contract Documents and Acceptability of Work A. Engineer will render decisions regarding the requirements of the Contract Documents, and judge the acceptability of the Work, pursuant to the specific procedures set forth herein for initial interpretations, Change Proposals, and acceptance of the Work. In rendering such decisions and judgments, Engineer will not show partiality to Owner or Contractor, and will not be liable to Owner, Contractor, or others in connection with any proceedings, interpretations, decisions, or judgments conducted or rendered in good faith. 10.07 Limitations on Engineer's Authority and Responsibilities A. Neither Engineer's authority or responsibility under this Article 10 or under any other provision of the Contract, nor any decision made by Engineer in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer, will create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. B. Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Engineer will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. C. Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. Engineer's review of the final Application for Payment and accompanying documentation, and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Contractor under Paragraph 15.06.A, will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests, and approvals, that the results certified indicate compliance with the Contract Documents. E. The limitations upon authority and responsibility set forth in this Paragraph 10.07 also apply to the Resident Project Representative, if any. 10.08 Compliance with Safety Program A. While at the Site, Engineer's employees and representatives will comply with the specific applicable requirements of Owner's and Contractor's safety programs of which Engineer has been informed. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 45 of 70 ARTICLE 11—CHANGES TO THE CONTRACT 11.01 Amending and Supplementing the Contract A. The Contract maybe amended or supplemented by a Change Order, a Work Change Directive, or a Field Order. B. If an amendment or supplement to the Contract includes a change in the Contract Price or the Contract Times, such amendment or supplement must be set forth in a Change Order. C. All changes to the Contract that involve (1) the performance or acceptability of the Work, (2) the design (as set forth in the Drawings, Specifications, or otherwise), or (3) other engineering or technical matters, must be supported by Engineer's recommendation. Owner and Contractor may amend other terms and conditions of the Contract without the recommendation of the Engineer. 11.02 Change Orders A. Owner and Contractor shall execute appropriate Change Orders covering: 1. Changes in Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; 2. Changes in Contract Price resulting from an Owner set-off, unless Contractor has duly contested such set-off; 3. Changes in the Work which are: (a) ordered by Owner pursuant to Paragraph 11.05, (b) required because of Owner's acceptance of defective Work under Paragraph 14.04 or Owner's correction of defective Work under Paragraph 14.07, or (c) agreed to by the parties, subject to the need for Engineer's recommendation if the change in the Work involves the design (as set forth in the Drawings, Specifications, or otherwise) or other engineering or technical matters; and 4. Changes that embody the substance of any final and binding results under: Paragraph 11.03.6, resolving the impact of a Work Change Directive; Paragraph 11.09, concerning Change Proposals; Article 12, Claims; Paragraph 13.02.D, final adjustments resulting from allowances; Paragraph 13.03.1), final adjustments relating to determination of quantities for Unit Price Work; and similar provisions. B. If Owner or Contractor refuses to execute a Change Order that is required to be executed under the terms of Paragraph 11.02.A, it will be deemed to be of full force and effect, as if fully executed. 11.03 Work Change Directives A. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the modification ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order, following negotiations by the parties as to the Work Change Directive's effect, if any, on the Contract Price and Contract Times; or, if negotiations are unsuccessful, by a determination under the terms of the Contract Documents governing adjustments, expressly including Paragraph 11.07 regarding change of Contract Price. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 46 of 70 B. If Owner has issued a Work Change Directive and: Contractor believes that an adjustment in Contract Times or Contract Price is necessary, then Contractor shall submit any Change Proposal seeking such an adjustment no later than 30 days after the completion of the Work set out in the Work Change Directive. 2. Owner believes that an adjustment in Contract Times or Contract Price is necessary, then Owner shall submit any Claim seeking such an adjustment no later than 60 days after issuance of the Work Change Directive. 11.04 Field Orders A. Engineer may authorize minor changes in the Work if the changes do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Such changes will be accomplished by a Field Order and will be binding on Owner and also on Contractor, which shall perform the Work involved promptly. B. If Contractor believes that a Field Order justifies an adjustment in the Contract Price or Contract Times, then before proceeding with the Work at issue, Contractor shall submit a Change Proposal as provided herein. 11.05 Owner -Authorized Changes in the Work A. Without invalidating the Contract and without notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the Work. Changes involving the design (as set forth in the Drawings, Specifications, or otherwise) or other engineering or technical matters will be supported by Engineer's recommendation. B. Such changes in the Work may be accomplished by a Change Order, if Owner and Contractor have agreed as to the effect, if any, of the changes on Contract Times or Contract Price; or by a Work Change Directive. Upon receipt of any such document, Contractor shall promptly proceed with the Work involved; or, in the case of a deletion in the Work, promptly cease construction activities with respect to such deleted Work. Added or revised Work must be performed under the applicable conditions of the Contract Documents. C. Nothing in this Paragraph 11.05 obligates Contractor to undertake work that Contractor reasonably concludes cannot be performed in a manner consistent with Contractor's safety obligations under the Contract Documents or Laws and Regulations. 11.06 Unauthorized Changes in the Work A. Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents, as amended, modified, or supplemented, except in the case of an emergency as provided in Paragraph 7.15 or in the case of uncovering Work as provided in Paragraph 14.05.C.2. 11.07 Change of Contract Price A. The Contract Price may only be changed by a Change Order. Any Change Proposal for an adjustment in the Contract Price must comply with the provisions of Paragraph 11.09. Any Claim for an adjustment of Contract Price must comply with the provisions of Article 12. B. An adjustment in the Contract Price will be determined as follows: EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 47 of 70 1. Where the Work involved is covered by unit prices contained in the Contract Documents, then by application of such unit prices to the quantities of the items involved (subject to the provisions of Paragraph 13.03); 2. Where the Work involved is not covered by unit prices contained in the Contract Documents, then by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with Paragraph 11.07.C.2); or 3. Where the Work involved is not covered by unit prices contained in the Contract Documents and the parties do not reach mutual agreement to a lump sum, then on the basis of the Cost of the Work (determined as provided in Paragraph 13.01) plus a Contractor's fee for overhead and profit (determined as provided in Paragraph 11.07.C). C. Contractor's Fee: When applicable, the Contractor's fee for overhead and profit will be determined as follows: 1. A mutually acceptable fixed fee; or 2. If a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. For costs incurred under Paragraphs 13.01.13.1 and 13.01.13.2, the Contractor's fee will be 15 percent; b. For costs incurred under Paragraph 13.01.13.3, the Contractor's fee will be 5 percent; c. Where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraphs 11.07.C.2.a and 11.07.C.2.b is that the Contractor's fee will be based on: (1) a fee of 15 percent of the costs incurred under Paragraphs 13.01.13.1 and 13.01.13.2 by the Subcontractor that actually performs the Work, at whatever tier, and (2) with respect to Contractor itself and to any Subcontractors of a tier higher than that of the Subcontractor that actually performs the Work, a fee of 5 percent of the amount (fee plus underlying costs incurred) attributable to the next lower tier Subcontractor; provided, however, that for any such subcontracted Work the maximum total fee to be paid by Owner will be no greater than 27 percent of the costs incurred by the Subcontractor that actually performs the Work; d. No fee will be payable on the basis of costs itemized under Paragraphs 13.01.13.4, 13.01.13.5, and 13.01.C; e. The amount of credit to be allowed by Contractor to Owner for any change which results in a net decrease in Cost of the Work will be the amount of the actual net decrease in Cost of the Work and a deduction of an additional amount equal to 5 percent of such actual net decrease in Cost of the Work; and f. When both additions and credits are involved in any one change or Change Proposal, the adjustment in Contractor's fee will be computed by determining the sum of the costs in each of the cost categories in Paragraph 13.01.13 (specifically, payroll costs, Paragraph 13.01.13.1; incorporated materials and equipment costs, Paragraph 13.01.13.2; Subcontract costs, Paragraph 13.01.13.3; special consultants costs, Paragraph 13.01.6.4; and other costs, Paragraph 13.01.13.5) and applying to each such cost category sum the appropriate fee from Paragraphs 11.07.C.2.a through 11.07.C.2.e, inclusive. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 48 of 70 11.08 Change of Contract Times A. The Contract Times may only be changed by a Change Order. Any Change Proposal for an adjustment in the Contract Times must comply with the provisions of Paragraph 11.09. Any Claim for an adjustment in the Contract Times must comply with the provisions of Article 12. B. Delay, disruption, and interference in the Work, and any related changes in Contract Times, are addressed in and governed by Paragraph 4.05. 11.09 Change Proposals A. Purpose and Content: Contractor shall submit a Change Proposal to Engineer to request an adjustment in the Contract Times or Contract Price; contest an initial decision by Engineer concerning the requirements of the Contract Documents or relating to the acceptability of the Work under the Contract Documents; challenge a set-off against payment due; or seek other relief under the Contract. The Change Proposal will specify any proposed change in Contract Times or Contract Price, or other proposed relief, and explain the reason for the proposed change, with citations to any governing or applicable provisions of the Contract Documents. Each Change Proposal will address only one issue, or a set of closely related issues. B. Change Proposal Procedures Submittal: Contractor shall submit each Change Proposal to Engineer within 30 days after the start of the event giving rise thereto, or after such initial decision. Supporting Data: The Contractor shall submit supporting data, including the proposed change in Contract Price or Contract Time (if any), to the Engineer and Owner within 15 days after the submittal of the Change Proposal. a. Change Proposals based on or related to delay, interruption, or interference must comply with the provisions of Paragraphs 4.05.D and 4.05.E. b. Change proposals related to a change of Contract Price must include full and detailed accounts of materials incorporated into the Work and labor and equipment used for the subject Work. The supporting data must be accompanied by a written statement that the supporting data are accurate and complete, and that any requested time or price adjustment is the entire adjustment to which Contractor believes it is entitled as a result of said event. Engineer's Initial Review: Engineer will advise Owner regarding the Change Proposal, and consider any comments or response from Owner regarding the Change Proposal. If in its discretion Engineer concludes that additional supporting data is needed before conducting a full review and making a decision regarding the Change Proposal, then Engineer may request that Contractor submit such additional supporting data by a date specified by Engineer, prior to Engineer beginning its full review of the Change Proposal. 4. Engineer's Full Review and Action on the Change Proposal: Upon receipt of Contractor's supporting data (including any additional data requested by Engineer), Engineer will conduct a full review of each Change Proposal and, within 30 days after such receipt of the Contractor's supporting data, either approve the Change Proposal in whole, deny it in whole, or approve it in part and deny it in part. Such actions must be in writing, with a copy provided to Owner and Contractor. If Engineer does not take action on the Change EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 49 of 70 Proposal within 30 days, then either Owner or Contractor may at any time thereafter submit a letter to the other party indicating that as a result of Engineer's inaction the Change Proposal is deemed denied, thereby commencing the time for appeal of the denial under Article 12. Binding Decision: Engineer's decision is final and binding upon Owner and Contractor, unless Owner or Contractor appeals the decision by filing a Claim under Article 12. C. Resolution of Certain Change Proposals: If the Change Proposal does not involve the design (as set forth in the Drawings, Specifications, or otherwise), the acceptability of the Work, or other engineering or technical matters, then Engineer will notify the parties in writing that the Engineer is unable to resolve the Change Proposal. For purposes of further resolution of such a Change Proposal, such notice will be deemed a denial, and Contractor may choose to seek resolution under the terms of Article 12. D. Post -Completion: Contractor shall not submit any Change Proposals after Engineer issues a written recommendation of final payment pursuant to Paragraph 15.06.13. 11.10 Notification to Surety A. If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times), the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change. ARTICLE 12—CLAIMS 12.01 Claims A. Claims Process: The following disputes between Owner and Contractor are subject to the Claims process set forth in this article: 1. Appeals by Owner or Contractor of Engineer's decisions regarding Change Proposals; 2. Owner demands for adjustments in the Contract Price or Contract Times, or other relief under the Contract Documents; 3. Disputes that Engineer has been unable to address because they do not involve the design (as set forth in the Drawings, Specifications, or otherwise), the acceptability of the Work, or other engineering or technical matters; and 4. Subject to the waiver provisions of Paragraph 15.07, any dispute arising after Engineer has issued a written recommendation of final payment pursuant to Paragraph 15.06.13. B. Submittal of Claim: The party submitting a Claim shall deliver it directly to the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto; in the case of appeals regarding Change Proposals within 30 days of the decision under appeal. The party submitting the Claim shall also furnish a copy to the Engineer, for its information only. The responsibility to substantiate a Claim rests with the party making the Claim. In the case of a Claim by Contractor seeking an increase in the Contract Times or Contract Price, Contractor shall certify that the Claim is made in good faith, that the supporting data are accurate and complete, and that to the best of Contractor's knowledge EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 50 of 70 and belief the amount of time or money requested accurately reflects the full amount to which Contractor is entitled. C. Review and Resolution: The party receiving a Claim shall review it thoroughly, giving full consideration to its merits. The two parties shall seek to resolve the Claim through the exchange of information and direct negotiations. The parties may extend the time for resolving the Claim by mutual agreement. All actions taken on a Claim will be stated in writing and submitted to the other party, with a copy to Engineer. D. Mediation 1. At any time after initiation of a Claim, Owner and Contractor may mutually agree to mediation of the underlying dispute. The agreement to mediate will stay the Claim submittal and response process. 2. If Owner and Contractor agree to mediation, then after 60 days from such agreement, either Owner or Contractor may unilaterally terminate the mediation process, and the Claim submittal and decision process will resume as of the date of the termination. If the mediation proceeds but is unsuccessful in resolving the dispute, the Claim submittal and decision process will resume as of the date of the conclusion of the mediation, as determined by the mediator. 3. Owner and Contractor shall each pay one-half of the mediator's fees and costs. E. Partial Approval: If the party receiving a Claim approves the Claim in part and denies it in part, such action will be final and binding unless within 30 days of such action the other party invokes the procedure set forth in Article 17 for final resolution of disputes. F. Denial of Claim: If efforts to resolve a Claim are not successful, the party receiving the Claim may deny it by giving written notice of denial to the other party. If the receiving party does not take action on the Claim within 90 days, then either Owner or Contractor may at any time thereafter submit a letter to the other party indicating that as a result of the inaction, the Claim is deemed denied, thereby commencing the time for appeal of the denial. A denial of the Claim will be final and binding unless within 30 days of the denial the other party invokes the procedure set forth in Article 17 for the final resolution of disputes. G. Final and Binding Results: If the parties reach a mutual agreement regarding a Claim, whether through approval of the Claim, direct negotiations, mediation, or otherwise; or if a Claim is approved in part and denied in part, or denied in full, and such actions become final and binding; then the results of the agreement or action on the Claim will be incorporated in a Change Order or other written document to the extent they affect the Contract, including the Work, the Contract Times, or the Contract Price. ARTICLE 13—COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK 13.01 Cost of the Work A. Purposes for Determination of Cost of the Work: The term Cost of the Work means the sum of all costs necessary for the proper performance of the Work at issue, as further defined below. The provisions of this Paragraph 13.01 are used for two distinct purposes: 1. To determine Cost of the Work when Cost of the Work is a component of the Contract Price, under cost -plus -fee, time -and -materials, or other cost -based terms; or EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 51 of 70 2. When needed to determine the value of a Change Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price. When the value of any such adjustment is determined on the basis of Cost of the Work, Contractor is entitled only to those additional or incremental costs required because of the change in the Work or because of the event giving rise to the adjustment. B. Costs Included: Except as otherwise may be agreed to in writing by Owner, costs included in the Cost of the Work will be in amounts no higher than those commonly incurred in the locality of the Project, will not include any of the costs itemized in Paragraph 13.01.C, and will include only the following items: 1. Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor in advance of the subject Work. Such employees include, without limitation, superintendents, foremen, safety managers, safety representatives, and other personnel employed full time on the Work. Payroll costs for employees not employed full time on the Work will be apportioned on the basis of their time spent on the Work. Payroll costs include, but are not limited to, salaries and wages plus the cost of fringe benefits, which include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, sick leave, and vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on Saturday, Sunday, or legal holidays, will be included in the above to the extent authorized by Owner. 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts accrue to Contractor unless Owner deposits funds with Contractor with which to make payments, in which case the cash discounts will accrue to Owner. All trade discounts, rebates, and refunds and returns from sale of surplus materials and equipment will accrue to Owner, and Contractor shall make provisions so that they may be obtained. 3. Payments made by Contractor to Subcontractors for Work performed by Subcontractors. If required by Owner, Contractor shall obtain competitive bids from subcontractors acceptable to Owner and Contractor and shall deliver such bids to Owner, which will then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee will be determined in the same manner as Contractor's Cost of the Work and fee as provided in this Paragraph 13.01. 4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed or retained for services specifically related to the Work. S. Other costs consisting of the following: a. The proportion of necessary transportation, travel, and subsistence expenses of Contractor's employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and maintenance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, which are EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 52 of 70 consumed in the performance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor. 1) In establishing included costs for materials such as scaffolding, plating, or sheeting, consideration will be given to the actual or the estimated life of the material for use on other projects; or rental rates may be established on the basis of purchase or salvage value of such items, whichever is less. Contractor will not be eligible for compensation for such items in an amount that exceeds the purchase cost of such item. c. Construction Equipment Rental 1) Rentals of all construction equipment and machinery, and the parts thereof, in accordance with rental agreements approved by Owner as to price (including any surcharge or special rates applicable to overtime use of the construction equipment or machinery), and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs will be in accordance with the terms of said rental agreements. The rental of any such equipment, machinery, or parts must cease when the use thereof is no longer necessary for the Work. 2) Costs for equipment and machinery owned by Contractor or a Contractor -related entity will be paid at a rate shown for such equipment in the equipment rental rate book specified in the Supplementary Conditions. An hourly rate will be computed by dividing the monthly rates by 176. These computed rates will include all operating costs. 3) With respect to Work that is the result of a Change Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price ("changed Work"), included costs will be based on the time the equipment or machinery is in use on the changed Work and the costs of transportation, loading, unloading, assembly, dismantling, and removal when directly attributable to the changed Work. The cost of any such equipment or machinery, or parts thereof, must cease to accrue when the use thereof is no longer necessary for the changed Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, as imposed by Laws and Regulations. e. Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. f. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by Contractor in connection with the performance of the Work (except losses and damages within the deductible amounts of builder's risk or other property insurance established in accordance with Paragraph 6.04), provided such losses and damages have resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses will be included in the Cost of the Work for the purpose of determining Contractor's fee. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 53 of 70 g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as communication service at the Site, express and courier services, and similar petty cash items in connection with the Work. i. The costs of premiums for all bonds and insurance that Contractor is required by the Contract Documents to purchase and maintain. C. Costs Excluded: The term Cost of the Work does not include any of the following items: 1. Payroll costs and other compensation of Contractor's officers, executives, principals, general managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 13.01.13.1 or specifically covered by Paragraph 13.01.13.4. The payroll costs and other compensation excluded here are to be considered administrative costs covered by the Contractor's fee. 2. The cost of purchasing, renting, or furnishing small tools and hand tools. 3. Expenses of Contractor's principal and branch offices other than Contractor's office at the Site. 4. Any part of Contractor's capital expenses, including interest on Contractor's capital employed for the Work and charges against Contractor for delinquent payments. 5. Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 6. Expenses incurred in preparing and advancing Claims. 7. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraph 13.01.13. D. Contractor's Fee 1. When the Work as a whole is performed on the basis of cost -plus -a -fee, then: a. Contractor's fee for the Work set forth in the Contract Documents as of the Effective Date of the Contract will be determined as set forth in the Agreement. b. for any Work covered by a Change Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price on the basis of Cost of the Work, Contractor's fee will be determined as follows: 1) When the fee for the Work as a whole is a percentage of the Cost of the Work, the fee will automatically adjust as the Cost of the Work changes. 2) When the fee for the Work as a whole is a fixed fee, the fee for any additions or deletions will be determined in accordance with Paragraph 11.07.C.2. 2. When the Work as a whole is performed on the basis of a stipulated sum, or any other basis other than cost -plus -a -fee, then Contractor's fee for any Work covered by a Change EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 54 of 70 Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price on the basis of Cost of the Work will be determined in accordance with Paragraph 11.07.C.2. E. Documentation and Audit: Whenever the Cost of the Work for any purpose is to be determined pursuant to this Article 13, Contractor and pertinent Subcontractors will establish and maintain records of the costs in accordance with generally accepted accounting practices. Subject to prior written notice, Owner will be afforded reasonable access, during normal business hours, to all Contractor's accounts, records, books, correspondence, instructions, drawings, receipts, vouchers, memoranda, and similar data relating to the Cost of the Work and Contractor's fee. Contractor shall preserve all such documents for a period of three years after the final payment by Owner. Pertinent Subcontractors will afford such access to Owner, and preserve such documents, to the same extent required of Contractor. 13.02 Allowances A. It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer. B. Cash Allowances: Contractor agrees that: 1. the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and 2. Contractor's costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment for any of the foregoing will be valid. C. Owner's Contingency Allowance: Contractor agrees that an Owner's contingency allowance, if any, is for the sole use of Owner to cover unanticipated costs. D. Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor for Work covered by allowances, and the Contract Price will be correspondingly adjusted. 13.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. B. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Payments to Contractor for Unit Price Work will be based on actual quantities. C. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor's overhead and profit for each separately identified item. D. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer's written decision EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 55 of 70 thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, and the final adjustment of Contract Price will be set forth in a Change Order, subject to the provisions of the following paragraph. E. Adjustments in Unit Price 1. Contractor or Owner shall be entitled to an adjustment in the unit price with respect to an item of Unit Price Work if: a. the quantity of the item of Unit Price Work performed by Contractor differs materially and significantly from the estimated quantity of such item indicated in the Agreement; and b. Contractor's unit costs to perform the item of Unit Price Work have changed materially and significantly as a result of the quantity change. 2. The adjustment in unit price will account for and be coordinated with any related changes in quantities of other items of Work, and in Contractor's costs to perform such other Work, such that the resulting overall change in Contract Price is equitable to Owner and Contractor. 3. Adjusted unit prices will apply to all units of that item. ARTICLE 14—TESTS AND INSPECTIONS; CORRECTION, REMOVAL, OR ACCEPTANCE OF DEFECTIVE WORK 14.01 Access to Work A. Owner, Engineer, their consultants and other representatives and personnel of Owner, independent testing laboratories, and authorities having jurisdiction have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's safety procedures and programs so that they may comply with such procedures and programs as applicable. 14.02 Tests, Inspections, and Approvals A. Contractor shall give Engineer timely notice of readiness of the Work (or specific parts thereof) for all required inspections and tests, and shall cooperate with inspection and testing personnel to facilitate required inspections and tests. B. Owner shall retain and pay for the services of an independent inspector, testing laboratory, or other qualified individual or entity to perform all inspections and tests expressly required by the Contract Documents to be furnished and paid for by Owner, except that costs incurred in connection with tests or inspections of covered Work will be governed by the provisions of Paragraph 14.05. C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 56 of 70 D. Contractor shall be responsible for arranging, obtaining, and paying for all inspections and tests required: 1. by the Contract Documents, unless the Contract Documents expressly allocate responsibility for a specific inspection or test to Owner; 2. to attain Owner's and Engineer's acceptance of materials or equipment to be incorporated in the Work; 3. by manufacturers of equipment furnished under the Contract Documents; 4. for testing, adjusting, and balancing of mechanical, electrical, and other equipment to be incorporated into the Work; and S. for acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections and tests will be performed by independent inspectors, testing laboratories, or other qualified individuals or entities acceptable to Owner and Engineer. E. If the Contract Documents require the Work (or part thereof) to be approved by Owner, Engineer, or another designated individual or entity, then Contractor shall assume full responsibility for arranging and obtaining such approvals. F. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of Engineer, Contractor shall, if requested by Engineer, uncover such Work for observation. Such uncovering will be at Contractor's expense unless Contractor had given Engineer timely notice of Contractor's intention to cover the same and Engineer had not acted with reasonable promptness in response to such notice. 14.03 Defective Work A. Contractor's Obligation: It is Contractor's obligation to assure that the Work is not defective. B. Engineer's Authority: Engineer has the authority to determine whether Work is defective, and to reject defective Work. C. Notice of Defects: Prompt written notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor. D. Correction, or Removal and Replacement: Promptly after receipt of written notice of defective Work, Contractor shall correct all such defective Work, whether or not fabricated, installed, or completed, or, if Engineer has rejected the defective Work, remove it from the Project and replace it with Work that is not defective. E. Preservation of Warranties: When correcting defective Work, Contractor shall take no action that would void or otherwise impair Owner's special warranty and guarantee, if any, on said Work. F. Costs and Damages: In addition to its correction, removal, and replacement obligations with respect to defective Work, Contractor shall pay all claims, costs, losses, and damages arising out of or relating to defective Work, including but not limited to the cost of the inspection, testing, correction, removal, replacement, or reconstruction of such defective Work, fines levied against Owner by governmental authorities because the Work is defective, and the costs of repair or replacement of work of others resulting from defective Work. Prior to final payment, if Owner and Contractor are unable to agree as to the measure of such claims, costs, EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 57 of 70 losses, and damages resulting from defective Work, then Owner may impose a reasonable set-off against payments due under Article 15. 14.04 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, Owner prefers to accept it, Owner may do so (subject, if such acceptance occurs prior to final payment, to Engineer's confirmation that such acceptance is in general accord with the design intent and applicable engineering principles, and will not endanger public safety). Contractor shall pay all claims, costs, losses, and damages attributable to Owner's evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness), and for the diminished value of the Work to the extent not otherwise paid by Contractor. If any such acceptance occurs prior to final payment, the necessary revisions in the Contract Documents with respect to the Work will be incorporated in a Change Order. If the parties are unable to agree as to the decrease in the Contract Price, reflecting the diminished value of Work so accepted, then Owner may impose a reasonable set-off against payments due under Article 15. If the acceptance of defective Work occurs after final payment, Contractor shall pay an appropriate amount to Owner. 14.05 Uncovering Work A. Engineer has the authority to require additional inspection or testing of the Work, whether or not the Work is fabricated, installed, or completed. B. If any Work is covered contrary to the written request of Engineer, then Contractor shall, if requested by Engineer, uncover such Work for Engineer's observation, and then replace the covering, all at Contractor's expense. C. If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, then Contractor, at Engineer's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Engineer may require, that portion of the Work in question, and provide all necessary labor, material, and equipment. 1. If it is found that the uncovered Work is defective, Contractor shall be responsible for all claims, costs, losses, and damages arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and pending Contractor's full discharge of this responsibility the Owner shall be entitled to impose a reasonable set-off against payments due under Article 15. 2. If the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, then Contractor may submit a Change Proposal within 30 days of the determination that the Work is not defective. 14.06 Owner May Stop the Work A. If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, then Owner may order Contractor to stop the Work, EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 58 of 70 or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work will not give rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 14.07 Owner May Correct Defective Work A. If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work, or to remove and replace defective Work as required by Engineer, then Owner may, after 7 days' written notice to Contractor, correct or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 14.07, Owner shall proceed expeditiously. In connection with such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, and incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Engineer and Engineer's consultants access to the Site to enable Owner to exercise the rights and remedies under this paragraph. C. All claims, costs, losses, and damages incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 14.07 will be charged against Contractor as set -offs against payments due under Article 15. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective Work. D. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this Paragraph 14.07. ARTICLE 15—PAYMENTS TO CONTRACTOR; SET -OFFS; COMPLETION; CORRECTION PERIOD 15.01 Progress Payments A. Basis for Progress Payments: The Schedule of Values established as provided in Article 2 will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to Engineer. Progress payments for Unit Price Work will be based on the number of units completed during the pay period, as determined under the provisions of Paragraph 13.03. Progress payments for cost -based Work will be based on Cost of the Work completed by Contractor during the pay period. B. Applications for Payments 1. At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. 2. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment must also be accompanied by: (a) a bill of sale, invoice, copies of subcontract or purchase order payments, or other documentation EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 59 of 70 establishing full payment by Contractor for the materials and equipment; (b) at Owner's request, documentation warranting that Owner has received the materials and equipment free and clear of all Liens; and (c) evidence that the materials and equipment are covered by appropriate property insurance, a warehouse bond, or other arrangements to protect Owner's interest therein, all of which must be satisfactory to Owner. 