Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Contract 2349
7,,r-z7r Owner / Contractor Agreement This agreement is made this 7,/iday of December, 2010, by and between the City of Columbia Heights ("the Owner') and Video Services, Inc. (VSI-the "Contractor"). PART 1- GENERAL 01.01 DESCRIPTION OF WORK: A. The Contractor shall furnish and install all cabling, outlets, terminations and all other equipment necessary for a complete Video Projection System, as described in the Council Chamber Technology Replacement Request For Bid dated October 28, 2010, Addendum 1 dated December 1, 2010, and Request for Information #1 and #2 and responses, hereinafter referred to collectively as "RFB". Total payment for the work as described above shall be $138,141.75 (One hundred thirty- eight thousand one hundred forty-one and 75/100 dollars). Payment of said contract amount shall be made as set forth in the Payment Policy herein. 01.02 PROJECT/SITE CONDITIONS A. VSI will comply with the terms and conditions of the RFB. 01.03 QUALITY ASSURANCE: A. VSI will comply with the terms and conditions of the RFB. B. Training: VSI will comply with the terms and conditions of the RFB. C. Correction period: VSI will comply with the terms and conditions of the RFB. 01.04 PAYMENT POLICY A. Payments: Owner shall pay 70% (seventy percent) of the total contract amount upon delivery of all equipment to City Hall located at 590 40 Avenue N.E., Columbia Heights, Minnesota. Said payment shall be made within 14 (fourteen) days of Owner being invoiced for same. Thereafter, Owner shall pay 15% (fifteen percent) of the total contract amount upon written notification that the work has reached Substantial Completion and is ready for inspection. Said payment shall be made within 14 (fourteen) days of Owner being invoiced for same. Owner shall retain 15% (fifteen percent) of the total contract amount until such time as all Closeout Procedures are completed, as set forth in the RFB. Said retainage shall then be paid by Owner within 14 (fourteen) days of being invoiced for same. B. Changes — VSI will comply with the terms and conditions of the RFB. 0L05 SUBMITTALS, A. Shop Drawings: VSI will comply with the teinis and conditions of the RFB. B. Recorded Drawings: VSI will comply with the terms and conditions of the RFB. C. Technical Manual: VSI will comply with the terms and conditions of the RFB. 01.06 MAINTENANCE SERVICE: A. VSI will comply with the terms and conditions of the RFB. PART 2— PRODUCTS A. VSI will comply with the terms and conditions of the RFB. PART 3— EXECUTION A. VSI will comply with the terms and conditions of the RFB. 03M1 SYSTEM ADJUSTMENT AND TESTS: A. VSI will comply with the terms and conditions of the RFB. PART 4 INSURANCE A. VSI will comply with the terms and conditions of the RFB. In witness whereof, the parties have set their hands this )7 ti.-day of December, 2010. CITY COLU BIA HEIGHTS (Mk' Approve. as 'orm: Gary . Peterson, Mayor Ai 7 Walter R. Fehst, ity anager Jim Hoeft, Cit, A • ey VIDEO SERVICES, INC. Terry Dahl, President Attachments: Request for Bid Bid Addendum 1, Issue Date December 1, 2010 Bid Proposal Request for Information #1 and #2 and Responses Certificates of Insurance Performance Bond Payment Bond CITY OF COLUMBIA HEIGHTS REQUEST FOR BID COUNCIL CHAMBER TECHNOLOGY REPLACEMENT OCTOBER 28, 2010 PREPARED BY: WILL CRAIG, CTS -D CDT KAARIN TAYLOR, CTS ELERT & ASSOCIATES (651) 430 -2772 FAx (651) 430 -2661 WWW.ELERT.COM Columbia Heights Council Chambers Technology RFB SECTION 00 01 10 — TABLE OF CONTENTS SECTION 00 01 10 — TABLE OF CONTENTS 2 SECTION 00 01 15 — LIST OF DRAWINGS 6 SECTION 00 20 00 — INSTRUCTIONS TO BIDDERS 7 PART 1 - DEFINITIONS 7 SECTION 00 31 13 — PRELIMINARY SCHEDULES 16 BID FORM 17 Commencement and Completion of Contract Work 19 Addendum Receipt 19 Signature 19 SECTION 00 70 00 — GENERAL CONDITIONS 20 PART 1 - GENERAL 20 1.01 Governing Clause 20 1.02 Supplementary Conditions 20 PART 2 - PRODUCTS 21 PART 3 - EXECUTION 21 SECTION 27 00 00 — GENERAL TECHNOLOGY REQUIREMENTS 22 PART 1 - GENERAL 22 1.01 Project Summary 22 1.02 Related Documents 22 1.03 Definitions 22 1.04 Reference Standards 22 1.05 Examination of Existing Conditions 25 1.06 Drawing Symbols 26 1.07 Product Storage and Handling Requirements 26 1.08 Contract Modification .Procedures 26 1.09 Owner- Furnished Products 27 1.10 Construction Progress Meetings 27 1.11 Construction .Progress Documentation 27 1.12 Submittal Procedures 28 1.13 Closeout Procedures 28 1.14 Project Management 29 1.15 Quality Assurance 29 1.16 Quality Control 30 PART 2 - PRODUCTS 30 2.01 Basic Equipment and Materials Requirements 30 2.02 Factory- Assembled Products 30 2.03 Racks, Cabinets, Hardware 30 ` Elert & Associates Section 00 01 10— Table of Contents Page 2 Columbia Heights Council Chambers Technology RFB 2.04 Power Devices 31 2.05 Cable and Connectors 31 2.06 Cable Management 32 2.07 Ancillary Hardware 32 2.08 Grounding Hardware 32 2.09 Compatibility of Related Equipment 33 2.10 Spare Parts 33 2.11 Maintenance Manuals 33 PART 3 - EXECUTION 33 3. 