Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
2017-2812
2017 -2812 AGREEMENT BETWEEN OWNER AND CONTRACTOR FOR CONSTRUCTION CONTRACT (STIPULATED PRICE) THIS AGREEMENT is by and between the CITY OF COLUMBIA HEIGHTS, MINNESOTA ( "Owner") and Forest Lake Contracting, Inc. Owner and Contractor hereby agree as follows: ARTICLE 1— WORK ( "Contractor ") 1.01 Contractor shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: 2017 STATE AID STREET REHABILITATION AND SIDEWALK IMPROVEMENTS — PROJECT 1705 2017 CSAH 2 STATE AID STORM SEWER AND STREET IMPROVEMENTS — PROJECT 1706 ARTICLE 2 —THE PROJECT 2.01 The Project, of which the Work under the Contract Documents is a part, is generally described as follows: CITY PROJECT NO. 1705, S.A.P. 113 - 110 -010 ♦ PARTIAL STREET RECONSTRUCTION ♦ SANITARY AND STORM SEWER INSTALLATION /REHABILITATION ♦ HYDRANT AND GATE VALVE RELOCATION ♦ CONCRETE CURB AND GUTTER ♦ ADA COMPLIANT PEDESTRIAN RAMPS ♦ CONCRETE SIDEWALK ♦ CONCRETE AND BITUMINOUS SURFACING ♦ MISCELLANEOUS CONSTRUCTION CITY PROJECT NO. 1706, S.A.P. 113 - 020 -006, S.A.P. 002 - 602 -012 ♦ FULL STREET RECONSTRUCTION ♦ STREET MILL AND OVERLAY ♦ SANITARY AND STORM SEWER INSTALLATION /REHABILITATION ♦ WATER MAIN, HYDRANT AND GATE VALVE RELOCATION ♦ CONCRETE CURB AND GUTTER ♦ ADA COMPLIANT PEDESTRIAN RAMPS ♦ CONCRETE SIDEWALK ♦ CONCRETE AND BITUMINOUS SURFACING ♦ MISCELLANEOUS CONSTRUCTION ALTERNATE 1, RESIDENTIAL DRIVEWAY CONSTRUCTION ALTERNATE 2, DEDUCT FOR SUBSTANIAL COMPLETION DATE OF JUNE 1, 2018 ADDENDUM 2 ♦ JPM HALL PARKING LOT ♦ 46TH AVENUE STREE RECONSTRUCTION EJCDC® C -520 (Rev. 1), Agreement Between Owner and Contractor for Construction Contract (Stipulated Price). Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 of 7 ARTICLE 3 — ENGINEER 3.01 The part of the Project that pertains to the Work has been designed by the CITY OF COLUMBIA HEIGHTS' ENGINEERING DEPARTMENT (ENGINEER). 3.02 The ENGINEER is to act as Owner's representative, assume all duties and responsibilities, and have the rights and authority assigned to Engineer in the Contract Documents in connection with the completion of the Work in accordance with the Contract Documents. ARTICLE 4 — CONTRACT TIMES 4.01 Time of the Essence A. All time limits for Milestones, if any, Substantial Completion, and completion and readiness for final payment as stated in the Contract Documents are of the essence of the Contract. 4.02 Contract Times: Dates A. The Work will be substantially completed on or before October 27, 2017 and completed and ready for final payment in accordance with Paragraph 15.06 of the General Conditions on or before November 22, 2017. B. If Alternate 2 is accepted by the City, the Work will be substantially completed on or before June 1, 2018 and completed and ready for final payment in accordance with Paragraph 15.06 of the General Conditions on or before June 29, 2018. 4.03 Liquidated Damages A. Contractor and Owner recognize that time is of the essence as stated in Paragraph 4.01 above and that Owner will suffer financial and other losses if the Work is not completed and Milestones not achieved within the times specified in Paragraph 4.02 above, plus any extensions thereof allowed in accordance with the Contract. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty): 1. Substantial Completion: Contractor shall pay Owner $1,000.00 for each day that expires after the time (as duly adjusted pursuant to the Contract) specified in Paragraph 4.02.A above for Substantial Completion until the Work is substantially complete. 2. Completion of Remaining Work: After Substantial Completion, if Contractor shall neglect, refuse, or fail to complete the remaining Work within the Contract Times (as duly adjusted pursuant to the Contract) for completion and readiness for final payment, Contractor shall pay Owner $1,000.00 for each day that expires after such time until the Work is completed and ready for final payment. 3. Liquidated damages for failing to timely attain Substantial Completion and final completion are not additive and will not be imposed concurrently. E1CDC11 C -520 (Rev. 1), Agreement Between Owner and Contractor for Construction Contract (Stipulated Price). Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 of 7 ARTICLE 5 — CONTRACT PRICE 5.01 Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents, subject to adjustment under the Contract: A. For all Work, at the prices stated in Contractor's Bid, attached hereto as an exhibit. B. The extended prices for Unit Price Work set forth as of the Effective Date of the Contract are based on estimated quantities. As provided in Paragraph 13.03 of the General Conditions, estimated quantities are not guaranteed, and determinations of actual quantities and classifications are to be made by Engineer. ARTICLE 6 — PAYMENT PROCEDURES 6.01 Submittal and Processing of Payments A. Contractor shall submit Applications for Payment in accordance with Article 15 of the General Conditions. Applications for Payment will be processed by Engineer as provided in the General Conditions. 6.02 Progress Payments, Retainage A. Owner shall make progress payments on account of the Contract Price on the basis of Contractor's Applications for Payment on or about the 15th day of each month during performance of the Work as provided in Paragraph 6.02.A.1 below, provided that such Applications for Payment have been submitted in a timely manner and otherwise meet the requirements of the Contract. All such payments will be measured by the Schedule of Values established as provided in the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no Schedule of Values, as provided elsewhere in the Contract. 1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below but, in each case, less the aggregate of payments previously made and less such amounts as Owner may withhold, including but not limited to liquidated damages, in accordance with the Contract a. 95 percent of Work completed (with the balance being retainage). If the Work has been 50 percent completed as determined by Engineer, and if the character and progress of the Work have been satisfactory to Owner and Engineer, then as long as the character and progress of the Work remain satisfactory to Owner and Engineer, there will be no additional retainage; and b. 95 percent of cost of materials and equipment not incorporated in the Work (with the balance being retainage). B. Upon Substantial Completion, Owner shall pay an amount sufficient to increase total payments to Contractor to 98 percent of the Work completed, less such amounts set off by Owner pursuant to Paragraph 15.01.E of the General Conditions, and less 200 percent of Engineer's estimate of the value of Work to be completed or corrected as shown on the punch list of items to be completed or corrected prior to final payment. 6.03 Final Payment A. Upon final completion and acceptance of the Work in accordance with Paragraph 15.06 of the General Conditions, Owner shall pay the remainder of the Contract Price as recommended by Engineer as provided in said Paragraph 15.06. EJCDC® C -520 (Rev. 1), Agreement Between Owner and Contractor for Construction Contract (Stipulated Price). Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 3 of 7 ARTICLE 7 — INTEREST 7.01 All amounts not paid when due shall bear interest at the rate stipulated in Minnesota Statute 161.322. ARTICLE 8 — CONTRACTOR'S REPRESENTATIONS 8.01 In order to induce Owner to enter into this Contract, Contractor makes the following representations: A. Contractor has examined and carefully studied the Contract Documents, and any data and reference items identified in the Contract Documents. B. Contractor has visited the Site, conducted a thorough, alert visual examination of the Site and adjacent areas, and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Contractor is familiar with and is satisfied as to all Laws and Regulations that may affect cost, progress, and performance of the Work. D. Contractor has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or adjacent to the Site and all drawings of physical conditions relating to existing surface or subsurface structures at the Site that have been identified in the Supplementary Conditions, especially with respect to Technical Data in such reports and drawings, and (2) reports and drawings relating to Hazardous Environmental Conditions, if any, at or adjacent to the Site that have been identified in the Supplementary Conditions, especially with respect to Technical Data in such reports and drawings. E. Contractor has considered the information known to Contractor itself; information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Contract Documents; and the Site - related reports and drawings identified in the Contract Documents, with respect to the effect of such information, observations, and documents on (1) the cost, progress, and performance of the Work; (2) the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor; and (3) Contractor's safety precautions and programs. F. Based on the information and observations referred to in the preceding paragraph, Contractor agrees that no further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract. G. Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Contract Documents. H. Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor. I. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. J. Contractor's entry into this Contract constitutes an incontrovertible representation by Contractor that without exception all prices in the Agreement are premised upon performing and furnishing the Work required by the Contract Documents. EJCDC® C -520 (Rev. 1), Agreement Between Owner and Contractor for Construction Contract (Stipulated Price). Copyright O 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 4 of 7 ARTICLE 9 — CONTRACT DOCUMENTS 9.01 Contents A. The Contract Documents consist of the following: 1. This Agreement (pages 1 to 7, inclusive). 2. Performance bond (pages 1 to 3, inclusive). 3. Payment bond (pages 1 to 3, inclusive). 4. Other bonds. a. _ (pages _ to _, inclusive). 5. General Conditions (pages 1 to 65, inclusive). 6. Supplementary Conditions (pages 00700 -66 to 00700 -74, inclusive). 7. Specifications as listed in the table of contents of the Project Manual. 8. Drawings (not attached but incorporated by reference) consisting of 2017 State Aid Street Rehabilitation and Sidewalk Improvements: 26 sheets with each sheet bearing the title 39th Avenue Reclamation and S.A.P. 113 - 110 -010 and 2017 CSAH 2 (40th Avenue) State Aid Storm Sewer and Street Improvements: 28 sheets with each sheet bearing the project numbers S.A.P 113 - 020 -006 and S.A.P. 002 - 602 -012. 9. Addenda (numbers 1 to 2, inclusive). 10. Exhibits to this Agreement (enumerated as follows): a. Contractor's Bid (pages 11 to 21, inclusive). 11. The following which may be delivered or issued on or after the Effective Date of the Contract and are not attached hereto: a. Notice to Proceed. b. Work Change Directives. c. Change Orders. B. The documents listed in Paragraph 9.01.A are attached to this Agreement (except as expressly noted otherwise above). C. There are no Contract Documents other than those listed above in this Article 9. D. The Contract Documents may only be amended, modified, or supplemented as provided in the General Conditions. E1CDC® C -520 (Rev. 1), Agreement Between Owner and Contractor for Construction Contract (Stipulated Price). Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 5 of 7 F ARTICLE 10 — MISCELLANEOUS 10.01 Terms A. Terms used in this Agreement will have the meanings stated in the General Conditions and the Supplementary Conditions. 10.02 Assignment of Contract A. Unless expressly agreed to elsewhere in the Contract, no assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, money that may become due and money that is due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 10.03 Successors and Assigns A. Owner and Contractor each binds itself, its successors, assigns,and legal representatives to the other party hereto, its successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. 10.04 Severability A. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 10.05 Contractor's Certifications A. Contractor certifies that it has not engaged in corrupt, fraudulent, collusive, or coercive practices in competing for or in executing the Contract. For the purposes of this Paragraph 10.05: 1. "corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the bidding process or in the Contract execution; 2. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the bidding process or the execution of the Contract to the detriment of Owner, (b) to establish Bid or Contract prices at artificial non - competitive levels, or (c) to deprive Owner of the benefits of free and open competition; 3. "collusive practice" means a scheme or arrangement between two or more Bidders, with or without the knowledge of Owner, a purpose of which is to establish Bid prices at artificial, non - competitive levels; and 4. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the bidding process or affect the execution of the Contract. 10.06 Other Provisions (if applicable). E1CDC® C -520 (Rev. 1), Agreement Between Owner and Contractor for Construction Contract (Stipulated Price). Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 6 of 7 |N WITNESS WHEREOF, Owner and Contractor have signed this Agreement. This Agreement will be effective nn (which is the Effective Date of the Contract\. OWNER: City of Columbia Heights Donna Schmitt, Mayor [CORPORATE SEAL] Attest: Title: t C teIr Address for giving notices: City of Columbia Heights 6373O~' Avenue NE Columbia Heights, MN 55421 (If OWNER ise corporation, attach evidence of authority to sign. |f OWNER isa public body, attach evidence of authority to sign and resolution or other documents authorizing execution of OWNER-CONTRACTOR Agreement.) Designated Representative: Name: Kevin Hansen Title: City Engineer Address: 63738 th Avenue NE Phone: 763-706-3705 Title: [CORPORATE SEAL] Attest: Title: Address for giving notices: License No.: (Where applicable) Agent for service mfprocess: (If Contractor isa corporation, a partnership, ora joint venture, attach evidence of authority to sign.) Designated Representative: Name: Title: Address: Phone: oCDCO C-520 (Rm1), Agreement Between Owner and Contractor for Construction Contract (Stipulated Price). Copyright m2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 7 of 7 ... AMr ,, ':3i • ► iii ORE -21" PAeklE L& Li1!P1VC, r,L' 1411:2 JA lIE VAQE: BIDS TO BE OPENED: 10:00 A.M. - TUESDAY, AUGUST 22,2017 This bid is submitted to: CITY OF COLUMBIA HEIGHTS 637 - 38' AVENUE NE COLUMBIA HEIGHTS, MN 55421 1. The undersigned BIDDER proposes and agrees, if this Bid is accepted, to enter into an agreement with OWNER on the form included in the Contract Documents to perform and furnish all Work as specified or indicated in the Contract Documents for the Contract Price and within the Contract time indicated in this bid and in accordance with the other terms and conditions of the Contract Document. BIDDER accepts all of the terms and conditions of the Advertisement or Invitation to Bid and Instruction to Bidders. This Bid will remain subject to acceptance for sixty (60) days after the day of Bid opening. BIDDER will sign and submit the Agreement with the Bonds and other documents required by the Bidding Requirements within fifteen (15) days after the date of OWNER'S NOTICE OF AWARD. 