3. Beginning with the second Application for Payment, each Application must include an affidavit of Contractor stating that all previous progress payments received by Contractor have been applied to discharge Contractor's legitimate obligations associated with prior Applications for Payment. 4. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. C. Review of Applications 1. Engineer will, within 10 days after receipt of each Application for Payment, including each resubmittal, either indicate in writing a recommendation of payment and present the Application to Owner, or return the Application to Contractor indicating in writing Engineer's reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application. 2. Engineer's recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer's observations of the executed Work as an experienced and qualified design professional, and on Engineer's review of the Application for Payment and the accompanying data and schedules, that to the best of Engineer's knowledge, information and belief: a. the Work has progressed to the point indicated; b. the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, the results of any subsequent tests called for in the Contract Documents, a final determination of quantities and classifications for Unit Price Work under Paragraph 13.03, and any other qualifications stated in the recommendation); and c. the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work. 3. By recommending any such payment Engineer will not thereby be deemed to have represented that: a. inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in the Contract; or b. there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 60 of 70 4. Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment, including final payment, will impose responsibility on Engineer: a. to supervise, direct, or control the Work; b. for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto; c. for Contractor's failure to comply with Laws and Regulations applicable to Contractor's performance of the Work; d. to make any examination to ascertain how or for what purposes Contractor has used the money paid by Owner; or e. to determine that title to any of the Work, materials, or equipment has passed to Owner free and clear of any Liens. 5. Engineer may refuse to recommend the whole or any part of any payment if, in Engineer's opinion, it would be incorrect to make the representations to Owner stated in Paragraph 15.01.C.2. 6. Engineer will recommend reductions in payment (set -offs) necessary in Engineer's opinion to protect Owner from loss because: a. the Work is defective, requiring correction or replacement; b. the Contract Price has been reduced by Change Orders; c. Owner has been required to correct defective Work in accordance with Paragraph 14.07, or has accepted defective Work pursuant to Paragraph 14.04; d. Owner has been required to remove or remediate a Hazardous Environmental Condition for which Contractor is responsible; or e. Engineer has actual knowledge of the occurrence of any of the events that would constitute a default by Contractor and therefore justify termination for cause under the Contract Documents. D. Payment Becomes Due 1. Ten days after presentation of the Application for Payment to Owner with Engineer's recommendation, the amount recommended (subject to any Owner set -offs) will become due, and when due will be paid by Owner to Contractor. E. Reductions in Payment by Owner 1. In addition to any reductions in payment (set -offs) recommended by Engineer, Owner is entitled to impose a set-off against payment based on any of the following: a. Claims have been made against Owner based on Contractor's conduct in the performance or furnishing of the Work, or Owner has incurred costs, losses, or damages resulting from Contractor's conduct in the performance or furnishing of the Work, including but not limited to claims, costs, losses, or damages from workplace injuries, adjacent property damage, non-compliance with Laws and Regulations, and patent infringement; EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 61 of 70 b. Contractor has failed to take reasonable and customary measures to avoid damage, delay, disruption, and interference with other work at or adjacent to the Site; c. Contractor has failed to provide and maintain required bonds or insurance; d. Owner has been required to remove or remediate a Hazardous Environmental Condition for which Contractor is responsible; e. Owner has incurred extra charges or engineering costs related to submittal reviews, evaluations of proposed substitutes, tests and inspections, or return visits to manufacturing or assembly facilities; f. The Work is defective, requiring correction or replacement; g. Owner has been required to correct defective Work in accordance with Paragraph 14.07, or has accepted defective Work pursuant to Paragraph 14.04; h. The Contract Price has been reduced by Change Orders; i. An event has occurred that would constitute a default by Contractor and therefore justify a termination for cause; j. Liquidated or other damages have accrued as a result of Contractor's failure to achieve Milestones, Substantial Completion, or final completion of the Work; k. Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of such Liens; or I. Other items entitle Owner to a set-off against the amount recommended. 2. If Owner imposes any set-off against payment, whether based on its own knowledge or on the written recommendations of Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and the specific amount of the reduction, and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, if Contractor remedies the reasons for such action. The reduction imposed will be binding on Contractor unless it duly submits a Change Proposal contesting the reduction. 3. Upon a subsequent determination that Owner's refusal of payment was not justified, the amount wrongfully withheld will be treated as an amount due as determined by Paragraph 15.01.D.1 and subject to interest as provided in the Agreement. 15.02 Contractor's Warranty of Title A. Contractor warrants and guarantees that title to all Work, materials, and equipment furnished under the Contract will pass to Owner free and clear of (1) all Liens and other title defects, and (2) all patent, licensing, copyright, or royalty obligations, no later than 7 days after the time of payment by Owner. 15.03 Substantial Completion A. When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete and request that Engineer issue a certificate of Substantial Completion. Contractor shall at the same time EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 62 of 70 submit to Owner and Engineer an initial draft of punch list items to be completed or corrected before final payment. B. Promptly after Contractor's notification, Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor. C. If Engineer considers the Work substantially complete, Engineer will deliver to Owner a preliminary certificate of Substantial Completion which will fix the date of Substantial Completion. Engineer shall attach to the certificate a punch list of items to be completed or corrected before final payment. Owner shall have 7 days after receipt of the preliminary certificate during which to make written objection to Engineer as to any provisions of the certificate or attached punch list. If, after considering the objections to the provisions of the preliminary certificate, Engineer concludes that the Work is not substantially complete, Engineer will, within 14 days after submission of the preliminary certificate to Owner, notify Contractor in writing that the Work is not substantially complete, stating the reasons therefor. If Owner does not object to the provisions of the certificate, or if despite consideration of Owner's objections Engineer concludes that the Work is substantially complete, then Engineer will, within said 14 days, execute and deliver to Owner and Contractor a final certificate of Substantial Completion (with a revised punch list of items to be completed or corrected) reflecting such changes from the preliminary certificate as Engineer believes justified after consideration of any objections from Owner. D. At the time of receipt of the preliminary certificate of Substantial Completion, Owner and Contractor will confer regarding Owner's use or occupancy of the Work following Substantial Completion, review the builder's risk insurance policy with respect to the end of the builder's risk coverage, and confirm the transition to coverage of the Work under a permanent property insurance policy held by Owner. Unless Owner and Contractor agree otherwise in writing, Owner shall bear responsibility for security, operation, protection of the Work, property insurance, maintenance, heat, and utilities upon Owner's use or occupancy of the Work. E. After Substantial Completion the Contractor shall promptly begin work on the punch list of items to be completed or corrected prior to final payment. In appropriate cases Contractor may submit monthly Applications for Payment for completed punch list items, following the progress payment procedures set forth above. F. Owner shall have the right to exclude Contractor from the Site after the date of Substantial Completion subject to allowing Contractor reasonable access to remove its property and complete or correct items on the punch list. 15.04 Partial Use or Occupancy A. Prior to Substantial Completion of all the Work, Owner may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which Owner, Engineer, and Contractor agree constitutes a separately functioning and usable part of the Work that can be used by Owner for its intended purpose without EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 63 of 70 significant interference with Contractor's performance of the remainder of the Work, subject to the following conditions: 1. At any time, Owner may request in writing that Contractor permit Owner to use or occupy any such part of the Work that Owner believes to be substantially complete. If and when Contractor agrees that such part of the Work is substantially complete, Contractor, Owner, and Engineer will follow the procedures of Paragraph 15.03.A through 15.03.E for that part of the Work. 2. At any time, Contractor may notify Owner and Engineer in writing that Contractor considers any such part of the Work substantially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 3. Within a reasonable time after either such request, Owner, Contractor, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner and Contractor in writing giving the reasons therefor. If Engineer considers that part of the Work to be substantially complete, the provisions of Paragraph 15.03 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 4. No use or occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of Paragraph 6.04 regarding builder's risk or other property insurance. 15.05 Final Inspection A. Upon written notice from Contractor that the entire Work or an agreed portion thereof is complete, Engineer will promptly make a final inspection with Owner and Contractor and will notify Contractor in writing of all particulars in which this inspection reveals that the Work, or agreed portion thereof, is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 15.06 Final Payment A. Application for Payment 1. After Contractor has, in the opinion of Engineer, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance, certificates of inspection, annotated record documents (as provided in Paragraph 7.12), and other documents, Contractor may make application for final payment. 2. The final Application for Payment must be accompanied (except as previously delivered) by: a. all documentation called for in the Contract Documents; b. consent of the surety, if any, to final payment; c. satisfactory evidence that all title issues have been resolved such that title to all Work, materials, and equipment has passed to Owner free and clear of any Liens or other title defects, or will so pass upon final payment. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 64 of 70 d. a list of all duly pending Change Proposals and Claims; and e. complete and legally effective releases or waivers (satisfactory to Owner) of all Lien rights arising out of the Work, and of Liens filed in connection with the Work. In lieu of the releases or waivers of Liens specified in Paragraph 15.06.A.2 and as approved by Owner, Contractor may furnish receipts or releases in full and an affidavit of Contractor that: (a) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (b) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which Owner might in anyway be responsible, or which might in any way result in liens or other burdens on Owner's property, have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any Lien, or Owner at its option may issue joint checks payable to Contractor and specified Subcontractors and Suppliers. B. Engineer's Review of Final Application and Recommendation of Payment: If, on the basis of Engineer's observation of the Work during construction and final inspection, and Engineer's review of the final Application for Payment and accompanying documentation as required by the Contract Documents, Engineer is satisfied that the Work has been completed and Contractor's other obligations under the Contract have been fulfilled, Engineer will, within 10 days after receipt of the final Application for Payment, indicate in writing Engineer's recommendation of final payment and present the final Application for Payment to Owner for payment. Such recommendation will account for any set -offs against payment that are necessary in Engineer's opinion to protect Owner from loss for the reasons stated above with respect to progress payments. Otherwise, Engineer will return the Application for Payment to Contractor, indicating in writing the reasons for refusing to recommend final payment, in which case Contractor shall make the necessary corrections and resubmit the Application for Payment. C. Notice of Acceptability: In support of its recommendation of payment of the final Application for Payment, Engineer will also give written notice to Owner and Contractor that the Work is acceptable, subject to stated limitations in the notice and to the provisions of Paragraph 15.07. D. Completion of Work: The Work is complete (subject to surviving obligations) when it is ready for final payment as established by the Engineer's written recommendation of final payment and issuance of notice of the acceptability of the Work. E. Final Payment Becomes Due: Upon receipt from Engineer of the final Application for Payment and accompanying documentation, Owner shall set off against the amount recommended by Engineer for final payment any further sum to which Owner is entitled, including but not limited to set -offs for liquidated damages and set -offs allowed under the provisions of this Contract with respect to progress payments. Owner shall pay the resulting balance due to Contractor within 30 days of Owner's receipt of the final Application for Payment from Engineer. 15.07 Waiver of Claims A. By making final payment, Owner waives its claim or right to liquidated damages or other damages for late completion by Contractor, except as set forth in an outstanding Claim, EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 65 of 70 appeal under the provisions of Article 17, set-off, or express reservation of rights by Owner. Owner reserves all other claims or rights after final payment. B. The acceptance of final payment by Contractor will constitute a waiver by Contractor of all claims and rights against Owner other than those pending matters that have been duly submitted as a Claim, or appealed under the provisions of Article 17. 15.08 Correction Period A. If within one year after the date of Substantial Completion (or such longer period of time as may be prescribed by the Supplementary Conditions or the terms of any applicable special guarantee required by the Contract Documents), Owner gives Contractor written notice that any Work has been found to be defective, or that Contractor's repair of any damages to the Site or adjacent areas has been found to be defective, then after receipt of such notice of defect Contractor shall promptly, without cost to Owner and in accordance with Owner's written instructions: 1. correct the defective repairs to the Site or such adjacent areas; 2. correct such defective Work; 3. remove the defective Work from the Project and replace it with Work that is not defective, if the defective Work has been rejected by Owner, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others, or to other land or areas resulting from the corrective measures. B. Owner shall give any such notice of defect within 60 days of the discovery that such Work or repairs is defective. If such notice is given within such 60 days but after the end of the correction period, the notice will be deemed a notice of defective Work under Paragraph 7.17.13. C. If, after receipt of a notice of defect within 60 days and within the correction period, Contractor does not promptly comply with the terms of Owner's written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. Contractor shall pay all costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others). Contractor's failure to pay such costs, losses, and damages within 10 days of invoice from Owner will be deemed the start of an event giving rise to a Claim under Paragraph 12.01.13, such that any related Claim must be brought within 30 days of the failure to pay. D. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications. E. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this paragraph, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 66 of 70 F. Contractor's obligations under this paragraph are in addition to all other obligations and warranties. The provisions of this paragraph are not to be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. ARTICLE 16—SUSPENSION OF WORK AND TERMINATION 16.