01 General 33 3.02 Coordination 34 3.03 Basic Execution Requirements 34 3.04 Preparation 35 3.05 Cleaning 35 3.06 Fire Stopping 36 3.07 Waterproofing 36 3.08 Racks, Cabinets, and Hardware 36 3.09 Grounding 36 3.10 Cable 37 3.11 Connectors 38 3.12 Equipment Installation 38 3.13 Rough -In 39 3.14 Cutting, Drilling, Patching, and Painting 39 3.15 Labeling 39 3.16 Additional Engineering Services 40 PART4 - TESTING 40 4.01 General 40 4.02 Testing 40 4.03 Grounding 41 SECTION 27 40 00 - AV /MULTIMEDIA GENERAL REQUIREMENTS 41 PART 1 - GENERAL 41 1.01 Reference 41 1.02 Scope Summary 41 1.03 Definitions 41 1.04 Reference Standards 41 1.05 Submittals 41 1.06 Correction Period 43 PART 2 - PRODUCT 43 2.01 Product Requirements 43 2.02 Product Specifications 44 2.03 Miscellaneous Material 44 2.04 Cable 44 2.05 Connectors 46 2.06 Interface Panels 47 PART 3 - EXECUTION 48 Elect & Associates Section 00 01 10 - Table of Contents Page 3 Columbia Heights Council Chambers Technology RFB 3.01 Equipment 48 3.02 Interconnection 48 3.03 Cable Management 48 3.04 Connector Termination 49 3.05 Training 49 3.06 Project Closeout 49 PART 4 - TESTING 50 4.01 Testing & Inspection 50 SECTION 27 41 00 — AUDIO VISUAL SYSTEMS 51 PART I - GENERAL 51 1.01 Reference 51 1.02 Scope Summary 51 1.03 Submittals 51 1.04 Correction Period 53 PART2- PRODUCT 53 2.01 Product Specifications 53 2.02 Misc. Parts & Materials 54 2.03 Cable Sleeving: 54 PART 3 - EXECUTION 55 3.01 Equipment Location 55 3.02 Equipment Configuration 55 3.03 Training 56 PART 4 - TESTING 56 4.01 System Testing 56 SECTION 27 47 00 — INTEGRATED CONTROL SYSTEMS 58 PART 1 - GENERAL 58 1.01 Reference 58 1.02 Scope Summary 58 1.03 Aesthetic Requirements 58 1.04 IT Coordination 58 1.05 Ownership 59 1.06 Deliverables 59 1.07 Upgrades 59 PART 2 - PRODUCT 59 2.01 Product Specifications 59 PART 3 - EXECUTION 60 3.01 Equipment Location 60 3.02 Configuration 60 3.03 Shutdown Features 60 PART 4 - TESTING 61 4.01 Testing 61 Elert & Associates Section 00 01 10 — Table of Contents Page 4 Columbia Heights Council Chambers Technology RFB APPENDIX A — EQUIPMENT SCHEDULES AUDIOVISUAL 62 APPENDIX B — EXISTING EQUIPMENT 65 F Elert & Associates Section 00 01 10 — Table of Contents Page 5 Columbia Heights Council Chambers Technology RFB SECTION 00 01 15 - LIST OF DRAWINGS The following drawings are included in the RFB package: T3 -AVO1 10/28/10 T4 -AVO1 10/28/10 T4 -AV02 10/28/10 T4 -AV03 10/28/10 T4 -AVO4 10/28/10 T4 -AV05 10/28/10 T4 -AV06 10/28/10 Elert & Associates Section 00 01 15 — List of Drawings Page 6 Columbia Heights Council Chambers Technology RFB SECTION 00 20 00 - INSTRUCTIONS TO BIDDERS PART 1 - DEFINITIONS 1.01 THE FOLLOWING TERMS MAY BE USED WITHIN THIS DOCUMENT: A. Documents: The complete package of Bid and Contract Requirements, related Division 27 sections, drawings, schedules, and addenda that make up this Request for Bid. B. Work: The provision of products and/or services to meet the requirements specified in these documents. C. Owner: Refers to the City of Columbia Heights. D. Consultant: Refers to Elert & Associates. E. Bidder: A vendor who is submitting a bid for consideration by the Owner and Consultant. F. Contractor: The Bidder selected by the Owner for a contract to complete the Work. G. Notice to Proceed: Written notice provided to the Contractor by Columbia Heights authorizing the Contractor to proceed with the Work and establishing the date for completion of the Work. 1.02 EXAMINATION OF SITE AND DOCUMENTS A. Bidders shall examine all documents, shall visit the site and record their own investigations, and shall inform themselves of all conditions under which the Work is to be performed at the site(s) of the Work, the structure of the ground, the obstacles that may be encountered, all conditions of the documents including superintendence of the Work, the requirements of temporary environmental controls, the time of completion, the list of subcontractors, and all other relevant matters that may affect the Work or the bid process. B. Failure to make the examination shall not result in any change order requests. C. Bidders shall base their bid on materials complying with the plans and specifications, and shall list all materials where the bid foul requires. 