11 I i 3. in submitting this bid, BIDDER represents, as more fully set forth in the Agreement, that: (a) BIDDER has examined copies of all the Bidding Documents and of the following Addenda (receipt of all of which is hereby acknowledged): Date Number - ) +2-CA2 01:6 -#'W --201`-7 ,Z (b) BIDDER has familiarized itself with the nature and extent of the Contract Documents, Work, .site, locality, and all local conditions and laws and regulations that in any manner may affect cost, progress, performance or furnishing of Work. (c) BIDDER has studied carefully all reports and drawings of subsurface conditions and drawings of physical conditions which are identified in the Supplementary Conditions as provided in Paragraph 5.03 & 5.04 of the General Conditions, and accepts the determination set forth in Paragraph S.C. 5.03 of the Supplementary Conditions of the extent of the technical data contained in such reports and drawings upon which BIDDER is entitled to rely. (d) BIDDER has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying) all such examinations, investigations, explorations, tests and studies (in addition to or to supplement those referred to in (c) above) which pertain to the subsurface or physical conditions at the site or otherwise may affect the cost, progress, performance or furnishing of the work as BIDDER considers necessary for the performance of furnishing the work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of Paragraph 5.03 & 5.04 of the General Conditions; and no additional examinations, investigations, explorations, tests, reports or similar information or data are or will be required by BIDDER for such purposes. (e) BIDDER has reviewed and checked all information and data shown or indicated on the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of said Underground Facilities. No additional examinations, investigations, explorations, tests, reports or similar information or data in respect of said Underground Facilities are or will be required by BIDDER in order to perform and furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of Paragraph 5.05 of the General Conditions. 12 I { (f) BIDDER has correlated the results of all such observations, examinations, investigations, explorations, tests, reports and studies with the terms and conditions of the Contract Documents. (g) BIDDER has given ENGINEER written notice of all conflicts, errors, discrepancies that it has discovered in the Contract Documents and the written resolution thereof by ENGINEER is acceptable to BIDDER. (h) This Bid is genuine and not made in the interest of or on behalf of any undisclosed person, firm or corporation and is not submitted in conformity with any agreement or rules of any group, association, organization or corporation; BIDDER has not directly or indirectly induced or solicited any other BIDDER to submit a false or sham Bid; BIDDER has not solicited or induced any person, firm or corporation to refrain from bidding; and BIDDER has not sought by collusion to obtain for itself any advantage over any other BIDDER or over OWNER. (i) Any other representation as required by Laws and Regulations. 4. BIDDER WILL COMPLETE THE WORK FOR THE FOLLOWING UNIT PRICE(S): (See Attached Pages 14 through 17) Quantities are indicated for the convenience of the Bidder: Final Payment will be based on actual quantities. 13 4 , BID PROPOSAL FORM - CITY OF COLUMBIA HEIGHTS 2017 STATE AID STREET REHABILITATION AND SIDEWALK IMPROVEMENTS SAP 113 - 110-010, CH PROJECT 1705 2017 CSAH 2 (40TH AVENUE) STATE AID STORM SEWER AND STREET IMPROVEMENTS SAP 113 - 020-006, SAP 002 - 602 -012, CH PROJECT 1706 2017 STATE AID STREET REHABILITATION AND SIDEWALK IMPROVEMENTS, CH PROJECT 1705 No. Item Unit Quan t Unit Price Amount 1 Mobilization Lump Sum i $ V0al co $ t jge'coosflci 2 Pavement marking removal Lin. Ft. 140 $ 94.00 $ S(pU. co 3 Remove concrete curb and gutter Lin. Ft. 2190 $ !j, t. C) $ ICcjSO. 00 4 Remove pipe sewer Lin. Ft 6 $ 3©,pC) $ ($C3.00 5 Remove hydrant lead including gate valve & box Lin. Ft 15 $ 30.C, $ L4 S0.00 6 Remove bituminous driveway pavement Sq. Yd. 425 $ " 7„ OC> $ aL-1 1 S. c)Cs 7 Remove concrete driveway /alley pavement Sq. Ft 2525 $ 1. QO $ -3 C) 3Q. cab 8 Remove concrete walk Sq. Ft. 2020 $ 1, QC) $ d14Q44.00 9 Remove drainage structure Each 1 $ y 00.00 $ LA 00. C30 10 Remove manhole tap slab Each 1 $ 400.00 $ 4 cc ob 11 Sawing concrete (Full depth) Lin. Ft. 400 $ fa, 0o $ at-000 ,aOO 12 Sawing bituminous (Full depth) Lin. Ft. 800 $ 1,13S $ 14 to. 0C) 13 Salvage guardrail Lin. Ft. 10 $ .Oa $ 5 (:O.. 00 14 Salvage MH or CB casting Each 22 $ 130.00 $ als(00'00 15 Salvage hydrant Each 1 $ 1900.0c> $ 1g 00.00 16 Salvage bollard Each 2 $ 10p.M $ a)O. 00 17 Common excavation (EV) (P) Cu. Yd. 656 $ 440, ti0 $ 61U.NC1,00 18 Full depth reclamation Sq. Yd. 8572 $ 1,1q $ 94 ,i1, A0 19 Salvage and respread reclaimed material (CV) (P) Cu. Yd. 2693 $ I'a.00 $ 32I3i(D -00 20 Haul & dispose of excess reclaimed material (EV) (P) Cu. Yd. 449 $ ji4,,pp $ 10ya(c .00 21 Bituminous patch special (Driveways) Sq. Yd. 325 $ 5 O, 00 $ t to diSO. CyD 22 Mill bituminous surface (3.0 ") S% Yd. 8572 $ (,,1 S $ rj $ 5'7.'g O 23 Haul millings to Keyes Park (LV) Cu. Yd. 900 $ S'50 $ ` elso. 04o 24 Bituminous material for tack coat Gal 760 $ _3,(E)o $ gzae_00 25 Type SP 9.5 wearing course mixture (3,C) Ton 1500 $ 6th,,, 922 $ [„>! io 26 Type SP 12.5 non wear course mixture (3,B) Ton 1000 $ =9&06 $ 51 000. p O 27 Concrete steps Each 1 $ 1W-ID0- aX:) $ 1 %,000_M 28 12" PVC pipe storm sewer, C900 Lin. Ft 390 $ 4.4-00 $ 1-7 %L-O, 00 29 6" PVC pipe storm sewer, SDR 26 Lin. Ft 40 $ g�3.0C) $ 1 Sao. M 30 Adjust valve box Each 7 $350.400 $ agr2a.00 31 Remove and replace valve box, incl adjustment Each 4 $ ) 3pfl,00 $ 5aoa" cab 32 6" gate valve and box Each 1 $ 1'10X3. fat) $ 14 Go. GU 33 Hydrant Each 1 $ !3M-0. CIO $ 5000.00 34 10 "x6" Tee fitting Each 1 $ 900 00 $ q!w. W 35 10" Coupling Each 1 $ , a, $ LQ=.0 0 36 6" DIP water main, CI -52 Lin. Ft 20 $ c,;, . M $ 1 oaa� Cib 37 10" DIP water main, CI-52 Lin. Ft 5 $ 1ten.00 $ SaID. CIO 38 Furnish and install MH top slab Each 1 $ -1150-1100 $ "750.00 39 Construct drainage structure, design X with casting Each 1 $ 1SC!o-cri, $ 1gC1O.00 40 Casting assembly Each 4 $ %)p. Co $ NCO. O'p 41 Reinstall manhole casting, new hdpe rings, seal Each 10 $ tew. OQ $ 00000,00 42 Reinstall catch basin casting, new concrete rings, seal Each 8 $ (om. no $ k4 sao, w 43 Construct drainage structure over existing pipe w/ casting Each 2 $.R f „p _00 $ to CaO. L7p 44 4" Concrete walk Sq. Ft. 7020 $ %00 $ t031$O.M 45 6" Concrete walk -Special Sq. Ft. 350 $ %.00 $ 10500.00 46 6" Concrete walk ADA Sq. Ft. 530 $ 10.00 $ (03W. 00 47 6" Concrete walk (High early) Sq. Ft. 310 $ 14,Ob $ l43c000 14 No. item Unit uanti Unit Price Amount 48 8" Concrete walk (High early) Sq. Ft. 3800 $ `1t .0t3 $ (001300, W 49 6" Concrete pavement (High early) Sq. Ft. 310 $ 1 p.