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 90 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times directly attributable to any such suspension. Any Change Proposal seeking such adjustments must be submitted no later than 30 days after the date fixed for resumption of Work. 16.02 Owner May Terminate for Cause A. The occurrence of any one or more of the following events will constitute a default by Contractor and justify termination for cause: 1. Contractor's persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment, or failure to adhere to the Progress Schedule); 2. Failure of Contractor to perform or otherwise to comply with a material term of the Contract Documents; 3. Contractor's disregard of Laws or Regulations of any public body having jurisdiction; or 4. Contractor's repeated disregard of the authority of Owner or Engineer. B. If one or more of the events identified in Paragraph 16.02.A occurs, then after giving Contractor (and any surety) 10 days' written notice that Owner is considering a declaration that Contractor is in default and termination of the Contract, Owner may proceed to: 1. declare Contractor to be in default, and give Contractor (and any surety) written notice that the Contract is terminated; and 2. enforce the rights available to Owner under any applicable performance bond. C. Subject to the terms and operation of any applicable performance bond, if Owner has terminated the Contract for cause, Owner may exclude Contractor from the Site, take possession of the Work, incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere, and complete the Work as Owner may deem expedient. D. Owner may not proceed with termination of the Contract under Paragraph 16.02.13 if Contractor within 7 days of receipt of notice of intent to terminate begins to correct its failure to perform and proceeds diligently to cure such failure. E. If Owner proceeds as provided in Paragraph 16.02.13, Contractor shall not be entitled to receive any further payment until the Work is completed. If the unpaid balance of the Contract Price exceeds the cost to complete the Work, including all related claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 67 of 70 attorneys, and other professionals) sustained by Owner, such excess will be paid to Contractor. If the cost to complete the Work including such related claims, costs, losses, and damages exceeds such unpaid balance, Contractor shall pay the difference to Owner. Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when so approved by Engineer, incorporated in a Change Order. When exercising any rights or remedies under this paragraph, Owner shall not be required to obtain the lowest price for the Work performed. F. Where Contractor's services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue, or any rights or remedies of Owner against Contractor or any surety under any payment bond or performance bond. Any retention or payment of money due Contractor by Owner will not release Contractor from liability. G. If and to the extent that Contractor has provided a performance bond under the provisions of Paragraph 6.01.A, the provisions of that bond will govern over any inconsistent provisions of Paragraphs 16.02.13 and 16.02.D. 16.03 Owner May Terminate for Convenience A. Upon 7 days' written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. In such case, Contractor shall be paid for (without duplication of any items): 1. completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums for overhead and profit on such Work; 2. expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials, or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; and 3. other reasonable expenses directly attributable to termination, including costs incurred to prepare a termination for convenience cost proposal. B. Contractor shall not be paid for any loss of anticipated profits or revenue, post -termination overhead costs, or other economic loss arising out of or resulting from such termination. 16.04 Contractor May Stop Work or Terminate A. If, through no act or fault of Contractor, (1) the Work is suspended for more than 90 consecutive days by Owner or under an order of court or other public authority, or (2) Engineer fails to act on any Application for Payment within 30 days after it is submitted, or (3) Owner fails for 30 days to pay Contractor any sum finally determined to be due, then Contractor may, upon 7 days' written notice to Owner and Engineer, and provided Owner or Engineer do not remedy such suspension or failure within that time, terminate the contract and recover from Owner payment on the same terms as provided in Paragraph 16.03. B. In lieu of terminating the Contract and without prejudice to any other right or remedy, if Engineer has failed to act on an Application for Payment within 30 days after it is submitted, or Owner has failed for 30 days to pay Contractor any sum finally determined to be due, Contractor may, 7 days after written notice to Owner and Engineer, stop the Work until payment is made of all such amounts due Contractor, including interest thereon. The EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 68 of 70 provisions of this paragraph are not intended to preclude Contractor from submitting a Change Proposal for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to Contractor's stopping the Work as permitted by this paragraph. ARTICLE 17—FINAL RESOLUTION OF DISPUTES 17.01 Methods and Procedures A. Disputes Subject to Final Resolution: The following disputed matters are subject to final resolution under the provisions of this article: 1. A timely appeal of an approval in part and denial in part of a Claim, or of a denial in full, pursuant to Article 12; and 2. Disputes between Owner and Contractor concerning the Work, or obligations under the Contract Documents, that arise after final payment has been made. B. Final Resolution of Disputes: For any dispute subject to resolution under this article, Owner or Contractor may: 1. elect in writing to invoke the dispute resolution process provided for in the Supplementary Conditions; 2. agree with the other party to submit the dispute to another dispute resolution process; or 3. if no dispute resolution process is provided for in the Supplementary Conditions or mutually agreed to, give written notice to the other party of the intent to submit the dispute to a court of competent jurisdiction. ARTICLE 18—MISCELLANEOUS 18.01 Giving Notice A. Whenever any provision of the Contract requires the giving of written notice to Owner, Engineer, or Contractor, it will be deemed to have been validly given only if delivered: 1. in person, by a commercial courier service or otherwise, to the recipient's place of business; 2. by registered or certified mail, postage prepaid, to the recipient's place of business; or 3. by e-mail to the recipient, with the words "Formal Notice" or similar in the e-mail's subject line. 18.02 Computation of Times A. When any period of time is referred to in the Contract by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 69 of 70 18.03 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract. The provisions of this paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 18.04 Limitation of Damages A. With respect to any and all Change Proposals, Claims, disputes subject to final resolution, and other matters at issue, neither Owner nor Engineer, nor any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, shall be liable to Contractor for any claims, costs, losses, or damages sustained by Contractor on or in connection with any other project or anticipated project. 18.05 No Waiver A. A party's non -enforcement of any provision will not constitute a waiver of that provision, nor will it affect the enforceability of that provision or of the remainder of this Contract. 18.06 Survival of Obligations A. All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract, as well as all continuing obligations indicated in the Contract, will survive final payment, completion, and acceptance of the Work or termination of the Contract or of the services of Contractor. 18.07 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 18.08 Assignment of Contract A. Unless expressly agreed to elsewhere in the Contract, no assignment by a party to this Contract of any rights under or interests in the Contract will be binding on the other party without the written consent of the party sought to be bound; and, specifically but without limitation, money that may become due and money that is due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract. 18.09 Successors and Assigns A. Owner and Contractor each binds itself, its successors, assigns, and legal representatives to the other party hereto, its successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. 18.10 Headings A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright° 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 70 of 70 TABLE OF CONTENTS OF SUPPLEMENTARY CONDITIONS TITLE ARTICLE NO. Introduction.................................................................................................................S.C. O DefinedTerms..........................................................................................................S.C. 1.01 Preliminary Schedules.......................................................................................... S.C. 2.03.A Intent........................................................................................................................S.C. 3.01 Reference Standards................................................................................................S.C. 3.02 Availabilityof Lands.................................................................................................S.C. 5.01 Reports and Drawings.......................................................................................... S.C. 5.03.A Contractor's Insurance.............................................................................................S.C. 6.03 Supervision and Superintendence...........................................................................S.C. 7.02 Permits.....................................................................................................................S.C. 7.09 Safety and Protection..............................................................................................S.C. 7.13 Submittals; Shop Drawings......................................................................................S.C. 7.16 Change Proposals; Change Proposal Procedures..................................................S.C. 11.09 Claims; Submittal of Claim.....................................................................................S.C. 12.01 Adjustments in Unit Price...................................................................................S.C. 13.03.E Tests, Inspections, and Approvals..........................................................................S.C. 14.02 Defective Work; Correction, Removal and Replacement .................................. S.C. 14.03.D ProgressPayments.................................................................................................S.C. 15.01 FinalPayment.........................................................................................................S.C. 15.06 CorrectionPeriod............................................................................................... S.C. 15.08.A Non -Discrimination Toward Handicapped Persons...............................................S.C. 18.11 C-700-72 SUPPLEMENTARY CONDITIONS ARTICLE S.C. O INTRODUCTION These Supplementary Conditions amend or supplement the Standard General Conditions of the Construction Contract (2018 Edition) and other provisions of the Contract Documents as indicated below. All provisions, which are not so amended, or supplemented, remain in full force and effect. ARTICLE S.C. 1.01 DEFINED TERMS The terms used in these Supplementary Conditions, which are defined in the Standard General Conditions of the Construction Contract (2018 Edition) have the meanings assigned to them in the General Conditions. 1. The use of the word "OWNER" refers to the City of Columbia Heights. 2. The use of the word "ENGINEER" refers to the City Engineer (or designated representative) of the City of Columbia Heights. 3. The use of the word "CONTRACTOR" refers to the firm or company contracted to do the work described in these specifications. 4. The use of the word "DEPARTMENT" shall be interpreted to mean the City of Columbia Heights 'Engineering' or Public Works Department. ARTICLE S.C. 2.03.A PRELIMINARY SCHEDULES Paragraph 2.03.A of the General Conditions shall be deleted and the following inserted in its place. "2.03.A Within ten (10) days after the Effective Date of the Contract (or as otherwise specifically required by the Contract Documents), and before starting any work at the site, Contractor shall submit to Engineer for timely review:" ARTICLE S.C. 3.01 INTENT Work under these Contract Documents shall be governed by all applicable Federal, State and Local laws, regulations, codes and ordinance and the Contract Documents. In the event of a conflict of meaning between any of the terms of the Contract Documents, the provisions of the document listed first below shall prevail over those of a document listed later: Contract Agreement C-700-73 Supplementary Conditions Project Plans Proposal and Proposal Form Addenda Technical Specifications — City of Columbia Heights Technical Specifications — Minnesota Department of Transportation General Conditions Special provisions and detail plans are intended to modify and prevail over standard plans and specifications. Should the Contract Documents conflict with any of the laws, regulations, codes, and ordinances mentioned in preceding paragraphs of these Supplementary Conditions, the laws and regulations shall take precedence. This shall not, however, be construed to relieve the Contractor from complying with the requirements of the Contract Documents which are in excess of, but not contrary to, the laws and regulations. ARTICLE S.C. 3.02 REFERENCE STANDARDS The work shall be performed in accordance with the Minnesota Department of Transportation "Standard Specifications for Construction", 2020 edition, and any supplements or amendments, including special provisions, thereto issued prior to the date of these Contract Documents, except as modified or supplemented by the "Standard Specifications for Trench Excavation and Backfill/Surface Restoration, Water main and Service Line Installation, and Sanitary Sewer and Storm Sewer Installation", 2020 Edition as published by the City Engineers Association of Minnesota and as modified or supplemented in these General Conditions, Supplementary Conditions or other Contract Documents. Coordination of plans and specifications shall be in accordance with the provisions of MnDOT Specification 1504, as modified by the following definitions: 3.02.1 Standard Specifications: Refer in precedent order to the "Standard Specifications", 2020 Edition as published by the City Engineers Association of Minnesota, the MnDOT Standard Specifications, 2020 edition, and the other specifications of ASTM, ANSI, AWWA, etc., as referenced and as published on the date of the bid advertisement. 3.02.2 Supplemental Specifications: Refer in precedent order to the Supplementary General Conditions and the General Conditions as contained in these Contract Documents. ARTICLE S.C. 5.01 AVAILABILITY OF LAND Amend Paragraph 5.01.A of the General Conditions by adding the following after the second sentence: "If Contractor believes that there has been delay in Owner's furnishing of lands, rights - of -way, easements, or permits, Contractor's sole remedy shall be an extension of C-700-74 contract time, for which the Contractor may make a claim therefore as provided in Article 11.08" And as so amended Paragraph 5.01.A remains in effect. ARTICLE S.C. 5.03.A REPORTS AND DRAWINGS Amend Paragraph 5.03.A of the General Conditions by adding the following sentence: "4. Reports and drawings described above are listed in the Table of Contents and provided with Appendixes unless otherwise noted." And as so amended Paragraph 5.03.A remains in effect. ARTICLE S.C. 6.03 CONTRACTOR'S INSURANCE The limits of liability for the insurance required by Paragraph 6.03 of the General Conditions shall provide coverage for not less than the following amounts, or greater, when required by laws and regulations. 6.03.A. Required Insurance 6.03.A.1. Workers' Compensation: STATE: STATUTORY APPLICABLE FEDERAL (E.G., LONGSHOREMAN'S) STATUTORY EMPLOYER'S LIABILITY $1,000,000 6.03.A.2. Commercial General Liability: 1. Bodily Injury (including completed operations and products liability): $1,000,000 Each Occurrence $2,000,000 Annual Aggregate 2. Property Damage: $1,000,000 Each Occurrence $2,000,000 Annual Aggregate or a combined single limit of: $2,000,000 3. Property Damage Liability Insurance will provide Explosion, Collapse and Underground Coverage's where applicable. Personal Iniury, with employment exclusion deleted: $2,000,000 Annual Aggregate C-700-75 6.03.A.3. Comprehensive Automobile liability: Bodily Injury: $1,000,000 Each Person $1,000,000 Each Occurrence Property Damage: $1,000,000 Each Occurrence or combined single limit of: $1,000,000 6.03.13. General Provisions: The Contractual Liability required by Paragraph 6.03.13.2. of the General Conditions shall provide coverage for not less than the following amounts: Bodily Injury: $1,000,000 Property Damage: $1,000,000 $2,000,000 6.03.C. Additional Insureds: Each Occurrence Each Occurrence Annual Aggregate The City of Columbia Heights shall be named as an additional insured. ARTICLE S.C. 7.02 SUPERVISION AND SUPERINTENDENCE The Contractor shall provide adequate supervision (superintendent) of the work as the job progresses. The superintendent shall report daily to the Engineer on the progress of the work and the number of men on the job. The superintendent shall maintain complete records of the work as it progresses and shall submit these records with each request for payment. The Contractor shall provide an adequate staff for properly coordinating and expediting the work, including office staff to handle by telephone any questions which may arise in the conductance of the work. ARTICLE S.C. 7.09 PERMITS The City of Columbia Heights will obtain permits that are necessary for this work from the C-700-76 following outside agencies: -- * Minnesota Department of Health -- * Metropolitan Council Environmental Service -- * Army Corp of Engineers. The Contractor is responsible to obtain permits that are necessary for this work from the following outside agencies: -- * Minnesota Department of Transportation -- * Anoka County Highway Department -- * Minnesota Pollution Control Agency (including General Storm -water Permit for Construction Activity) -- * Mississippi Watershed Management Organization --* Rice Creek Watershed District -- * Department of Natural Resources. All work under this contract shall take place on City -owned property, City -owned right-of-way, County -owned right-of-way, MnDOT-owned right-of-way, or easements to be obtained by the City under this contract. No work shall commence until the necessary permits are obtained. Before work is started, the Contractor shall obtain necessary locations of all underground utilities by contacting GOPHER STATE ONE CALL at 651-454-0002. ARTICLE S.C. 7.13 SAFETY AND PROTECTION Amend Paragraph 7.13.13. of the General Conditions by inserting the following after the first sentence: "In addition, Contractor shall provide a "competent person" as defined by O.S.H.A. on site when trench work is being performed." And as so amended Paragraph 7.13.13. remains in effect. ARTICLE S.C. 7.16 SUBMITTALS; SHOP DRAWINGS Amend Paragraph 7.16.B.1.b of the General Conditions by inserting the following after the first sentence: "Each shop drawing for a manhole or a catch basin shall reference the plan page number and the structure number." And as so amended Paragraph 7.16.B.1.b remains in effect. ARTICLE S.C. 11.09 CHANGE PROPOSALS; CHANGE PROPOSAL PROCEDURES Amend the first sentence of Paragraph 11.09.13.1. of the General Conditions to read as follows: C-700-77 "Contractor shall submit each Change Proposal to Engineer promptly (but in no event later than ten days) after the start of the event giving rise thereto, or after such initial decision. And as so amended Paragraph 11.09.13. remains in effect. ARTICLE