1.03 INSURANCE A. The successful Bidder shall purchase and maintain such insurance as will protect it from claims set forth below that may arise out of or result from their operations under the contract, whether the operations be by them, by a subcontractor, or by anyone employed by them. Elert & Associates 00 20 00 — Instructions to Bidders 7 Columbia Heights Council Chambers Technology RFB B. The successful Bidder agrees to indemnify and hold the Owner harmless from any and all claims, demands, damages, actions, or causes of action arising or to arise against the Owner by reason of the successful Bidder's performance of the contract. C. Such insurance shall be acquired for and on behalf of the successful Bidder in protecting them from claims for damages for bodily injuries, including sickness or disease, death, and care and loss of services, as well as from claims for property damages, including loss of use, which may arise from operations under the contract, whether such operations be by the selected Bidder or anyone directly or indirectly employed by them. D. The successful Bidder is required to carry the following insurance coverage and types at a minimum: 1. Comprehensive General Liability: Coverage shall have minimum limits of $1,000,000 each occurrence and $3,000,000 aggregate combined single limit for bodily injury liability and property damage liability. This shall include premises and operations, independent contractors, products and complete operations, contractual liability, and personal injury liability. This shall be maintained for three (3) years after completion of work if this policy is on a claim made basis. 2. Business and Auto Liability: Coverage shall have minimum limits of $500,000 per occurrence and $1,000,000 aggregate combined single limit for bodily injury liability and property damage liability. This shall include owned vehicles, hired and non -owned vehicles, and employee non - ownership. 3. Property Insurance: Coverage shall be all risk and shall be in a broad form basis, including coverage for explosion, collapse, and damage in and around facilities. The coverage also should include off -site and in- transit exposures. 4. Worker's Compensation: a. State: Statutory b. Applicable Federal: Statutory c. Employer's Liability: $100,000 per accident, per employee $1,000,000 disease, policy aggregate $100,000 disease, each employee E. Certificates shall name the Owner as an additional insured on all liability policies. Prior to the start of work, the successful Bidder shall furnish certificates or adequate proof of the foregoing insurance. Certificates furnished by the successful Bidder or their subcontractors shall contain a clause stating, "Owner is to be notified in writing at least thirty (30) days prior Elert & Associates 00 20 00 — Instructions to Bidders 8 Columbia Heights Council Chambers Technology RFB to cancellation of, or any material change in, the policy." Such notice is to be sent to Owner's Purchasing Agent. F. The company providing insurance for the successful Bidder and their subcontractors must be licensed to do business in the State of Minnesota and be acceptable to the Owner. G. The successful Bidder shall be responsible for all losses that fall under any deductibles on required insurance coverage. 1.04 INTERPRETATIONS AND CHANGES BY ADDENDA A. If any Bidder is in doubt as to the meaning of any part of the Plans or Specifications, the contractor may submit a written request to Elert & Associates for an interpretation of that part. It shall be the responsibility of the Bidder to gain a clear and comprehensive understanding of the bid documents requirements. It shall be the responsibility of the Bidder to obtain interpretations or clarifications before submitting a bid. Any interpretation or change will be made only by addendum numbered, dated, and issued to each Bidder on record of receiving a set of bid documents. Neither Elert & Associates nor Owner shall be responsible for any other explanations or interpretations of the documents. B. Questions should be sent to: Will Craig, Elert & Associates will.craig @elert.com C. Questions may not be directed to Owner personnel or any other parties. D. Questions may be submitted only until date listed in Schedules Section 00 31 13. E. Addenda will be sent to Bidders via email. Bidders shall respond to Consultant indicating receipt of addenda document(s). 