()o $ 3"Q �] 0t) 50 8" Concrete pavement (High early) Sq. Ft. 2700 $ llo.rsb -a-, $ 4 S 00•>: 51 Concrete curb and gutter Design S512 (high early) Lin. Ft. 2530 $ 2.00 $ :1013 L40. 00 52 Truncated domes Sq. Ft. 188 t $ 4q. 0C) $_C� ! p0 53 Reinstall guardrail Lin. Ft. 10 $ $C1r,0b $50 54 Reinstall bollards Each 2 $ Spe( 5 .00 $ X00.00 55 Traffic control Lump Sum 1 $ V0 $ _ 40 4roc cc 56 Storm drain inlet protection Each 13 -owl $ 150.0 D $ RS0.00 57 Fertilizer Type 3 Pound 45 $ 1, OC) $ 45. oo 58 Sandy clay loam topsoil borrow (LV) Cu. Yd. 75 $ 10.1DO $ SOSO , 00 59 Compost Grade 2 Cu. Yd. 75 $ S, p0 $ IS 15.00 60 Seeding Acre 0.15 $ :?QW.00 $ t- 45Ci.00 61 Seed mixture 25 -131 Pound 35 $ -3. Ob $ (O r. aq 62 Turf establishment Lump Sum 1 $ 500 CC) $ 5- O0, C30 63 Hydraulic mulch matrix Pound 380 $ 3 _Q0 $ 1 NO. 00 64 4" Broken line Epoxy Lin. Ft. 290 $ 0.Io0 _ $ -744-06 65 4" Double solid line Epoxy Lin. Ft. 460 $ 1.90 $ 2.00 66 4" Solid line Epoxy Lin. Ft. 3450 $ 0„ iaQ $ '-;o0,70, EX) 67 6" Solid line Prefomed tape ground in Lin. R. 570 $ 9.%0 $ s11 (o-W 68 12" Solid line Paint Lin. Ft. 230 $ �,�(j $ -7 31P.00 69 24" Solid line Preformed tape ground in Lin. Ft. 75 $. 00 $ W50. Co $ t}aox,, 00 TOTAL BID PROJECT 1705 Common excavation, CV - P (haul to Keyes Park & stockpile) Cu. Yd. $ 1 / j „ 633 � U0 Base Bid Written in Words 0' 2017 CSAH 2 STATE AID STORM SEWER AND STREET IMPROVEMENTS, CH PROJECT 1706 No. Item Unit Quant Unit Price Amount 1 Mobilization Lump Sum 1 $ 00$ (s'.� Ecck 00 2 Clearing Each 2 $ 1000.00 $ 1, O0c'.�. ice' 3 Grubbing Each 2$ a 5O, W$ S C O.00 4 Remove concrete curb and gutter Lin. Ft. 1440 $ 4.00 $ SMoM 0b 5 Remove water main Un. Ft. 30 $ 1 S ,_00 $ 1,.1 So_ Cto 6 Remove hydrant lead including gate valve and box Lin. Ft. 12 $ 15, C0 $ 1 g ©; 00 7 Remove sewer pipe Lin. Ft. 665 $ 1 t®, 00 $ 10, (,r ga OC+ 8 Remove manhole top Lin. Ft. 5.2 $ qC!o. 00 $_ ai 0$0. ar 9 Remove concrete walk Sq. Ft. 6643 $ 1. pp $ q 3 o th 10 Remove concrete driveway /apron Sq. Ft. 1526 $ (, ( C3 $ 1 Le:g. (0 11 Remove concrete street/alley Sq. Ft. 231 $ 1 44c) 12 Remove bituminous pavement, 9" depth Sq. Yd. 3293 $ 13 Remove bituminous driveway Sq. Yd, 140 $ -7.0O $ c113O,00 14 Remove riprap Cu. Yd. 5 $ 5.00 $ r C'& 1"1� . 15 Remove catch basin /manhole Each 17 $ $SO,OrC) $ 17950.00 16 Remove handhole Each 2 $ a00 , 0b $ y 0d. 00 17 Sawing concrete (Full depth) Lin. Ft. 231 $ S , Co j $ , \SS _,bi0 18 Sawing bituminous (Full depth) Lin. Ft. 996 $ i.S5 $ ), as �a.'l� 19 Salvage MH or CB Casting Each 22 $ 1_10.04 $ S too. 00 20 Salvage hydrant Each 1 $ C-70CX :).M .9 $ Z)900-00 21 Abandoned pipe sewer Each 2 $ ( 1 -W $ aD0© -oo 22 Dewatering at pond edge Lump Sum 1 $ 4000. DO $ t}aox,, 00 23 Common excavation, CV - P (haul to Keyes Park & stockpile) Cu. Yd. 2308 $ 1 Q .M $ 24 Common excavation, CV - P (haul & dispose) Cu. Yd. 540 $ ((p QO $ f41 t{Oj p� LN No. Item 25 Subgrade correction, CV ( if needed } 26 Geotextiie fabric (if needed) 27 Select granular borrow 28 Pipe bedding, class 8 29 Granular foundation 3/8" to 1 -1/2" rock 30 Aggregate base class 5, CV 31 Bituminous patch special, 4" depth 32 Bituminous patch special, 3" depth 33 Mill bituminous pavement, 3" depth 34 Mill bituminous pavement, l" depth 35 Bituminous material for tack coat 36 Type SP 12.5 wearing course mixture (3,E) 37 Type SP 12.5 non - wearing course mixture (3,B) 38 18" HP pipe sewer 39 24" HP pipe sewer 40 36" HP pipe sewer 41 36" RC pipe sewer, CL -V 42 install 36" concrete apron with trash guard 43 8" PVC sanitary sewer cleanout 44 Reconnect sanitary sewer service 45 6" PVC pipe sewer, Schedule 40 46 8" PVC pipe sewer, SDR 26 47 6" Gate valve and box, including hydrant valve 48 Hydrant 49 Watermain offset 50 Adjust valve box 51 Reconnect water service 52 6" DIP watermain, CL -52 53 8" DIP watermain, CL -S2 54 3/4" Type K copper pipe 55 Ductile iron fittings 56 Reconstruct sanitary MH top 57 Construct drainage structure, Design C -1 with casting 58 Construct drainage structure, Design E-1 with casting 59 Construct drainage structure, Design X with casting 60 Construct drainage structure, Design Y with casting 61 Construct hydrodynamic separator 62 Casting assembly with HDPE rings (sanitary) 63 Casting assembly with HDPE rings, 24" Dia. (sanitary) 64 Random riprap CI-11 65 4" Concrete walk 66 Concrete walk ADA 67 Concrete curb and gutter Design 8618 68 Concrete curb and gutter Design 5512 69 6" Concrete driveway /apron 70 8" Concrete street/alley 71 8" Concrete crosswalk - Color 72 Truncated domes 73 Traffic control 74 Install handhole 75 Rigid PVC loop detector, 6'x 6' 76 Splice loop detector 77 2/C#14 Loop lead -in 78 Silt fence WWOMCP ebe�% U+., 16 Unit Quant Unit Price Cu. Yd. 1167 $ kp.00 Sq. Yd. 4182 $ U.0 i Ton 268 $ (#,V,00 Ton 745 $ Qa.00) Ton 314 $ %,, OQ Ton 3793 $ ((p.013 Sq. Yd. 100 $ r^f (,, d (+�► Sq. Yd. 140 Sq. Yd. 6082 $ t , 1j 0 Sq. Yd. 1875 $ 1,30 Gallon 865 $ sdic) Ton 1705 3 $ tp /, 00 Ton 350 $ l01 Lin. Ft. 57 $ 3Ip.00 Lin. Ft. 221 $ %4(p,C)() Lin. Ft. 808 $ -70.00 Lin. Ft. 90 $ i S0.00 Each 1 $ Each 2 C1 W. C)O Each 2 $ SOD.C)O Lin. Ft. 40 $ 110.1DO Lin. Ft. 42 $ jam, p0 Each 1 $ 4000,00 Each i $ 5'c" ,00 Each 2 $ aL(00.fiO Each 8 $ --?SCK 00 Each 5 $ 1- 100.00 Lin. Ft. 27 $ S0.00 Lin. Ft. 30. $ gyp, OC ) Lin. Ft. 5o $ 10 C'.OQ Lb 1390 $ a.0(3 Lin. Ft. 8 $ qC 0.00 Each 6 $ 33()0, t20- Each 4 $ :5000.OQ Each i $ (C)00.00 Each X 2 $ 3000.M Each �$ , r $3G -.M Each 10 $ (000.00 Each 1 $ 1OOO.00 Cu. Yd. 5 $ \10.04 Sq. Ft. 6438 $ `$'.50 Sq. Ft. 468 $ (1.00 Lin. Ft. 1181 $ 35; Ct)o Lin. Ft. 308 $ yS.Ot3 Sq. Ft. 1692 $ l LOCO Sq. Ft. 386 $ (;.C)(:) Sq. Ft, 157 $ 90, CC) Sq. Ft. 92 $ ILAcj, C)O Lump sum i $;�p�C o.CX3 Each 2 $ li tOC3.Q0 Each 10 $j Each to $ tp>iy ryp Lin. Ft. 756 $ 1 -00 Lin. Ft. 250 $ '--3,1]j} acrfir ..� 5,0 W (-1.w Amount s IS i• . -- • ;• a" 00 sJa� .00 r v at 00 .r o y , • • • i• ,,� •M •• • ! •ri n• 1000,00 • • +r •• • *o a i :N• #• ,,, • i #a .. nr • _ •♦ •� •• • 1900-00 ♦ r• s • .. . f s w� „ za sa • �a •a i• a .W +• ► # • i� ice• • • No. item Unit Quant Unit Price Amount 79 Storm drain inlet protection Each 10 $ 15o -oc) $ ( Sc70, oD 80 Fertilizer, Type 3 Pound 26 $ 1.00 $ 00 81 Sandy clay loam topsoil borrow (LV) Cu. Yd. 42 $ _75-00 $ -3(50. p� 82 Compost, Grade 2 Cu. Yd. 42 $ QS-00 $ (O SO.QO 83 Seeding Acre 0.08 $ 5000, 00 $ 00.00 84 Seed mixture 25 -131 Pound 20 $ 3. 