S.C. 12.01 CLAIMS; SUBMITTAL OF CLAIM Amend the first sentence of Paragraph 12.01.13. of the General Conditions to read as follows: "The party submitting a Claim shall deliver it directly to the other party to the Contract promptly (but in no event later than ten days) after the start of the event giving rise thereto; in the case of appeals regarding Change Proposals within 30 days of the decision under appeal. And as so amended Paragraph 12.01.13. remains in effect. Except as specifically authorized in writing by the Engineer at the time additional work is done beyond the original scope of the Contract Documents, the Contractor shall have and make no claims for additional compensation. The Contractor's plea of ignorance of foreseeable conditions which will create difficulties or hindrances in the execution of the work will not be acceptable to the Owner as an excuse for any failure of the Contractor to fulfill the requirements of the Contract Documents, and shall not be a basis for the Contractor's claim for additional compensation. Any discrepancies in or conflicts between the items described in these Contract Documents must be submitted, in writing, to the Engineer for adjustment prior to proceeding with the work, as any claims for additional compensation to achieve compliance with the requirements of those items will not be allowed or considered. ARTICLE S.C. 13.03.E. ADJUSTMENTS IN UNIT PRICE ARTICLE G.C. 13.03.E. shall be amended by deleting this section in its entirety and substituting instead the following language: "There will be no adjustment in unit price for increased or decreased quantities under this Contract." ARTICLE S.C. 14.02 TEST, INSPECTIONS, AND APPROVALS ARTICLE G.C. 14.02.13 shall be amended by deleting this section in its entirety and substituting instead the following language: C-700-78 The project site sampling and testing of materials, called for hereinafter, shall be conducted by an independent testing laboratory approved by the Engineer, except as otherwise specified. All "Contractor" testing required by the SALT Schedule of Materials Control shall be paid for by the Contractor at all specified locations. All "Agency" and "Contracting Authority's Representative" testing shall be ordered and paid for by the Owner. The Contractor shall provide whatever services are needed to sample materials and perform these tests at all specified locations. Tests shall be made in accordance with the American Society for Testing and Materials (ASTM) Standard and Tentative Specifications that apply, except as otherwise specified. Inspections and testing shall in no way relieve the Contractor or Supplier from responsibility in furnishing materials and workmanship in accordance with the plans and specifications. The Contractor shall inform the Engineer when the construction item is ready to be tested. The Engineer may elect to delay the testing a reasonable amount of time to incorporate a larger area or quantity. All initial "Agency" tests at the specified locations shall be ordered by the Engineer and paid for by the Owner. Signed copies of all test reports shall be sent at once to the Engineer and the Contractor. These copies shall be received by the Engineer prior to authorizing the placement of any materials. The City is not responsible for delays caused by the testing laboratory. Should the specified tests fail to meet the requirements of the specifications, the Contractor shall take such additional tests at his expense as may be required to satisfy the Engineer that the materials conform to the specifications. The Contractor shall provide the Engineer with a letter from an approved testing laboratory indicating that all materials meet the requirements of the specifications and all tests as required have been completed according to specifications. Rejected materials shall immediately be removed from the site and shall not be used in the work. Signed copies of all reports on tests shall be sent at once to the Engineer and the Contractor. These copies shall be received by the Engineer prior to the placing of any of the tested items. Rejected materials shall immediately be removed from the site and shall not be used in the work. Inspections and testing shall in no way relieve the Contractor or Supplier from responsibility in furnishing materials and workmanship in accordance with the plans and specifications. Density test will be by "Specified Density" method. ARTICLE S.C. 14.03.11) DEFECTIVE WORK; CORRECTION, REMOVAL AND REPLACEMENT Amend Paragraph 14.03.D. of the General Conditions by inserting the following after the first C-700-79 sentence: "Correction work for bituminous surfacing shall conform to the requirements and standard plates in the City's right-of-way ordinance." And as so amended Paragraph 14.03.D. remains in effect. ARTICLE S.C. 15.01 PROGRESS PAYMENTS The Contractor must pay subcontractor(s) in accordance with Minnesota Statute 337.10 Building and Construction Contracts; Prohibited Provisions. After Substantial Completion, the Owner shall pay an amount sufficient to increase total payments to Contractor in accordance with Minnesota Statute 15.72 Progress Payments on Public Contracts; Retainage. ARTICLE S.C. 15.06 FINAL PAYMENT Before final payment is made for the work on this project, the Contractor must make a satisfactory showing that he has complied with the provisions of M.S.A. 290.92 requiring the withholding of State income taxes for wages paid to employees on this project. Receipt by the Owner of the Certificates of Compliance from the Commissioner of Taxation (IC-134) will satisfy this requirement. The Contractor is advised that before such certificate can be issued, he must first place on file with the Commissioner of Taxation an affidavit that he has complied with the provisions of M.S.A 290.92. The required affidavit form will be supplied by the Commissioner of Taxation, Centennial Office Building, St. Paul, Minnesota, on request. ARTICLE S.C. 15.08.A CORRECTION PERIOD Amend the first sentence of Paragraph 15.08.A. of the General Conditions to read as follows: "If within two years after the date of substantial completion in utility trench areas and one year after the date of substantial completion for the remainder of the construction, or such longer period of time as may be prescribed by Laws or Regulations or by the terms of any applicable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for CONTRACTOR's use by OWNER or permitted by Laws and Regulations as contemplated in paragraph 6.11.A is found to be defective, CONTRACTOR shall promptly, without cost to OWNER and in accordance with OWNER's written instructions: (i) repair such defective land or areas, or (ii) correct such defective Work or, if the defective Work has been rejected by OWNER, remove it from the Project and replace it with Work that is not defective, and (iii) satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom." C-700-80 And as so amended Paragraph 15.08.A. remains in effect. ARTICLE S.C. 18 MISCELLANEOUS ADD: ARTICLE S.C. 18.11 NON -DISCRIMINATION TOWARD HANDICAPPED PERSONS Before final payment is made for work on this project, the Contractor shall submit a letter to the Owner stating that the Contractor's firm maintains a policy of non-discrimination towards persons with handicapped conditions. C-700-81 DIVISION I GENERAL REQUIREMENTS (2014) DIV I - GENERAL - PAGE 1 OF 19 1. 2 3. 4. 5. 6. 7. 8. 9. 10. 11. 12. 13. 14. 15. 16. 17. 18. 19. 20. 21. 22. 23. 24. 25. 26. 27. 28. TABLE OF CONTENTS DIVISION I GENERAL REQUIREMENTS Page General....................................................................................................................... 3 Scopeof Work............................................................................................................ 3 Description of Project................................................................................................ 3 WorkSequence....................................................................................................... 3-4 Awardof Bids............................................................................................................. 4 Preconstruction Conference...................................................................................... 4 Protection of Existing Facilities.................................................................................. 5 Construction Stakes -- Alignment and Grades........................................................ 5-6 Inspectionof Work..................................................................................................... 6 Rubber -Tired Equipment........................................................................................... 6 SiteMaintenance....................................................................................................6-8 FinalInspection.......................................................................................................... 8 Samplingand Testing.............................................................................................. 8-9 Temporary Sanitary Facilities................................................................................... 10 Protection of the Public........................................................................................... 10 Traffic Provisions, Signing and Public Safety ...................................................... 10-11 Protection of Adjacent Properties........................................................................... 11 Air and Water Pollution...................................................................................... 11-12 ErosionControl........................................................................................................ 12 ConstructionLimits.................................................................................................. 12 Timeof Work........................................................................................................... 13 LiquidatedDamages................................................................................................. 13 Compensation for Increased or Decreased Quantities ........................................... 13 PartialPayments...................................................................................................... 13 Mobilization............................................................................................................. 13 Dewatering............................................................................................................... 14 TemporaryWater..................................................................................................... 14 SpecialProvisions................................................................................................ 15-21 DIV I - GENERAL - PAGE 2 OF 19 DIVISION I GENERAL REQUIREMENTS The General Conditions and Instructions to Bidders of the Work under contract as set forth in these Contract Documents shall apply to all work and materials furnished under these General Requirements and Technical Specifications except as may be hereinafter modified. 2. SCOPE OF WORK The Work to be carried out under these General Requirements shall include furnishing all labor, materials, tools, and equipment necessary for the construction of the proposed improvements, complete in place as described in these General Requirements. 3. DESCRIPTION OF PROJECT The following is a brief description of the work included as part of this project: 2022 Public Safety Fence Improvements — City Project Number 2207 This project involves fence construction at the following location: 825 4111 Ave NE, Columbia Heights, MN 55421 Work includes removals, new fence and related fence construction and gating. 4. WORK SEQUENCE The work shall be substantially completed on or before October 30, 2022, and ready for final inspection by November 20, 2022. Substantial completion shall be defined as the fence and gating fully installed and ready for contractor to install electrical and control components. Final completion shall be defined as the completion of all work as represented in the plans and specifications including restoration. Prior to the start of any work, as noted elsewhere in these Contract Documents, the Contractor shall submit in writing to the Engineer for approval, a schedule of procedure and after once approved, he shall not deviate from it without written permission from the Engineer. The schedule of procedure shall indicate the number of crews and men to be employed, locations of work for each crew, time schedule, work sequence, and moves and other pertinent information as required by the Engineer. DIV I - GENERAL - PAGE 3 OF 19 The Contractor shall perform his work in such a manner as to cause the least interference with and delay to such other work as may be in progress at the time, by other contractors. 5. AWARD OF BIDS As noted in the Instructions to Bidders, the City Council will be considering Award of Bids of the work at its regular meeting on Monday, July 25, 2022. It is anticipated that the City Council will award the contract at that time. It should be noted that there will be no compensation for increased or decreased quantities and the City reserves the right to reduce certain quantities or delete certain items from each section of the bids as the City considers the Award of Bids. 6. PRECONSTRUCTION CONFERENCE Prior to the start of the work, there will be a preconstruction conference arranged by the Engineer. Representatives of the Engineer and Contractor (including his project superintendent) shall be present at this meeting. Utility companies which service the City of Columbia Heights will also be invited to attend. At this meeting, the Contractor shall designate a competent project superintendent who shall be familiar with all phases of the work to be executed and who shall oversee the work during its progress. The project superintendent shall represent the Contractor in his absence, and communications and directions given by him shall be as binding as if given to the Contractor. Also at this meeting, the Contractor shall submit in writing to the Engineer for approval, a schedule of procedure indicating the order in which the Contractor proposes to perform the various stages of the work, the dates on which he will start the several salient features thereof (including procurement of materials, plant and equipment), and the contemplated dates for completing the same. This schedule shall be in the form of a bar chart of a suitable scale to indicate appropriately the percentage of work scheduled and completed by weekly intervals. The Contractor shall not deviate from said schedule after it has been approved without the permission of the Engineer. The Contractor's project superintendent shall attend a preconstruction meeting with property owners/residents adjacent to the construction areas and Engineering Department staff. 7. PROTECTION OF EXISTING FACILITIES A. The information shown on the plans has been provided by the supplier(s), DIV I - GENERAL - PAGE 4 OF 19 including the City of Columbia Heights. The owner does not guarantee the locations as shown on the plans. It is the Contractor's responsibility to ascertain the final location of all utilities by field verification and to notify the utility companies or affected agency a minimum of 72 hours prior to the commencement of work in each area. The Contractor shall notify the Engineer of any conflict between the existing utilities and the proposed construction. The Engineer in cooperation with utility companies shall determine the necessity for any relocation of these utilities. B. The Contractor shall protect all existing utilities and facilities so that they will continue to function in their proper manner both during construction and in the future. Any supporting structure that may be required because of the Contractor's operations shall be provided by him. The Contractor shall bring to the attention of the Engineer any conditions such as sand in manholes or valve boxes existing prior to the Contractor's excavation. Once excavation has commenced, it will be assumed that all damage to underground utilities has been caused by the Contractor's operations and it will be his responsibility to make the necessary repairs. 8. CONSTRUCTION STAKES -- ALIGNMENT AND GRADES All work under this Contract shall be constructed in accordance with lines and grades shown on the drawings and as established by the Engineer. These lines and grades may be modified by the Engineer as provided in the General Conditions. The Contractor shall render such assistance to the Engineer as may be required to accomplish the staking for proper execution of the work. The Contractor shall give the Engineer sufficient notice (two working days or more) of his need for the establishment of line and grade. After lines and grades for any part of the work have been set by the Engineer, the Contractor shall be held responsible for the proper execution of the work to such lines and grades until their removal is authorized by the Engineer. The Contractor shall, at his own expense, correct any mistakes caused by their unauthorized disturbance or removal. The Engineer may require that work be suspended at any time when, for any reason, such marks cannot be properly followed. No additional compensation shall be allowed the Contractor for any claims of crews being held up because of lack of line and grade stakes unless he has submitted a written request to the Engineer at least two working days in advance and is following a previously approved schedule of work. The Contractor shall assume full responsibility for all measurements made by him from the stakes and marks so established. DIV I - GENERAL - PAGE 5 OF 19 The Contractor shall be responsible for the preservation of all stakes and marks, and if any of the construction stakes or marks have been carelessly or willfully destroyed or disturbed by his forces, the cost of replacing them will be charged against him and will be deducted from the payment for the work. 9. INSPECTION OF WORK A. The Owner shall have the right to inspect the work at the job and storage site(s). The Contractor shall facilitate access to the work for the purpose of said inspection. B. Defects or departures from the Contract Documents uncovered during inspections shall be corrected by the Contractor at his expense. 10. RUBBER -TIRED EQUIPMENT The Contractor shall provide and use only rubber -tired dozers, front-end loaders and other necessary equipment, on all work where street pavement or portions of pavement are undisturbed. All such pavements shall be protected as the Engineer may direct. No compensation will be allowed the Contractor for replacement of damaged street pavements or utilities not scheduled for replacement. 