1.05 PREPARATION OF BID RESPONSE A. The Bidder shall submit the bid on the furnished form. The blank spaces on the response —and the questionnaire that may be attached to the bid —must be filled in correctly with ink or typewriter. Pencil is unacceptable. A bid containing an alteration or erasure of any price contained in the bid, which is used in determining the lowest responsible bid, may be rejected unless the alteration or erasure is corrected as herein provided. B. An alteration or erasure may be crossed out and the correction printed in ink or typewritten adjacent to it and initialed in ink by the person signing the bid. In the event that any price used in determining the lowest responsible bid is expressed in both written and numerical form, the written representation shall govern all cases. ,-" - Elert & Associates 00 20 00 — Instructions to Bidders 9 Columbia Heights Council Chambers Technology RFB C. The Bidder must submit with her/his bid all catalogs, drawings, specifications, descriptive information, and other details of equipment or materials included in their bid but not specifically named by manufacturer and model number in this specification, so that the merits of the various designs may be determined by the Consultant. Failure to comply may be cause for rejection. D. Bid must contain the signature of an authorized agent empowered to bind the Bidder in a contract. 1.06 INCURRING COSTS A. Owner is not liable for any costs incurred with replying to this bid. 1.07 CONSIDERATION OF BIDS A. Owner reserves the right to accept or reject any or all bids or parts of bids and to waive informalities therein. 1.08 CONTRACTOR QUALIFICATIONS A. By submitting Bid, Bidder certifies as to meeting the following requirements: 1. Has completed three or more projects of at least 75% of the size or value to that being proposed. 2. Has access to all necessary equipment and has organizational capacity and technical competence necessary to do Work properly and expeditiously. 3. Maintains a permanent place of business. 4. Maintains a minimum of three (3) full time installers /technicians. 5. Will use employee or sub - contractor certified by Crestron as a Crestron Certified Programmer or Crestron Authorized Independent Programmer to perform programming of Crestron system. Copy of certificate shall be submitted with Bid. 6. Provides sworn financial statement upon request, which evidences that Bidder has adequate financial resources to complete Work, as well as other work Bidder is presently under contract to complete. 7. Is bondable for the terms of the contract. 8. Has a documented safety program with a history of satisfactory past performance. 9. Has a minimum of three like job references from within the last three years. References shall accompany Bid response and shall include job description, point of contact, mailing address, and telephone number. - Elert & Associates 00 20 00 — Instructions to Bidders 10 Columbia Heights Council Chambers Technology RFB 10. Has a record of satisfactorily completing past projects. Criteria that will be considered in determining satisfactory completion of projects by Contractor include: a. Completed contracts in accordance with Contract Documents. b. Diligently pursued execution of the work and completed contracts according to the established time schedule. c. Fulfilled guarantee requirements of Contract Documents. B. Owner will make such investigations as is deemed necessary to determine ability of Bidder to perform Work, and Bidder shall furnish Owner information and data for this purpose at Owner's request. Before award of contract can be approved, Owner shall be satisfied that Bidder meets the above requirements. Owner reserves the right to reject Bid if evidence submitted by, or investigation of, Bidder fails to satisfy Owner that Bidder is responsible and qualified to carry out obligations of contract and to complete Work. 1.09 UNIT PRICES A. In cases where any part of the bid is to be received on the unit price basis, the quantities stated are approximate only, and will be used in making a comparison of bids. Each Bidder will be required to make her/his own estimates of the actual quantities involved and to calculate her /his unit price accordingly. B. Unit prices will be requested in the section(s) where pertinent. In the event the Bid Form does not specifically provide a blank for requested unit prices, the Bidder is instructed to provide the unit price separately along with their bid. C. The unit price may be used to add or deduct quantities of units as represented by the unit price. D. Failure to provide requested unit prices may result in the rejection of the Bidder's bid. E. A bid including unit prices may be rejected if it is found to be unbalanced. 1.10 STATE EXCISE AND USE TAX A. In submitting the bid, the Bidder is understood to have included in the price any applicable County, State or Federal sales, excise, or use tax on all materials, supplies, and equipment that are to be used in the project. 