00 $ (00 , p 85 Landscape rock restoration, 965 40th Avenue Lump sum 1 $ -1Q0, 00 $ -7 p a, 00 86 Turf establishment Lump sum 1 $ $ GID0.06 87 Hydraulic mulch matrix Pound 200 $ 'J =p0 $ (nqp, ca 88 Pavement mssg (Arrow) Preformed tape grin Sq. Ft. 20 $ CiO $ 000, 00 89 Pavement mssg (Lt Arrow) Preformed tape gr in Sq. Ft. 25 $ 50.00 $ a s 0.00 90 Pavement mssg (Rt Arrow) Preformed tape gr in Sq. Ft. 25 $ SO , 00 $ t a 5 O 91 4" Solid line - Epoxy Lin. Ft. 3888 $ o. to O $ :>33 D.80 92 4" Broken line - Epoxy Lin. Ft. 290 $ O . is © $ ( 7 14 , O D 93 4" Double solid line - Epoxy Lin. Ft. 373 $ 1.Q $ W t4 7. (0 0 94 8" Solid line -Epoxy Lin. Ft. 127 $ ,4.90 $ y 95 24" Solid line - Preformed tape gr in Lin. Ft. 60 $ a0.00 $ (3 QQ, 00 96 Crosswalk - Preformed tape gr in Sq. Ft. 486 $ , 60 $ 9 .03 y, 0C) TOTALaBID PROJECT 1706 ,,, , _ _ _ _ . _ _ , . _ �. , $ v �' a, C/ 2'-- e� Base Bid Written i aqw- -4 AA 7(100 ALTERNATE 1- RESIDENTIAL CONSTRUCTION With this alternate, Columbia Heights residents located adjacent to the construction project may purchase driveway or sidewalk construction services at their request at the City bid prices listed below. These purchases are to be a direct private agreement between the resident and contractor. The residents will be entitled to the same service, quality and price as guaranteed in the City bid. No. Item Unit Quanti Unit Price Amount 1 Remove bituminous driveway Sq. Yd. 10 $ 17.013 $ 17 a. 00 2 Remove concrete driveway Sq. Ft 90 $ --770 $ o'00 — 3 Remove concrete sidewalk Sq. Ft. 100 $ 3 -0b $ — qr - 00 4 Remove concrete step Sq. Ft 10 $ Sp. 00 _ $ o0.0t> 5 Aggregate base class 5, CV Cu. Yd. 5 $ j a5. 06 -.,�- $ (05S. 0 d 6 Bituminous driveway Sq. Yd. 10 $ " 5. M $ + ca ©, pp 7 Concrete driveway Sq. Ft. 90 $ x,00 $ 1$00.00 S Concrete sidewalk Sq. Ft 100 $ 1 Q -00 $ l,; jM -0 0 9 Concrete step Sq. Ft. 10 $ U00.00 $ 1 (000 , QO Total Bid Aitemate ALTERNA eductl . o4for Substantial completion date June 1, 2018 s must begin and be completed within the same calendar year TOTAL PROJECT 1705 AND 1706 PLUS ALT. 1 TOTAL PROJECT 1705 AND 1706 PLUS ALT.1 PLUS ALT. 2 17 `t tp5. ibt� $ 0471 f7 - 7Z BID PROPOSAL FORM ADDENDUM 2 - CITY OF COLUMBIA HEIGHTS 2017 STATE Aid STREET REHABILITATION AND SIDEWALK IMPROVEMENTS SAP 113 - 110-010, CH PROJECT 1705 2017 CSAH 2 (40TH AVENUE) STATE AID STORM SEWER AND STREET IMPROVEMENTS SAP 113 -020 -006, SAP 002 - 602 -012, CH PROJECT 1706 JPM HALL PARKING LOT PARTIAL RECONSTRUCTION Unit Price No. Item Unit 1 Mobilization Lump Sum 2 Remove concrete curb Lin. Ft. 3 Remove concrete curb and gutter Lin. Ft. 4 Remove concrete driveway pavement Sq. Ft. 5 Full depth reclamation Sq. Yd. 6 Haul full depth reclamation (LV) Cu. Yd. 7 Bituminous material for tack coat Gat 8 Type SP 9.5 wearing course mixture (2,B) Ton 9 6" Concrete driveway pavement Sq. Ft. 10 Concrete curb Lin. Ft. 11 Concrete curb and gutter Lin. Ft. 12 Storm drain inlet protection Each 13 Fertilizer Type 3 Pound 14 Sandy clay loam topsoil borrow (LV) Cu. Yd. 15 Compost Grade 2 Cu. Yd. 16 Seeding Acre 17 Seed mixture 25 -131 Pound 18 Turf establishment Lump Sum 19 Hydraulic mulch matrix Pound 20 4" Solid line - Paint Lin. Ft. TOTAL JPM HALL PARKING LOT PARTIAL RECONSTRUCTION 46TH AVENUE STREET RECONSTRUCTION No. Item 1 Mobilization 2 Remove concrete curb and gutter 3 Remove concrete sidewalk 4 Remove bituminous pavement, 9" depth 5 Sawing concrete (Full depth) 6 Sawing bituminous (Full depth) 7 Common excavation, CV - P 8 Compaction subcut, CV 9 Geotextile fabric 10 Select granular borrow, CV 11 Aggregate base class 5, CV 12 Bituminous material for tack coat 13 Type SP 9.5 wearing course mixture (2,B) 14 Type SP 12.5 non - wearing course mixture (2,B) 15 6" PVC pipe sewer, Sch 40 16 6" PVC perforated pipe sewer, Sch 40 17 8" PVC storm sewer cleanout, Sch 40 18 4" Concrete walk 19 Concrete curb and gutter Design 8618 20 Traffic control 21 Storm drain inlet protection 22 Fertilizer, Type 3 23 Sandy clay loam topsoil borrow (LV) 17A Unit Lump Sum Lin. Ft. Sq. Ft. Sq. Yd. Lin. Ft. Lin. Ft. Cu. Yd. Cu. Yd. Sq. Yd. Cu. Yd. Cu. Yd. Galion Ton Ton Lin. Ft. Lin. Ft. Each Sq. Ft. Lin. Ft. Lump sum Each Pound Cu. Yd. Quantity Unit Price Amount 1 $ n",- Or--. $ `'ttic-�o.00 120 $ 9. ac, $ lv f3o. acs 46 $ 9.00 $ �f/jV , on 21 $ j .I,oa $ a " -1a0 2,646 $ 5.00 $ /3,a3ry.va 286 $ iy.00 $ ya0-Y 914 $ A., $ /y fyc7`;✓, nn 437 $ OD $ {t�Q,c7O 21 $ 35.coo $��r��. f> 109 $ To .coo $ 5 `7r S'v.s ao 46. $ S -o,coo $ _ 13. c $ car @a 2 $ 15'o,00 $ '3ac> •oo 3 $_ i_crc.) 4 $ . o o $ 4 $ 30.0a $ /C )o • 00 0.01 $ 11'' l?0W oCi $ /[9 fi . c• va 2 $ 3, oo $ 1 $ SOU. C.'o $ S'.'o0. c�c> 25 $ 3,00 $ 7 5 . o c, 1,250 $ a, cats $ ,), roo, o" 4 $ I *p Or? $ CA 11q oo Quantity�9Unit Price Amount 1 $ gj {y 'O . co $ �► t0 , 382 $ -5. Vp $ ft( /O•v >C� 22 $ 0 cs $ r.Yq, a0 789 $ $ 6' ,�0•c5o 6 $- $ 914 $ A., $ /y fyc7`;✓, nn 279 $ $.po $a3 X04 927 $• acs $��r��. f> 577 $ l7, oo $ 1'05 c 261 40 $ 33, vo $3 -4d;' $ _ 13. c $ car @a t 260 $ -7 L)O $ 19,54X), U4 23 $ SO.00 $ �JSO.csa 393 $ c� $ 1 --i� $ 22 $ 35,0o $ 77c1.e>e 382 $ �f $". ©c, $ 77,140. a o 1 $ �?ty o oo $ clt> v G Cn r 4 $ I *p Or? $ o00- OCR 9 $ — )-00 $ 1.00 12 $ tbn,(70 $�.aZ130 dd No. item Unit Quantity 24 Compost, Grade 2 Cu. Yd. 12 25 Seeding Acre 0.03 26 Seed mixture 25 -131 Pound 6 27 Turf establishment Lump sum 1 28 Hydraulic mulch matrix Pound 75 29 4" Solid line - Paint Lin. Ft. 140 30 4" Broken line - Paint Lin. Ft. 60 TOTAL 46TH AVENUE STREET RECONSTRUCTION TOTAL BID ADDENDUM 2 Unit Price Amount 5 k4, C900 .<2(5 $ '30 • o 0 $ 3 . c+c� $ 51'"00• a0 $ $ 3-co S � -hex? $ to I (>O $ _ 3 lc a . 00 $_ Wel lid f3U Total Bid Addendum Written in ords fig BID SUMMARY: TOTAL BID PROJECT 1705 $ State Aid Street Rehabilitation and Sidewalk improvements (From page 15) TOTAL BID PROJECT 1706 $�, CSAH 2 State Aid Storm Sewer and Street Improvements (From page 17) TOTAL BID ALTERNATE 1 $ 7, ®Cs Residential Driveway and Sidewalk Construction {From page 17) TOTAL DEDUCTION ALTERNATE 2 ($ t ,7j ow, W ) Deduction for Substantial completion date June 1, 2018 Project(s) must begin and be completed within the same calendar year (From page 17) TOTAL BID ADDENDUM 2 $ 1PM Hall Parking Lot 46th Avenue Street Reconstruction TOTAL PROJECT $ 17B 5. BIDDER agrees that the Work will be completed as follows: CITY PROJECT NUMBERS 1705 AND 1706 • FULL STREET RECONSTRUCTION • PARTIAL STREET RECONSTRUCTION • STREET MILL AND OVERLAY • SANITARY AND STORM SEWER INSTALLATION/REHABILITATION • WATER MAIN, HYDRANT AND GATE VALVE RELOCATION • CONCRETE CURB AND GUTTER • ADA COMPLIANT PEDESTRIAN RAMPS • CONCRETE SIDEWALK • CONCRETE AND BITUMINOUS SURFACING • MISCELLANEOUS CONSTRUCTION Final inspection by November 22, 2017 in accordance with Paragraph 15.05 of the General Conditions. If Alternate 2 is accepted by the City, final inspection by June 29, 2018 in accordance with Paragraph 15.05 of the General Conditions. BIDDER accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the work on time. 6. The following documents are attached to and made a condition of the BID. (a) Affidavit of Non - Collusion. (b) Responsible Contractor Verification and Certification of Compliance (c) When referenced in the Instruction to Bidders, section 9, include a tabulation of Subcontractors, Suppliers, and other persons and organizations that are required to be identified in the bid. 7. Communications concerning this BID shall be addressed to the address of BIDDER indicated below. 8. The terms used in this BID, which are defined in the General Conditions of the Construction Contract included as part of the Contract Documents, have the meanings assigned to them in the General Conditions. SUBMITTED ON: (Ab — Zw : 2017.. 18 AN INDIVIDUAL By (SEAL) (individual's Name) Doing Business As Address Telephone No A PARTNERSHIP B (SEAL) (Firm Name) Business Address Telephone No. (Continued on next page.) (General Partner) 19 By F -O' (-!T!