11. SITE MAINTENANCE Maintenance of the streets and areas under construction, detours, by-passes and equipment yards used in conjunction with the project shall be the responsibility of the Contractor. Said maintenance shall include keeping the right-of-way free of obstacles and parked equipment, blading the traveled ways, and controlling the dust/debris in and around the construction area. The maintenance responsibility herein described shall be inherent to the Contractor and shall be applicable at all times, including weekends, throughout the construction period. The Contractor shall provide periodic inspection of the project, particularly during and after storms, to maintain blinker and barricades, provide dust and erosion control and general maintenance. If the Contractor is negligent in this respect, the City reserves the right to perform this work with its own forces at overtime rates. Keeping right-of-way free of obstacles and parked equipment Site maintenance shall include keeping streets, boulevards, and sidewalks free of obstacles, such as street signs, construction materials, barricades that are not in use, debris and parked equipment. DIV I - GENERAL - PAGE 6 OF 19 The Contractor shall remove all debris associated with the items of work included under this Contract. This debris shall be removed upon completion of each phase of the work or at such other times as may be necessary for coordination of the work of the Owner or others, the safety of employees, and the public or as required by applicable codes and regulations. No dumpsters are permitted at the construction site. Should the Contractor not remove rubbish or debris or not cleanup the site as specified above, the Owner reserves the right to have this work done by others and charge the Contractor for the expense of said work. Needed equipment shall be parked on the street under construction. Private vehicles shall be parked outside the project area. Controlling dust/debris in and around the construction area The construction area must be cleaned up daily. When dust becomes or appears to be becoming a nuisance or problem to the area or nearby residents, it shall be the responsibility of the Contractor to immediately alleviate the undesirable conditions. Streets in the area not under construction shall be kept free of construction materials, dirt, and other undesirable material. Once excavation has commenced, the City shall notify the Contractor when adjacent streets or alleys require sweeping. The contractor shall sweep said streets or alleys within 24 hours of the notice. The costs of such work will be charged to the Contractor. Section 2130 of the specifications is hereby amended to provide that the Contractor shall furnish and apply all water necessary on the project, including water used as dust palliative, washing of equipment, etc., and that such water shall be considered as an incidental item to the Contract and no direct payment will be made therefore. If the Contractor elects, he may use water from the City's water distribution system at no charge, provided he makes suitable arrangements with the Water Department. Water from private sources may be used only if permission has been granted by the property owner. Disregard of this provision shall be cause for suspension of the project until the Contractor can show evidence that men have hired specifically to perform the above work and will be on the project at all times. Where materials or debris have washed or flowed into or have been placed in ditches, gutters, drains, catch basins or elsewhere as a result of the Contractor's operations, such material or debris shall be removed and satisfactorily disposed of during progress of the work. All ditches, channels, drains, etc., shall be kept in clean and neat conditions. Temporary Haul Roads DIV I - GENERAL - PAGE 7 OF 19 The Contractor shall be responsible for construction of all necessary temporary haul roads required to complete the required excavation and disposal. Construction of temporary haul roads shall also include placement of necessary granular material over existing bituminous roadway surfaces. This material shall be of sufficient depth to allow for protection of existing bituminous surfaces. Construction of necessary haul roads shall be considered an incidental item to other construction items and no direct compensation will be made. 12. FINAL INSPECTION Upon written notice from the Contractor that the project is completed, the Engineer will make a preliminary inspection with the Contractor present. Upon completion of this preliminary inspection the Engineer will notify the Contractor, in writing, of any particulars in which this inspection reveals that the work is defective or incomplete. Upon receiving the written notice from the Engineer, the Contractor shall immediately undertake the work required to remedy defects and complete the project to the satisfaction of the Engineer. When the Contractor has corrected or completed the items as listed in the Engineer's Written Notice, he shall inform the Engineer, in writing, that the required work has been completed. Upon receipt of this notice, the Engineer, in the presence of the Contractor shall make his final inspection of the project. Should the Engineer find all work satisfactory at the time of this inspection, the Contractor will be allowed to make application for final payment in accordance with the provisions of the Contract Documents. Should the Engineer still find dissatisfaction with the work, the Engineer will inform the Contractor of the deficiencies and will deny the Contractor's request for final payment, until such time as the Contractor has satisfactorily completed the required work. 13. SAMPLING AND TESTING The project site sampling and testing of materials, called for hereinafter, shall be conducted by an independent testing laboratory approved by the Engineer, except as otherwise specified. All "Contractor" testing required by the SALT Schedule of Materials Control shall be paid for by the Contractor at all specified locations. All "Agency" and "Contracting Authority's Representative" testing shall be ordered and paid for by the Owner. The Contractor shall provide whatever services are needed to sample materials and perform these tests at all specified locations. Tests shall be made in accordance with the American Society for Testing and Materials (ASTM) Standard and Tentative Specifications that apply, except as otherwise specified. Inspections and testing shall in no way relieve the Contractor or Supplier from DIV I - GENERAL - PAGE 8 OF 19 responsibility in furnishing materials and workmanship in accordance with the plans and specifications. The Contractor shall inform the Engineer when the construction item is ready to be tested. The Engineer may elect to delay the testing a reasonable amount of time to incorporate a larger area or quantity. All initial "Agency" tests at the specified locations shall be ordered by the Engineer and paid for by the Owner. Signed copies of all test reports shall be sent at once to the Engineer and the Contractor. These copies shall be received by the Engineer prior to authorizing the placement of any materials. The City is not responsible for delays caused by the testing laboratory. Should the specified tests fail to meet the requirements of the specifications, the Contractor shall take such additional tests at his expense as may be required to satisfy the Engineer that the materials conform to the specifications. The Contractor shall provide the Engineer with a letter from an approved testing laboratory indicating that all materials meet the requirements of the specifications and all tests as required have been completed according to specifications. Rejected materials shall immediately be removed from the site and shall not be used in the work. Signed copies of all reports on tests shall be sent at once to the Engineer and the Contractor. These copies shall be received by the Engineer prior to the placing of any of the tested items. Rejected materials shall immediately be removed from the site and shall not be used in the work. Inspections and testing shall in no way relieve the Contractor or Supplier from responsibility in furnishing materials and workmanship in accordance with the plans and specifications. Density test will be by "Specified Density" method. 14. TEMPORARY SANITARY FACILITIES The Contractor shall furnish and maintain a temporary closet or privy of a type and a location approved by the Engineer. Any person working on the project shall be allowed to use the facility. The facility shall be removed when directed by the Engineer. 15. PROTECTION OF THE PUBLIC The Contractor shall provide all necessary barricades, fences and other protection as required for the proper execution of the work and for the protection of his employees, employees of the Owner, and other personnel according to all Federal, State, and Local regulations. This provision shall be incidental to the construction and no direct compensation will be paid therefor. The Contractor shall backfill all excavation at the end of each working day to the DIV I - GENERAL - PAGE 9 OF 19 satisfaction of the Engineer. This work shall be considered incidental to construction and no direct compensation shall be paid therefor. 16. TRAFFIC PROVISIONS, SIGNING AND PUBLIC SAFETY A. MNDOT 1404 and 1710 shall apply except as supplemented below: 1. All work under this Contract which may affect traffic shall be coordinated with the Engineer so as to provide reasonable traffic access to the area under construction. The Engineer reserves the right to require immediate backfilling of any street area which the Engineer deems to be in the best interests of traffic circulation within the City. The Contractor shall be responsible to maintain the backfilled trench in a condition to allow the passage of traffic until such time as restoration or reconstruction of the surface. No additional compensation will be paid for this maintenance. 2. The Contractor shall furnish, erect, and maintain warning lights and barricades as required by the Engineer to adequately warn and protect pedestrian and vehicular traffic from hazardous protrusions, materials, excavations, etc., resulting directly or indirectly from the construction. No payment will be made therefore. These lights, signs, etc., shall be placed by the Contractor in accordance with the Minnesota Manual on Uniform Traffic Control Devices (MN MUTCD). 3. At all times the Contractor shall prosecute his work in a manner which will allow access to all areas within the project by police and fire equipment. B. Method of Measurement: 1. Measure all required procedures and equipment on a lump sum basis. 2. No measurement will be made for individual items, equipment or temporary pavement markings. 3. Procedural and equipment revisions resulting from minor changes or field adjustments will be considered incidental. C. Basis of Payment: 1. Payment for the maintenance of traffic shall be at the Contract Unit Price as listed on the Bid Form. All associated work items shall be considered incidental. DIV I - GENERAL - PAGE 10 OF 19 2. Progress payment amounts for traffic control will be determined by the percentage of the total contract completed based on the following schedule: % OF CONTRACT Completed % of Item Paid 5% 15% 25% 40% 50% 70% 75% 90% 100% 100% 17. PROTECTION OF ADJACENT PROPERTIES The Contractor shall take whatever steps are necessary to protect adjoining properties and structures from hazards in connection with his performance of the work. The Contractor shall be responsible for all damages to properties and structures that occur as a result of his operations. Existing property iron monuments (capped or uncapped) disturbed by the Contractor shall be replaced at the Contractor's expense. Existing irrigation and pet containment systems disturbed by the Contractor shall be repaired at the Contractor's expense. 18. AIR AND WATER POLLUTION Pollution of natural resources of air, land, and water by operations under this Contract shall be prevented, controlled and abated in accordance with the rules, regulations, and standards adopted and established by the Minnesota Pollution Control Agency. The Contractor shall be responsible for dust control as an incidental item. 19. EROSION CONTROL Erosion control measures installed and maintained by the Contractor shall meet or exceed the requirements in the National Pollutant Discharge Elimination System (NPDES) Permit, whether or not a General Stormwater Permit for Construction Activity is required from the Minnesota Pollution Control Agency for this project. Erosion control shall include but not limited to the following: • silt fence, • fiber blanket/logs, • soil stabilization methods, • diversion ditches, DIV I - GENERAL - PAGE 11 OF 19 • storm drain inlet protection, • staked hay bales around manholes/catch basins, and • rock construction entrances, all which will be considered incidental to the project cost unless a pay item is provided. If the erosion control materials need to be removed to facilitate construction, these materials shall be replaced as soon as the construction item is completed. Failure to maintain the erosion control will be sufficient cause to withhold further payments on the project until the maintenance is complete. In addition, concrete ready -mix trucks shall have self-contained wash -out units. 20. CONSTRUCTION LIMITS The City will endeavor to have obtained all necessary easements and rights -of -way prior to the start of construction. Failure to acquire all easements and rights -of -way prior to the start of construction shall not be cause for the Contractor to request a time extension. Prior to beginning work, the City must have the necessary rights -of - way and easements. The Contractor shall confine his operations to the limits of the construction area. The Contractor shall contact the Engineer and obtain permission before storing, stockpiling, building haul roads, excavation, etc., outside existing rights -of -way. Clearing and grubbing shall be contained within the right-of-way, unless otherwise approved by the Engineer. 21. TIME OF WORK The Contractor shall notify the Owner in advance of all times when men and equipment are to work on this construction. In accordance with ordinances of the City of Columbia Heights, no work on this project shall take place between the hours of 7:00 p.m. and 7:00 a.m. and any time on Sundays, unless permission has been granted by the Owner. 22. LIQUIDATED DAMAGES Section 1807.2, Wavier of Liquidated Damages, is amended by eliminating the second paragraph in its entirety. Liquidated damages will accrue during the period from November 1st to April 15th inclusive, if the work has not been completed according to the stipulated schedule for substantial and final completion. DIV I - GENERAL - PAGE 12 OF 19 23. COMPENSATION FOR INCREASED OR DECREASED QUANTITIES Delete Paragraphs 1 through 3, MnDOT Section 1903 and substitute the following: "There will be no adjustment in unit price for increased or decreased quantities under this Contract." 24. PARTIAL PAYMENTS Quantities for each street shall be recorded by the Contractor and submitted to the Engineering Department prior to request for partial payment. 25. MOBILIZATION A. This item shall consist of preparatory work and operations, including, but not limited to, those necessary for the movement of personnel, equipment, supplies and incidentals to the Project site; for the establishment of all Contractor offices and buildings or other facilities necessary for work on the Project. B. Progress payment amounts for mobilization will be determined by the percentage of the total contract completed based on the following schedule: % OF CONTRACT Completed % of Item Paid 10% 50% 50% 75% 100% 100% 26. DEWATERING The Contractor shall provide excavation dewatering as necessary to allow for construction on stable foundation all at the expense of the Contractor. Dewatering operations may be controlled by permit from the DNR or other agencies. The Contractor is responsible for application for any necessary permits and compliance with all conditions to permits. The cost of all dewatering shall be incidental to the utility construction operation. 27. TEMPORARY WATER Water for new construction purposes may be obtained from the City. The Contractor shall make suitable arrangements with the Water Department for the location where water may be obtained. The City will not charge for water for all normal requirements, but reserves the right to charge the costs of any water which DIV I - GENERAL - PAGE 13 OF 19 is used over these normal requirements; such cost to be charged to the contractor. DIV I - GENERAL - PAGE 14 OF 19 DIVISION I SPECIAL PROVISIONS - GENERAL REQUIREMENTS 28. SPECIAL PROVISIONS 2. SCOPE OF WORK Materials used on the project must be from the MnDOT Approved/Qualified and Certified Product Lists when product types are listed. 11. SITE MAINTENANCE If the Contractor is negligent in performing site maintenance, the City reserves the right to perform this work with its own forces at the City's cost times an overhead multiplier of 2.9. 