(y C� .t � r�i`, (SEAL) (Corporation Name) L / AJ—F- 2E6- (State of Incorporation) (Name of Person Authorized to Sign) (Title) In Business Address 11777 O't _ 01' Ut Fr-55-r (M5 M' Q Wiz_` Telephone No.ros'l L4 (, L4' ggpO A JOINT VENTURE By (Name) (Address) By (Name) (Address) Each joint venturer must sign. The manner of signing for each individual, partnership and corporation that is a party to the joint venture should be in the manner indicated above. 20 STATE • •,�!► • COUNTYOF i (1) That I am the BIDDER (if the bidder is an individual), a partner in the BIDDER (if the bidder is a partnership) of an officer or employee of the BIDDER corporation having authority to sign on its behalf (if the BIDDER is a corporation; (2) That the attached bid or bids have been arrived at by the BIDDER individually and have been submitted without collusion with, and without any agreement, understanding or planned common course of action with any vendor of materials, supplies, equipment or services described in the invitation to bid designed to limit individual bidding or competition; (3) That the contents of the bid or bids have not been communicated by the BIDDER, or its employees or agents, to any person not any employee or agent of the BIDDER, or its surety, on any bond furnished with the bid or bids, and will not be communicated to any person, prior to any official opening of the bids, or bids; and; (4) That I have fully informed myself regarding the accuracy of the statements made in this affidavit. NAME kY 21 ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE CONTRACTOR (name and address): Forest Lake Contracting, Inc. 14777 Lake Drive NE Forest Lake, MN 55025 OWN E R (name and address): City of Columbia Heights 637 38th Avenue N.E. Columbia Heights, MN 55421 CONSTRUCTION CONTRACT Effective Date of the Agreement: August 28, 2017 Amount: $1,698,085.52 SURETY (name and address of principal place of business): Western Surety Company 333 S. Wabash Ave. Chicago, IL 60604 Description (name and location): 2017 CSAH 2 State Aid Storm Sewer and Street Improvements - Project 1706, SAP 113 -020 -006, SAP 002 -602 -012, 2017 State Aid Street Rehabilitation and Sidewalk BOND Improvements - Project 1705, SAP 113- 110 -010 Bond Number: 30019853 Date (not earlier than the Effective Date of the Agreement of the Construction Contract): August 31, 2017 Amount: $1,698,085.52 Modifications to this Bond Form: ® None ❑ See Paragraph 16 Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause this Performance Bond to be duly executed by an authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL Forest Lake Contracting, Inc. (seal) Contractor's Name and Corporate Seal Signature SURETY Western Surety Company (seal) Surety's =JS 8y - Signature (attach power of attorney) Notes: (1) Provide supplemental execution by any additional parties, such as joint venturers. (2) Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. HMO C -610, Performance Bond Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 1 of 3 1. The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. 2. If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Paragraph 3. 3. if there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after: 11 The Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor, and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. if the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Paragraph 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor, and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; 3.2 The Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and 3.3 The Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. 4. Failure on the part of the Owner to comply with the notice requirement in Paragraph 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. 5. When the Owner has satisfied the conditions of Paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following actions: 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owners concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor, and with reasonable promptness under the circumstances: 5.4.1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or 5.4.2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. 6. If the Surety does not proceed as provided in Paragraph 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Paragraph 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 7. If the Surety elects to act under Paragraph 5.1, 5.2, or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication for: 7.1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; 7.2 additional legal, design professional, and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Paragraph 5; and 7.3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non - performance of the Contractor. 8. If the Surety elects to act under Paragraph 5.1, 5.3, or 5.4, the Surety's liability is limited to the amount of this Bond. 9. The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors, and assigns. EJCDC® C -610, Performance Bond Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 2 of 3 10. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations. 11. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minimum periods of limitations available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to the Surety, the Owner, or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. 13. When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond, 14. Definitions 14.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made including allowance for the Contractor for any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. 14.2 Construction Contract: The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. 14.3 Contractor Default: Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract, 14.4 Owner Default: Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 14.5 Contract Documents: All the documents that comprise the agreement between the Owner and Contractor. 15. If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 16. Modifications to this Bond are as follows: E1CDC® C -610, Performance Bond Copyright Q 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 3 of 3 ENGINEERS JOINT CONTRACT DOCUMENTS COWAITTEE CONTRACTOR (name and address): SURETY (name and address of principal place of business): Forest Lake Contracting, Inc. Western Surety Company 333 S. Wabash Ave. 14777 Lake Drive NE Chicago, IL 60604 Forest Lake, MN 55025 OWNER (name and address): City of Columbia Heights 637 38th Avenue N.E., Columbia Heights, MN 55421 CONSTRUCTION CONTRACT Effective Date of the Agreement: August 28, 2017 Amount: $1,698,085.52 Description (name and location): 2017 CSAH 2 State Aid Storm Sewer and Street Improvements - Project 1706, SAP 113- 020 -006, SAP 002 - 602 -012, 2017 State Aid Street Rehabilitation and Sidewalk BOND Improvements - Project 1705, SAP 113- 110 -010 Bond Number: 30019853 Date (not earlier than the Effective Date of the Agreement of the Construction Contract): August 31, 2017 Amount: $1,698,085.52 Modifications to this Bond Form: ® None ❑ See Paragraph 18 Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause this Payment Bond to be duly executed by an authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL Forest Lake Contracting, Inc. (seal) Contractor's Name and Corporate Seal By, Signature i V ,, Print Name Signature SURETY Western Surety Company (Seal) Surety's N e a Cor orate Seal By Signature (attach power of attorney) R.C. Bowman Print Name Attorney -in -Fact Title C, Attest: ,i Signature r Surety Account Representative Title Title Notes: (2) Provide supplemental execution by any additional parties, such as joint venturers. (2) Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. E1CDC® C -615, Payment Bond Copyright ® 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 1 of 3 6. If a notice of non - payment required by Paragraph 5.1.1 is 1. The Contractor and Surety, jointly and severally, bind given by the Owner to the Contractor, that is sufficient to themselves, their heirs, executors, administrators, satisfy a Claimant's obligation to furnish a written notice of successors, and assigns to the Owner to pay for labor, non- payment under Paragraph 5.1.1. materials, and equipment furnished for use in the performance of the Construction Contract, which is 7. When a Claimant has satisfied the conditions of Paragraph incorporated herein by reference, subject to the following 5.1 or 5.2, whichever is applicable, the Surety shall terms. promptly and at the Surety's expense take the following actions: 2, if the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies, and holds 7.1 Send an answer to the Claimant, with a copy to the harmless the Owner from claims, demands, liens, or suits Owner, within sixty (60) days after receipt of the by any person or entity seeking payment for labor, Claim, stating the amounts that are undisputed and materials, or equipment furnished for use in the the basis for challenging any amounts that are performance of the Construction Contract, then the Surety disputed; and and the Contractor shall have no obligation under this Bond. 7.2 Pay or arrange for payment of any undisputed amounts. 3. if there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this 7.3 The Surety's failure to discharge its obligations Bond shall arise after the Owner has promptly notified the under Paragraph 7.1 or 7.2 shall not be deemed to Contractor and the Surety (at the address described in constitute a waiver of defenses the Surety or Paragraph 13) of claims, demands, liens, or suits against Contractor may have or acquire as to a Claim, the Owner or the Owner's property by any person or except as to undisputed amounts for which the entity seeking payment for labor, materials, or equipment Surety and Claimant have reached agreement. If, furnished for use in the performance of the Construction however, the Surety fails to discharge its Contract, and tendered defense of such claims, demands, obligations under Paragraph 7.1 or 7.2, the Surety liens, or suits to the Contractor and the Surety, shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to 4. When the Owner has satisfied the conditions in Paragraph recover any sums found to be due and owing to 3, the Surety shall promptly and at the Surety's expense the Claimant. defend, indemnify, and hold harmless the Owner against a duly tendered claim, demand, lien, or suit. 8. The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's 5. The Surety's obligations to a Claimant under this Bond fees provided under Paragraph 73, and the amount of this shall arise after the following: Bond shall be credited for any payments made in good faith by the Surety. 5.1 Claimants who do not have a direct contract with the Contractor, 9. Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance 5.1.1 have furnished a written notice of non- of the Construction Contract and to satisfy claims, if any, payment to the Contractor, stating with under any construction performance bond. By the substantial accuracy the amount claimed Contractor furnishing and the Owner accepting this Bond, and the name of the party to whom the they agree that all funds earned by the Contractor in the materials were, or equipment was, performance of the Construction Contract are dedicated furnished or supplied or for whom the to satisfy obligations of the Contractor and Surety under labor was done or performed, within this Bond, subject to the Owner's priority to use the funds ninety (90) days after having last for the completion of the work, performed labor or last furnished materials or equipment included in the 10. The Surety shall not be liable to the Owner, Claimants, or Claim; and others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be 5.1.2 have sent a Claim to the Surety (at the liable for the payment of any costs or expenses of any address described in Paragraph 13). Claimant under this Bond, and shall have under this Bond no obligation to make payments to or give notice on 5.2 Claimants who are employed by or have a direct behalf of Claimants, or otherwise have any obligations to contract with the Contractor have sent a Claim to Claimants under this Bond. the Surety (at the address described in Paragraph 13). 11. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations. EJCDC® C -615, Payment Bond Copyright O 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of civil Engineers. All rights reserved. 2 of 3 12. No suit or action shall be commenced by a Claimant under 8. The total amount due and unpaid to the this Bond other than in a court of competent jurisdiction in Claimant for labor, materials, or equipment the state in which the project that is the subject of the furnished as of the date of the Claim. Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a 16.2 Claimant: An individual or entity having a direct Claim to the Surety pursuant to Paragraph 5.1.2 or 5.2, or contract with the Contractor or with a (2) on which the last labor or service was performed by subcontractor of the Contractor to furnish labor, anyone or the last materials or equipment were furnished materials, or equipment for use in the performance by anyone under the Construction Contract, whichever of of the Construction Contract. The term Claimant (1) or (2) first occurs. If the provisions of this paragraph also includes any individual or entity that has are void or prohibited by law, the minimum period of rightfully asserted a claim under an applicable limitation available to sureties as a defense in the mechanic's lien or similar statute against the real jurisdiction of the suit shall be applicable. property upon which the Project is located. The intent of this Bond shall be to include without 13. Notice and Claims to the Surety, the Owner, or the limitation in the terms of "labor, materials, or Contractor shall be mailed or delivered to the address equipment" that part of the water, gas, power, shown on the page on which their signature appears. light, heat, oil, gasoline, telephone service, or Actual receipt of notice or Claims, however accomplished, rental equipment used in the Construction shall be sufficient compliance as of the date received. Contract, architectural and engineering services required for performance of the work of the 14. When this Bond has been furnished to comply with a Contractor and the Contractor's subcontractors, statutory or other legal requirement in the location where and all other items for which a mechanic's lien may the construction was to be performed, any provision in be asserted in the jurisdiction where the labor, this Bond conflicting with said statutory or legal materials, or equipment were furnished. requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal 16.3 Construction Contract: The agreement between requirement shall be deemed incorporated herein. When the Owner and Contractor identified on the cover so furnished, the intent is that this Bond shall be construed page, including all Contract Documents and all as a statutory bond and not as a common law bond. changes made to the agreement and the Contract Documents. 