16. TRAFFIC PROVISIONS, SIGNING AND PUBLIC SAFETY Traffic shall be maintained in accordance with MnDOT 1404 and traffic control devices shall be furnished in accordance with MnDOT 1710 and the following: The Contractor shall furnish, install, maintain and remove all traffic control devices in accordance with the Traffic Control Layouts/Typical Traffic Control Layouts in the Plans (if applicable), these Special Provisions, and the Minnesota Manual on Uniform Traffic Control Devices (MN MUTCD) C including the most recent edition of the Field Manual for temporary traffic control zone layouts. The Engineer will have the right to modify the requirements for traffic control as he/she deems necessary due to existing field conditions. Special Protect Requirements: A. Notification of Lane or Street Closures to Public Safety Departments The Contractor shall contact the Fire and Police Departments prior to commencement of work and shall file with them the name of the contractor, name and emergency phone number of superintendent or person in charge, and location of the work area. Prior to blocking any traffic lanes or streets, notification of both the Fire and Police Departments shall be coordinated through the Engineering DIV I - GENERAL - PAGE 15 OF 19 Department. B. Driveway Access During the progress of construction, the Contractor shall make every effort to provide access to Public Safety parking lots. Access must be always maintained from one side. Prior notice must be given to any restrictions upon ingress or egress to parking areas, garages or drive lanes. The contractor will notify Engineer of changes and work on alternatives. C. Pedestrian Access During the progress of construction, the Contractor shall provide safe passage for pedestrians. Temporary Lane Closure Requirements: A. Temporary lane closures or other restrictions by the Contractor, during work hours and consistent with the time restrictions, will be permitted during those hours and at those locations approved by the Engineer. Requests for temporary lane closures shall be made at least 24 hours prior to such closures. The Contractor shall furnish, erect, and maintain all traffic control devices required for these closures. This may include, but is not limited to, barricades, advance warning arrow boards, warning signs, flaggers with two-way radios, trailers, flashers and cones. Application of traffic control devices shall be in accordance with the MN MUTCD. Sign panels shall be in accordance with the MnDOT Standard Signs Manual. B. The Owner reserves the right to impose time limitations on temporary lane closures, or other restrictions to traffic on other roads, as may be necessary to safely provide for traffic. The Engineer will have the right to lengthen, shorten, or otherwise modify the foregoing periods of restrictions as actual traffic conditions may warrant. C. All temporary lane closures used at night shall have plastic drum -like channelizers (or Type I barricades with steady burn lights) in the lane closure taper and also in any shifts in traffic alignment. D. When a temporary lane closure is used by the Contractor, the closure shall be incidental work and no direct compensation will be made. E. Temporary lane closures will not be permitted during non -working hours or inclement weather, nor any other time when, in the opinion of the Engineer, the lane closure will be a greater than normal hazard DIV I - GENERAL - PAGE 16 OF 19 to traffic. General Requirements: A. The Contractor shall be responsible for proper relocation of traffic control devices misplaced by Contractor and Subcontractor operations. B. The Contractor shall inspect, on a daily basis, all traffic control devices, which he has furnished and installed, and verify that the devices are placed in accordance with these Special Provisions, and the MN MUTCD. Any discrepancy between the placement and the required placement shall be immediately corrected. C. When signs are installed, they shall be mounted on posts driven into the ground at the proper height and lateral offset as detailed in the MN MUTCD. If this is not possible, they shall be mounted on portable supports or barricades as approved by the Engineer. When signs are removed, the sign posts shall also be removed as soon as possible. D. The Contractor shall be required to cover or remove all traffic control devices which may be inconsistent with traffic patterns during all traffic switches. E. All in -place signs and delineators mounted on less than three posts (not including back bracing) and which interfere with the Contractor's normal operation, shall be relocated outside of the work area by the Contractor at the direction of the Engineer. Upon completion of work at each sign location, or at the direction of the Engineer, the signs shall be replaced as near to their original locations as possible or to a location designated by the Engineer. Where it is necessary to remove "STOP" or other regulatory signs, the Contractor shall provide qualified flaggers when determined to be needed by the Engineer, until the signs are re -installed. Signs and structures damaged by the Contractor shall be replaced by him at his own expense. F. The Contractor shall provide, at his own expense, protective devices necessary to protect traffic from drop-offs, falling objects, splatter, or other hazards which may exist during construction operations. G. The Contractor will not be permitted to park his vehicles or construction equipment so as to obstruct any traffic control device. H. On any road open to traffic, materials, equipment, and other objects as determined by the Engineer, shall not be stored within the clear zone, as determined by the Engineer and as defined by AASHTO's DIV I - GENERAL - PAGE 17 OF 19 "Roadside Design Guide", 411 edition, unless adequately protected by a traffic barrier. Sandbags will be the only acceptable weight to stabilize traffic control devices. During freezing conditions, the sand for bags and impact barrels shall be mixed with a de-icer to prevent the sand from freezing. The sandbags shall be placed and maintained at the base of the traffic control devices to the satisfaction of the Engineer. All personnel working on or near the traveled roadway shall wear reflectorized safety apparel approved by OSHA. Traffic Control: This work shall consist of furnishing, installing, maintaining, and removing the traffic control devices required to safely provide for traffic as required by these Special Provisions: A. Maintenance of traffic control devices shall be continuous throughout the term of the Contract, including periods of suspension. The Contractor will be required to respond to any call from the Engineer for maintenance of traffic control devices within two hours from the time of notification. The Contractor shall provide a means of receiving calls for maintenance on a 24-hour-a-day basis throughout the term of the Contract. B. All signs shall conform to the Standard Signs Manual or as shown in the Plans. All barricades shall conform to Standard Plate 80001. All other devices shall conform to the Minnesota Manual on Uniform Traffic Control Devices, except as otherwise detailed in the Plans. Plates to be installed on in -place signs shall be installed using nylon washer spacers to provide air space between the plate and the in - place sign. C. No measurement will be made of the various items that constitute Traffic Control, but all such work will be construed to be included in the single Lump Sum for which payment is made. 19. EROSION CONTROL If the Contractor is negligent in maintaining erosion control measures, the City reserves the right to perform this work with its own forces at the City's cost times an overhead multiplier of 2.9. 20. CONSTRUCTION LIMITS DIV I - GENERAL - PAGE 18 OF 19 If it becomes necessary to obtain other easements to complete the construction, the Contractor can only obtain an extension of time. Unit prices will not be adjusted because of any delay. Unless otherwise noted on the plans, the construction area is defined as the street right-of-way. The Contractor shall protect adjacent slope paving, retaining wall, and other landscaping features. DIV I - GENERAL - PAGE 19 OF 19 DIVISION II STANDARD SPECIFICATIONS [ie1.l REMOVALS, EXCAVATION, STREET, CONSTRUCTION, AND RESTORATION 2014 DIV II - CONSTRUCTION - PAGE 1 OF 14 TABLE OF CONTENTS DIVISION II REMOVALS, EXCAVATION AND RESTORATION Page 1. Temporary Erosion Control................................................................................................. 3 2. Clearing and Grubbing..................................................................................................... 3-4 3. Excavations and Removal of Miscellaneous Structures .................................................. 4-5 6. Excavation and Backfill........................................................................................................ 5 12. Restoration..........................................................................................................................6 19. Topsoil and Sod................................................................................................................ 6-7 20. Finished Site Grading.......................................................................................................... 7 21. Special Provisions...........................................................................................................8-14 DIV 11- CONSTRUCTION - PAGE 2 OF 14 DIVISION II REMOVALS, EXCAVATION, STREET CONSTRUCTION AND RESTORATION 1. TEMPORARY EROSION CONTROL Erosion control measures installed and maintained by the Contractor shall meet or exceed the requirements in the National Pollutant Discharge Elimination System (NPDES) Permit, whether or not a General Stormwater Permit for Construction Activity is required from the Minnesota Pollution Control Agency for this project. Erosion control shall include but not limited to the following: • silt fence, • fiber blanket/logs, • soil stabilization methods, • diversion ditches, • storm drain inlet protection, • staked hay bales around manholes/catch basins, and • rock construction entrances, all which will be considered incidental to the project cost unless a pay item is provided. If the erosion control materials need to be removed to facilitate construction, these materials shall be replaced as soon as the construction item is completed. The contractor shall be responsible to remove erosion control devices upon turf establishment or prior to final completion. All stockpiled excavation material shall be shaped and covered in a manner so as to minimize erosion of this material. Erosion control barriers shall be as shown on the Plans or as directed by the Engineer. Erosion control barriers shall be maintained until final acceptance and final completion of the project. This shall be considered incidental to the project cost unless a pay item is provided. In addition, concrete ready -mix trucks shall have self-contained wash -out units. 2. CLEARING AND GRUBBING Payment for clearing and grubbing for shrubs, brush, stumps, windfall, and other plant life shall be incidental. If a specific line item for area clearing and grubbing is not included in the Bid Proposal Form, the work shall be considered incidental to the Contract. DIV 11- CONSTRUCTION - PAGE 3 OF 14 Clearing shall be construed as the complete removal and disposal of all portions of a tree which exist above ground except stumps. Grubbing shall be construed as the removal and disposal of the portions of a tree which exist below ground and stumps. Clearing operations shall be confined to the areas of road grading work except as directed by the Engineer. The Engineer shall designate such trees within the work area that are to be preserved. These trees shall be protected from injury or defacement during the construction period by the Contractor. Current and pertinent governmental regulations concerning disposal of trees, including but not limited to elm and ash trees, shall be obeyed. All brush shall be cut flush with the ground surface. Logs, windfalls, trees, snags, stumps, and other debris shall be removed from the excavation areas except as follows. In the roadway areas all stumps shall be grubbed. In other embankment areas, stumps may be flush cut. All stumps shall be grubbed in excavation areas. The removal of all trees required shall be accomplished in accordance with 2101 of MnDOT specifications. Payment shall be incidental to the contract. Some damage to the boulevard area is anticipated as necessary for construction procedure and no compensation will be made for restoration. The sawing or cutting of any existing monolithic sidewalks, concrete pipe or concrete structures, driveways, curbs and gutters, or bituminous pavement and to allow proper matching with new construction shall be accomplished by the Contractor as an incidental item to the contract for payment purposes unless specifically noted as a pay item in the specifications or indicated on the plans. Street name identification, speed limit or traffic signs and mailboxes may be located along parts of the work. So as to not interfere with the work, the Contractor shall remove these signs and mailboxes as directed by the Engineer as an item incidental to other pay items. These items shall be reinstalled as directed by the Engineer and shall be considered incidental to other pay items. Other miscellaneous structures may also need to be removed and possibly relocated as directed by the Engineer and as noted on the plans. Payment for these miscellaneous removals shall be considered incidental except as indicated on the plans and bid proposal form and shall include all costs involved in completing the removals. Payment will be full compensation for excavation, removal, and proper disposal of items. The Contractor shall remove and replace any fence within the construction limits of this contract. All fences shall be replaced in a condition better than or equal to that DIV II - CONSTRUCTION - PAGE 4 OF 14 which existed before construction. Unless a pay item is included on the proposal form, payment for fence removal and replacement shall be incidental to the improvement construction and no direct compensation will be paid therefor. Miscellaneous structures that must be removed shall be disposed of by the Contractor at his option subject to applicable City, County, and State regulations. Materials may not be buried on -site except as directed in writing by the Engineer. The cost of removal and disposal of all miscellaneous structures and excess materials and all costs connected therewith shall be considered incidental to the contract for payment purposes unless specifically noted as a pay item in the following sections or on the plans. 6. EXCAVATION AND EMBANKMENT Surface materials, such as topsoil in easements, ditches, or boulevards, and any gravel base in roadways shall be first carefully laid aside to be used last in finishing the backfilling procedure. Bituminous materials, concrete, sod, and other materials not suitable for trench backfilling shall be disposed of by the Contractor at no additional cost to the City unless specified on the plans or in the specifications as a pay item and shall include all costs involved in removing and disposing of material. All other excavated materials, where suitable, shall be replaced in the trench and compacted by mechanical means as approved by the Engineer. All excavation shall be accomplished in a careful and workmanlike manner so as to limit the area of surface disturbance to a minimum. Excessive surface disturbance due to poor workmanship or carelessness shall be replaced by the Contractor at his expense. Where ground water is encountered in the excavation, the Contractor shall effectively dewater and stabilize the foundation to permit proper construction and this work will be considered incidental to the project and no direct payment will be made therefor. Dewatering operations may be controlled by permit from the DNR or other agencies. The Contractor is responsible for application of any necessary permits and compliance with all conditions of the permits. Trees are to be protected to the fullest extent feasible. Such brush clearing and tree trimming necessary shall be done by experienced workmen. This Work shall be considered incidental to excavation and no direct compensation will be made therefor. Where the excavation and placement are near existing trees, special care must be exercised to minimize root damage. Root cutting, sealing and protection must be accomplished in accordance with direction of the Engineer. DIV II - CONSTRUCTION - PAGE 5 OF 14 12. RESTORATION All disturbed areas shall be restored to their original condition or better as soon as possible to minimize inconvenience to the public and liability of the Contractor. All existing grassed areas which are disturbed shall be restored with topsoil and seed as directed by the Engineer, except where areas are specifically ordered to be sodded. Sod shall be furnished and placed in accordance with MnDOT specification 2575, except that 6" of compacted topsoil shall be placed beneath the sod. Turf restoration must be maintained into a growing season in accordance with MnDOT 2575.3L & N, to the satisfaction of the Engineer. Disturbed pavements shall be restored according to methods described on the plans and in these specifications. The wear course shall be paved after turf restoration. Manholes, catch basins, valve boxes, and water service castings (curb boxes), will be required to be adjusted in accordance with the City's standards as specified herein to match finished grade work. This work will be considered incidental to restoration and no direct payment will be made unless otherwise provided for in the proposal form. Where existing driveway grades match proposed street grades, the driveway shall remain. However, where driveway elevations must change for proper grade matching, the driveways shall be regraded using in -place materials as directed by the Engineer. This regrading work shall be considered incidental to other pay items and no direct compensation will be made therefor. 19. TOPSOIL AND SOD Restoration is not anticipated on this project. If the contractor creates a large disturbance in the contract area, and restoration is needed it will be considered incidental to this project. It is the contractor's responsibility to remove all excess material and ensure site conditions are restored to preconstruction conditions. Topsoil is intended to be furnished and placed 6" thick on all sod and seed areas. The material shall be compacted firmly and raked prior to placement of sod. Sod shall meet the requirements of MnDOT Specifications, section 3878, type A — Lawn Sod. Payment for sod shall be on a square yard basis, measured in place. Topsoil shall be in accordance with MnDOT Specifications, section 3877, type A, or as modified by the Engineer and state on the plans and in the specifications. Payment for topsoil shall be on a cubic yard basis, loose volume (L.V.). No sod shall be placed on existing sod, but shall be "cut in" to abut existing sod. The DIV II - CONSTRUCTION - PAGE 6 OF 14 minimum "piece" of sod which can be placed shall be 18" by 18". Sod shall be placed in accordance with the most current MnDOT Specifications, section 3878. Payment for sod shall be on a square yard basis, excluding topsoil. 1►•I��d1►1f;�:L��l��l:�_V VLSI The Contractor shall be required to grade the entire site within the property line where turf is to be established or topsoil only placed. This work shall include all grading, leveling, berm construction, compaction, etc., to bring the site elevation to final grade. The tolerances defined in Part 8, Subgrade Preparation of this Division shall apply. This item does not apply to pavement areas. Payment for this work shall be incidental to topsoil placement and/or sodding and no direct compensation will be paid therefor. DIV II - CONSTRUCTION - PAGE 7 OF 14 DIVISION II SPECIAL PROVISIONS 21. REMOVALS, EXCAVATION, CONSTRUCTION, FENCING, GATING, RESTORATION, AND PAVEMENT MARKINGS Any material used on this project requiring pre -approval by MnDOT shall be included on the MnDOT Approved/Qualified Product Lists. The Contractor shall keep equipment off new bituminous and concrete surfaces, including curb and gutter whenever possible. As work progresses, new surfaces shall be protected from damage including scuffing by all equipment. 1. TEMPORARY EROSION CONTROL All slopes equal to or greater than 3:1 shall be restored with a one step bonded fiber matrix erosion control system, such as Soil Guard, by Weyerhaeuser, at a minimum rate of 3000 Ibs/acre. Uneven and irregular soil surfaces may require an application rate of 4000 Ibs/acre. Wood fiber blankets shall only be used upon approval of the Engineer. Payment shall be incidental to the project. 2. CLEARING AND GRUBBING Clearing and grubbing is defined as removing and disposing of trees, shrubs, brush, stumps, roots, windfalls, and other plant life, including dead and decayed matter, that exists within the construction areas which are not specifically designated to remain. This work shall be done in accordance with MnDOT Spec. 2101. The Engineer will establish the ROW lines and construction limits within which the clearing and grubbing operations are to be confined. The Contractor shall protect that which is to remain in accordance with MnDOT 1712, and shall conduct all clearing and grubbing operations in a manner that will not damage or jeopardize the surrounding plant life and property. The clearing operations should consist of cutting and removing the trees, shrubs, bushes, windfalls and other vegetation in the designated areas. At the same time the Contractor should prune off, as directed, any low hanging, unsound, or unsightly branches on the trees and shrubs designated to DIV II - CONSTRUCTION - PAGE 8 OF 14 remain. Brush should be defined as all bushes, shrubs and other vegetation that can be cut with a brush scythe or mowing machine, together with isolated trees less than the size defined as significant, above. All brush should be cut off within 6 inches of the ground surface. The grubbing operations shall consist of removing and disposing of the stumps, roots and other remains in the designated areas to the right-of-way line. Unless otherwise permitted, stumps shall be removed completely. Except in areas to be excavated, all depressions resulting from the grubbing operations shall be backfilled with suitable material and compacted to the satisfaction of the Engineer. This work item is considered incidental to the grubbing operations. It shall be determined that the clearing and grubbing has been satisfactorily completed before permitting grading operations in a given area to start. Any trees or shrubs within a clearing area that are designated to be preserved are to be identified and marked by the Engineer. Such markings may consist of tying or attaching to the tree, where it will be readily visible, a suitable placard or tag bearing the word SAVE. Temporary fencing shall be installed where existing fencing is taken down to facilitate construction. At other locations, when indicated on the Plans or when directed by the Engineer, the Contractor shall install temporary fencing at the construction limits prior to any construction activities in order to protect vegetation or further delineate the work areas. Temporary fencing shall be considered incidental. 