15. Upon requests by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. 16. Definitions 16.1 Claim: A written statement by the Claimant including at a minimum: 1. The name of the Claimant; 2. The name of the person for whom the labor was done, or materials or equipment furnished; 3. A copy of the agreement or purchase order pursuant to which labor, materials, or equipment was furnished for use in the performance of the Construction Contract; 4. A brief description of the labor, materials, or equipment furnished; 5. The date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; 6. The total amount earned by the Claimant for labor, materials, or equipment furnished as of the date of the Claim; 7. The total amount of previous payments received by the Claimant; and 16.4 Owner Default: Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 16.5 Contract Documents: All the documents that comprise the agreement between the Owner and Contractor. 17. If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 18. Modifications to this Bond are as follows: EJCDC® C -615, Payment Bond Copyright O 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. 3 of 3 CORPORATE ACKNOWLEDGMENT State of Minnesota ) )Ss County of Anoka ) On this day of / ) °° i ,before me appeared F , to me personally known, who, being by me duly sworn, did say that he /she is the', of Forest Lake Contracting, Inc. , a corporation, that the seal affixed to the foregoing instrument is the corporate seal of said corporation, and that said instrument was executed in behalf of said corporation by authority of its Board of Directors, and that saidf acknowledged said instrument to be the free act and deed Of-said, corporation. CHRISTOPHER MICHAEL BROWN y� Notary Public Minnesota ion Ex Msjqmrv31,2020 State of Minnesota ) )Ss County of Hennepin ) r f 1 Notary Public° �' County, _ My commission expires SURETY ACKNOWLEDGMENT On this 31st day of August 2017 , before me appeared R.C. Bowman , to me personally know, who being by me duly sworn, did say that (s)he is the Attorney -in -Fact of Western Surety Company , a corporation, that the seal affixed to the foregoing instrument is the corporate seal of said corporation and that said instrument was executed in behalf of said corporation by authority of its Board of Directors; and that said R.C. Bowman acknowledged said instrument to be the ,,free,pct and deed of said corporation. l� r Notary Public Hennepin County, Minnesota My commission expires 1/31/2022 � \\ � \ : «: � � z y «< ��:y<� ..»«� � � : , .: � . y� :{ y... .:. :. .w \ ^\ \ \ \ \a \ \^ / \�� \� � � � �� : . . . ,.p � © » +�- � � . .� � � � �� \� \ ® Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint R. Scott Egginton, John E. Tauer, Kurt C. Lundblad, Craig Remick, Jerome T. Ouimet, R. W. Frank, Nicole Stillings, Rachel Thomas, Joshua R. Loftis, Brian J. Oestreich, Melinda C. Blodgett, Sandra M. Doze, Lin Ulven, Ted Jorgensen, R. C. Bowman, Colby D. White, Individually of Minneapolis, MN, its true and lawful Attorney(s) -in -Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 22nd day of August, 2017. r��suaErr�y, WESTERN SURETY COMPANY ArQ'r'RP OAq '-�3.'s Woo r�,y i *`tSfAy %a�: .ysf0li ,�p`. v TM DPK ww,,,,n,N,,, 4aul T. Bruflat, Vice President State of South Dakota ss County of Minnehaha On this 22nd day of August, 2017, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires J. MOHR � SOUTHY P DAKOTA June 23, 2021 90UMDAKOrR J. Mohr, Notary Public CERTIFICATE I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 31 St day of August 2017 . "s"sET. WESTERN SURETY COMPANY tiWep�PP�s91�G, �Jt.s��V gip« Q'rN DAK�,F �aeuuun."'� L. Nelson, Assistant Secretary Form F4280 -7 -2012 Authorizing By -Law ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. AC ' ® CERTIFICATE F LIABILITY INSURANCE DATE(MMIDDlYYYn 18/31/2017 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Cobb Strecker Dunphy & Zimmermann 225 South Sixth Street Suite 1900 CcOOMNEACT Diane O'Leary PNONE 612 -349 -2495 FAX Ngh EMAIL , doleary @csdz.com INSURERS AFFORDING COVERAGE NAIC # Minneapolis MN 55402 INSURERA:Charter Oak Fire Insurance Company 25615 1/1/2017 INSURED FORELAKI INSURER B: Travelers Indemnity Company 25658 Forest Lake Contracting Inc INSURER c: Phoenix Insurance Company 25623 14777 Lake Dr NE MED EXP (Any one person) $10,00_0 Forest Lake, MN 55025 INSURER D: INSURER E: INSURER F PERSONAL & ADV INJURY $1,000,000 COVERAGES CFRTIFICATF Nt1MRFR- 1500951423 RFVISI(IN NIIMRFR- THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, INSR LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER POLICY EFF MMIDD POLICY EXP MMIDDIYYYY LIMBS A X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE ❑ OCCUR DTC09D078188COF17 1/1/2017 1/1/2018 EACH OCCURRENCE $1,000,000 DAMAGE (RENTED PREMISES S Ea occurrence ) $300,0_00 MED EXP (Any one person) $10,00_0 PERSONAL & ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 POLICY �. E LOC PRODUCTS - COMPIOPAGG $2,000,000 $ OTHER: B AUTOMOBILE LIABILITY DT8109DO78188IND17 1/1/2017 111/2018 COMBINED SINGLE-LIMIT Ea accident $ 1,000,000 X BODILY INJURY (Per person) $ ANY AUTO OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY (Per accident) $ HIRED NON -OWNED AUTOS ONLY AUTOS ONLY r PROPERTY DAMAGE Per accident $ X Comp: $2,000 X Coll: $2,000 Hired Auto Phys Dirge $ACV of Vehicle B X UMBRELLA LIAB X OCCUR CUP9H0794441726 111/2017 1/1/2018 EACH OCCURRENCE $10,000,000 AGGREGATE $10,000,000 EXCESSLtA6 CLAIMS -MADE DED X I RETENTION $10,000 $ C WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN DTNUB91307818817 1/1/2017 1/1/2018 X PER OTH- STATUTE ER E.L. EACH ACCIDENT $500,000 ANY PROPRIEfORfPARTNER/EXECUTNE OFFICER/MEMBER EXCLUDED? P N 1 A E.L. DISEASE - EA EMPLOYEE $500,000 (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $500,000 A Property - Blanket -Repl Cost Leases Rented Equipment - ACV Owned Equipment - ACV QT6608A280787COF17 1/112017 1/1/2018 $1,000 Deductible $917,752 Bldg /Cont $1,000 Deductible $500,000 Per Item $1,000 Deductible $2,635,570 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 181, Additional Remarks Schedule, may be attached if more space is required) Project: 2017 State Aid Street Rehabilitation and Sidewalk Improvements - Project 1705, S.A.P. 113 -110 -010 and 2017 CSAH 2 State Aid Storm Sewer and Street Improvements - Project 1706, S.A.P. 113 -020 -006, S.A.P. 002 -602 -012 Additional Insured only if required by written contract with respect to General Liability: City of Columbia Heights and all others as shown in written contract %.Gtt I trILA 1 t nvf -UCrc GANt;tLLA I IUN City of Columbia Heights Public Works Department 637 38th Avenue NE Columbia Heights MN 55421 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIV O 1988 -2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016103) The ACORD name and logo are registered marks of ACORD