3. EXCAVATION AND REMOVAL OF MISCELLANEOUS STRUCTURES A. The City reserves the right to have the Contractor stockpile any or all excess material at a site chosen by the Engineer. The stockpile site shall not be more than three (3) miles from the construction site. This work shall be considered incidental to construction and no direct compensation shall be paid therefor. B. On certain projects where work is performed in existing street areas, streets shall be restored to the specified cross-section or to existing conditions. There shall be no additional compensation for excess excavation of subgrade for establishment of tolerance grades where specified cross sections vary from existing conditions. 12. RESTORATION A. TOPSOIL DIV II - CONSTRUCTION - PAGE 9 OF 14 All turf areas disturbed by the construction shall be covered with a topsoil material meeting MnDOT Specification 3877.2A "Common Topsoil Borrow". The borrow shall meet the requirements of MnDOT Specification 3877, Table 3877-1, except 100% of the material shall pass through the 3/4" sieve. The topsoil mix shall be free of rock, debris, wood, roots and lumps and fine graded as directed by the City Engineer. Topsoil shall be placed a minimum of 6" thick over the area to be sodded or seeded. The topsoil fine grading shall not be completed more than 24 hours prior to the sod laying or seeding operation. The contractor shall not dump topsoil on the street unless specifically approved by the engineer in the field. Topsoil stockpiled on the street shall not be allowed to remain overnight unless proper safety flashers are installed and approved by the engineer in the field. At all times during grading, preparation and turf restoration, it shall be the contractor's responsibility to see that all catch basins in the construction area are kept clean. Gutters shall be cleaned and free of dirt and other materials at the end of each working day to ensure proper drainage. Payment for topsoil shall be considered incidental to the contract. Watering the sod shall be the responsibility of the contractor for 30 days. E. SEED Seed and hydraulic mulch will be installed only at locations shown on the plans, or as directed by the City Engineer. Hydroseeding and hydraulic mulch shall be done as separate applications, in accordance with MnDOT Specification 2575 and as modified herein. If seed is not planted before June 151", the City Engineer may require temporary hydraulic mulch shall be applied to the turf areas. Permanent seeding can be resumed between August 151" and October 151n Watering of the seed until 80% establishment shall be the DIV II - CONSTRUCTION - PAGE 10 OF 14 responsibility of the contractor. The seed mix shall be approved by the City Engineer prior to placement. The mix shall be MnDOT seed mixture 25-151, or an approved substitute. Seed shall be treated with Tazo-ST (hand seeding) or Tazo-B (hydroseeding), manufactured by TerraMax, or an approved equal. Apply Tazo in accordance with manufacturer's recommendations. Hand seeding: Seed shall be applied at an application rate of 150 pounds per acre, in two applications, for a total of 300 pounds per acre. Seed applications shall be in a criss-cross pattern, such as north - south and then east -west. Lightly rake seed %" to %" into the surface of the topsoil. Hydroseeding: Seed shall be applied at an application rate of 300 pounds per acre. A tracer product shall be used within the hydroseeding process, and will be considered incidental. Payment for seed and additive shall be incidental to the contract. F. HYDRAULIC MULCH Hydraulic mulch shall be Flexterra High Performance -Flexible Growth Medium, as manufactured by Profile Products, LLC, or an approved equal. Mix and apply mulch as recommended by manufacturer. Prior to application, the following shall be mixed in the tank with hydraulic mulch, on per acre basis: • 500 pounds plant starter 1-3-3 organic fertilizer • 6 ounces Tenacity (Mesotrione) weed control • 15 gallons Coron 28-0-0 (70% CRN) • 2 gallons Hydra -Hume • 2 gallons Nucleus O-Phos 8-24-0 • 16 ounces Kickstand PGR • 20 ounces ZyPro • .5 gallons Reservoir SP The Contractor will protect existing items in or near the construction area from overspray, including, but not limited to hard surfaces, landscape and plantings, fire hydrants and signs. Payment for hydraulic mulch and fertilizer shall be considered incidental to the contract. DIV II - CONSTRUCTION - PAGE 11 OF 14 G. TURF ESTABLISHMENT In the fall, after the turf has been established, provide a spray application of the following solution, on a per acre basis: • 2 gallons Hydra -Hume • 1 gallon Soaker Plus • 0.5 gallon Renova This is considered incidental to turf establishment. H. RESTORE LANDSCAPE Landscape materials shall be replaced in a condition better than or equal to that which existed before construction. Payment for landscaping restoration shall be incidental to the contract. STREET SWEEPING The contractor shall sweep the streets within two (2) calendar days following the completion of the sodding operations. This sweeping shall be with a pick-up power sweeper and shall continue until all loose material is completely cleaned up to the satisfaction of the Engineer. Also, all catch basins shall be cleaned to the engineer's satisfaction within the same time requirements stated above. 14. FENCE AND FABRIC REMOVAL All fence removals will require the removal of all components, including the footings. Disposal of the fence material shall be considered incidental to the removals, and the responsibility of the contractor. In area specifically called out for fabric removal only, slip sleeves will be installed on existing posts. Payment for fabric and fence removal will be by linear foot. 15. FENCE INSTALLATION CHAIN LINK FENCE All chain link fence posts must be installed to a minimum depth of 48". The posts can be air driven where not otherwise specified. Chain link specifications are to be designed as: DIV 11- CONSTRUCTION - PAGE 12 OF 14 1. 9 gauge core, 1" mesh, black vinyl coated chain link fabric 2. 1-5/8" top, middle and bottom rail 3. 2-1/2" line posts 4. 3" terminal posts 5. 4" gate posts 6. Top selvage twisted All installations must meet manufacturers recommendations. Where retaining wall exists there is a reinforcing geo grid installed. When footings are installed in areas where the geo grid is present, only a hole sufficiently sized for the footing is allowable. The mesh grid must be exposed before installing footings, and grid cut and removed to eliminate the risk of pulling the geo grid with auger. Where fence reinstallation would be difficult because of unknown underground infrastructure the installation of engineer approved slip sleeves are acceptable to bring the fence height to 8'. The installation of the slip sleeve must meet manufacturers recommended installation, and all exposed and welded areas must be primed and painted with exterior color matched metal adhering paint. Payment for chain link fence installation will be by linear foot. STEEL SECURITY FENCE The steel security fence shall be 8' Impasse II Gauntlet 3 rail, or Engineer's approved equal. The steel fence must have footings placed at every post. These posts are to be space no greater than 8', or at the manufacturers recommended width, whichever is less. Installation of all components must meet manufacturers recommended installation. No greater than 1" shall be allowed between the fence and the surrounding grade. Approved Equals must have: 1. 8' height 2. Base steel material 3. Uniform zinc coating 4. Phosphate & conversion coating 5. Epoxy base coat 6. Polyester powder finish coat 7. Security fasteners 8. Corrugated shape to resist prying or bending 9. Recessed bolt holes to prevent removal of bolt heads with standard tools DIV 11- CONSTRUCTION - PAGE 13 OF 14 10. 14 gauge Pales with a minimum bend to the top of the pale of 8-3/4" out from the property. Payment for steel fence installation will be by linear foot. 16. GATE REMOVAL Two access points to the employee parking lot are in place with sliding gates. The southern most access point has a single sliding gate; the northern point has two sliding gates. All three gates will be completely removed along with all posts, footings, electrical and control components. Payment for gate removals will be made on each gate removed. 17. GATE INSTALL Installation of 2 — 22' wide x 8' tall black vinyl coated chain -link Pivot AutoGates with 1" mesh and contoured to the ground and curbs. When gate is closed no greater than 1" opening between road surface and bottom of the gate. Gate installation will include footings, fence connections and verification of proper operation. Payment for gate installations will be made on each gate installed basis. 18. ACCESS CONTROLS AND PEDESTAL INSTALLATION Access Controls, electrical and concrete work to be completed by others and is not included in this project. The bidder is responsible for ensuring City staff know when the gates will be installed to minimize time between installation and access control work. DIV II - CONSTRUCTION - PAGE 14 OF 14 Ei • L NO 1 1 I -I I I I I I I I I 1 CONNECT TO EXISTING FENCE CONNECT TO EXISTING FENCE I CON TRUCT BOLLARD CONSTRUCT CONCRETE MED AN AND ACC SS CONTROL p I UGp C-ONS4TRUCT NEW GATE REMOV� CONCRETE CURB AND ACCESS CONTROL REMOVE EXISTING GATE r\ 20' r REMOVE 20' OF CHAIN LINK FENCE 9- REMOVE CONCRETE MAINTENANCE STRIP m a U m a U REMOVE EIXISTING FENCE NSTALL NEW ANTI —CLIMB CHAIN LINK FENCE —PROTECT EXISTING FENCE m 7 U m Q U I REMOVE EXISTING GATE INSTALS NEW GATE Q I i =MAMMON c wm�=- 7 6'm ILI �Q REMOVE CHAIN LINK FABRIC, EXTEN E POSTS, m INSTALL NEW CHAIN I INIVI FABRIC, T ADD ADDITIONAL BRACING ASO NEEDED I -CAB CAB CAB 'CAB m U1 m V -•T rf i Q Q RECONNECT AC UESS CONTROL M*Mdpo - m �MM i Q m U �uhm � ' ^aMom mw0MA Q - ■� OM AN � m Q fA m U 1 0 - a U 1r � Q Q I U � � REMOVE EXISTING FENCE 1- E TI Q . -INSTALL GAUNTLET ANTI —CLIMB FENCE cn m I U - I U m1m a a �■ mmm ir _ I _ . v 63 v Q WV / - �' EXISTING WATER MAIN v - I v T - _ CAB —SCAB EXISTING CABLE COMMUNICATION LINE F/o F F/o F/o F/o F/o F/o F/o / F/o F/o F/o F/o F/o - E X I S T I N G RIGHT OF WAY _ SANITARY S E V�l� F/0 F/0 F/C F/o '� F/o F/0 F C F/C F/C F/o F/o F/o F/o F/o F/0 F/0 _ a EXISTING FIBER OPTIC LINE DESIGNED BY :BEN LUND SCALE 5 PROJECT 2207 DRAWN BY: BEN LUND HORIZONTAL : 1"=20' PUBLIC SAFETY DATE : 4/20/2022 COLUMBIA 04'HEIGHTS VERTICAL : 1" = 5' FENCING PLAN CONSTRUCTED 20' 4a' ASBUILT o SHEET 1 OF 1 1 - CAB -d REMOVE EXISTING FENCE INSTALL GAUNTLET ANTI —CLIMB FENCE ■ IN Contractor's Business Name: C e-- Address: t-ofe-S�- LAV,,Q� µ N S S 0 zS Phone No: $CXD — Fax No: BID FORM PROJECT IDENTIFICATION: 2022 PUBLIC SAFETY FENCE IMPROVEMENTS CITY PROJECT NUMBER 2207 *11 Lei 4 *0 2*01 This bid is submitted to: 10:00 A.M. - Tuesday. July 19. 2022 CITY OF COLUMBIA HEIGHTS 637 - 38TH AVENUE NE COLUMBIA HEIGHTS, MN 55421 1. The undersigned BIDDER proposes and agrees, if this Bid is accepted, to enter into an agreement with OWNER on the form included in the Contract Documents to perform and furnish all Work as specified or indicated in the Contract Documents for the Contract Price and within the Contract time indicated in this bid and in accordance with the other terms and conditions of the Contract Document. 2. BIDDER accepts all of the terms and conditions of the Advertisement or Invitation to Bid and Instruction to Bidders. This Bid will remain subject to acceptance for sixty (60) days after the day of Bid opening. BIDDER will sign and submit the Agreement with other documents required by the Bidding Requirements within fifteen (15) days after the date of OWNER'S NOTICE OF AWARD. 3. In submitting this bid, BIDDER represents, as more fully set forth in the Agreement, 11 that: (a) BIDDER has examined copies of all the Bidding Documents and of the following Addenda (receipt of all of which is hereby acknowledged): Date I Number tJ � (b) BIDDER has familiarized itself with the nature and extent of the Contract Documents, Work, site, locality, and all local conditions and laws and regulations that in any manner may affect cost, progress, performance or furnishing of Work. (c) BIDDER has studied carefully all reports and drawings of subsurface conditions and drawings of physical conditions which are identified in the Supplementary Conditions as provided in Paragraph 5.03 & 5.04 of the General Conditions, and accepts the determination set forth in Paragraph S.C. 5.03 of the Supplementary Conditions of the extent of the technical data contained in such reports and drawings upon which BIDDER is entitled to rely. (d) BIDDER has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying) all such examinations, investigations, explorations, tests and studies (in addition to or to supplement those referred to in (c) above) which pertain to the subsurface or physical conditions at the site or otherwise may affect the cost, progress, performance or furnishing of the work as BIDDER considers necessary for the performance of furnishing the work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of Paragraph 5.03 & 5.04 of the General Conditions; and no additional examinations, investigations, explorations, tests, reports or similar information or data are or will be required by BIDDER for such purposes. (e) BIDDER has reviewed and checked all information and data shown or indicated on the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of said Underground Facilities. No additional examinations, investigations, explorations, tests, reports or similar information or data in respect of said Underground Facilities are or will be required by BIDDER in order to perform and furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of Paragraph 5.05 of 12 the General Conditions. (f) BIDDER has correlated the results of all such observations, examinations, investigations, explorations, tests, reports and studies with the terms and conditions of the Contract Documents. (g) BIDDER has given ENGINEER written notice of all conflicts, errors, discrepancies that it has discovered in the Contract Documents and the written resolution thereof by ENGINEER is acceptable to BIDDER. (h) This Bid is genuine and not made in the interest of or on behalf of any undisclosed person, firm or corporation and is not submitted in conformity with any agreement or rules of any group, association, organization or corporation; BIDDER has not directly or indirectly induced or solicited any other BIDDER to submit a false or sham Bid; BIDDER has not solicited or induced any person, firm or corporation to refrain from bidding; and BIDDER has not sought by collusion to obtain for itself any advantage over any other BIDDER or over OWNER. (i) Any other representation as required by Laws and Regulations. 4. BIDDER WILL COMPLETE THE WORK FOR THE FOLLOWING UNIT PRICE(S): (See Attached Pages 14 through 16) Quantities are indicated for the convenience of the Bidder. Final Payment will be based on actual quantities. 13 Ln r Z rD G) d rD A-4 cn cn v G) Et C 7 rD rt r+ n 3 a- -n rD 7 n rD n At v O ram+ rD rD m CL rD N W N rD rD v r o D M Q n � V n � rD m o C m M � m o D < M r+ m n 3. V S n S ❑7 T I T-n n! T I S 4A 3 O < rD G) v N 0o —I 0 N W v O N n S 7 r TI CD 7 n rD rD 3 O fD CD n O rD -n rD 3 n oa r C 3 IIc n 3 rTr � C !z 3 C W Un O O O O (D 0 •�, ,D o0 � a W m `fin 4 U) O V C W r n D T m � r m z N n O m N W � r Op n r m Ln D ; m -n z m ul T ' m n z - n c m O -0 r ;Z ( M O m N N OV z f ( D N H W O Ln O O V STATE OF 1 Z2��GIDTit COUNTY OF G ! AFFIDAVIT OF NON -COLLUSION: (1) That I am the BIDDER (if the bidder is an individual), a partner in the BIDDER (if the bidder is a partnership) of an officer or employee of the BIDDER corporation having authority to sign on its behalf (if the BIDDER is a corporation; (2) That the attached bid or bids have been arrived at by the BIDDER individually and have been submitted without collusion with, and without any agreement, understanding or planned common course of action with any vendor of materials, supplies, equipment or services described in the invitation to bid designed to limit individual bidding or competition; (3) That the contents of the bid or bids have not been communicated by the BIDDER, or its employees or agents, to any person not any employee or agent of the BIDDER, or its surety, on any bond furnished with the bid or bids, and will not be communicated to any person, prior to any official opening of the bids, or bids; and; (4) That I have fully informed myself regarding the accuracy of the statements made in this affidavit. BIDDER �AW �Qe e,,' t�,O FIRM AKING BIDS Subscribedpnd sworn to before me this ! 59� `"' day of '�Tu k--t 6,.,- l/ NAME L-AV'tx ri Linda M Capra OFFICIAL T NOTARY PUBLIC MINNESOTA ►sty comma F-Ores Jan. 31, 2M 15 2022. STATE OF MINNESOTA - RESPONSIBLE CONTRACTOR CERTIFICATE Applies to all prime contracts in excess of $50,000 A responsible contractor is defined in Minnesota Statutes §16C.285, subdivision 3. Any prime contractor or subcontractor who does not meet the minimum criteria under Minnesota Statutes §16C.285, subdivision 3, or who fails to verify that it meets those criteria, is not a responsible contractor and is not eligible to be awarded a construction contract for the project or to perform work on the project. A false statement under oath verifying compliance with any of the minimum criteria shall render the prime contractor or subcontractor that makes the false statement ineligible to be awarded a construction contract for the project and may result in termination of a contract awarded to a prime contractor or subcontractor that makes a false statement. A prime contractor shall submit to the contracting authority upon request copies of the signed verifications of compliance from all subcontractors of any tier pursuant to subdivision 3, clause 7. By signing this statement, I, lae-14 j (typed or printed name), _ Mtnl,n (title) certify that I am an owner or officer of the company and do verify under oat that my company is in compliance with each of the minimum criteria listed in the law. (�&04W Ggsl (name of the person, 4artnership or corporation submitting this proposal) 6(wElfrk'e- (business address) Signed: 7 %q (" d or horized representative) Date 16