1.11 BID SECURITY A. Each Bid shall be accompanied by a certified check, Bid/Bid bond, or cashier's check in the sum of not less than 5% of the total Bid amount made payable to Owner, conditioned upon the Bidder entering into a contract with Elert & Associates 00 20 00 — Instructions to Bidders 11 Columbia Heights Council Chambers Technology RFB Owner in accordance with the teiuis of their Bid. Any bonding company used must be licensed in the state of Minnesota. B. It is agreed that the Bid/Bid security will constitute liquidated damages, and not a penalty, for the failure of refusal of the successful Bidder to execute and deliver the contractual documents, in a correct form, within ten (10) days after receipt of the contractual documents. C. The Bid and Bid security shall be returned within 30 days after the Bid opening, or in the event of a successful Bid, return shall not be made after the completion of work or after the proper posting of a performance bond. 1.12 PERFORMANCE & PAYMENT BONDS A. The successful Bidder will be required to produce a performance bond and a payment bond in the amount of 100 percent of the Bid award at no additional cost to the owner. The bonds must be furnished within 10 days of award. 1.13 EXCEPTIONS A. Bidders who stipulate in their bid any condition not contained in these specifications and other documents and drawings shall provide written justification for their stipulation on the Exceptions page of the Bid response. 1.14 DOCUMENT SUBMISSION AND DELIVERY A. Bidders shall be submitted in a sealed envelope. One original and two copies shall be provided. B. Bids shall consist of the following, in the following order: 1. Cover Letter 2. Bid Security 3. Bid Form 4. List of Exceptions (if any) 5. Proposed Project Team Qualifications a. Identify the following team members: i. Sales /Management contact (include full contact information) ii. Project Manager (include full contact information) iii. Lead Technician iv. Crestron Programmer v. DSP Programmer vi. Other installers, as applicable Elert & Associates 00 20 00 — Instructions to Bidders 12 Columbia Heights Council Chambers Technology RFB b. Provide brief description of experience of each, noting industry or manufacturer certifications where applicable. c. Indicate which team members, if any, are subcontractors or part-time employees. 6. Programming Certification Certificate(s) a. Project requires either Crestron Certified Programmer or Crestron Independent Authorized Programmer. 7. List of References a. Three similar project references, with contact information. 8. Pricing Summary Page a. Complete provided Appendix A equipment schedules. C. Bids shall be delivered to: City of Columbia Heights Attn: Ms. Linda Magee 590 40` Ave., N.E., Columbia Heights MN 55421 1.15 WITHDRAWAL OF BIDS A. Bidders may withdraw their bid at any time before the time set for the receiving of bids. Notice must be sent via email to all bid recipients. 1.16 BID ACCEPTANCE A. Owner reserves the right to accept or reject any or all bids and waive formalities or irregularities in the process. A bid, once submitted, shall be deemed final and binding on the Bidder, and shall constitute an option with Owner to enter into a contract upon the terms set forth in the bid. All bid prices must be valid for 60 days from bid due date. 1.17 BID AWARD A. Owner reserves the right to award the bid in whole or in part, by item, and/or by group of items where such actions serve the best interests of Owner. Owner reserves the right to award alternates in any order that serves the best interests of Owner. 1.18 CONTRACT NEGOTIATIONS A. Owner reserves the right to negotiate a contract after the successful Contractor is selected. 1.19 COMMENCEMENT AND COMPLETION Elert & Associates 00 20 00 — Instructions to Bidders 13 Columbia Heights Council Chambers Technology RFB A. The successful Bidder must agree to coordinate the work schedule with the General Contractor, Electrical Contractor, and Owner; to commence the work on or before a date to be specified in a written "Notice to Proceed "; and to fully complete all the work per the schedule outlined in Section 00 31 13. Completion time will be converted to a specific date at the time the "Notice to Proceed" is issued. Refer also to General Conditions, the article titled "Time for Completion of the Project." 1.20 COMPLIANCE WITH LAWS /STANDARDS A. The successful Bidder shall comply with all Federal, State, and local laws, statutes, ordinances, rules, and regulations now in effect or hereinafter adopted pertaining to this contract or to the facilities, programs, and staff for which the successful Bidder is responsible. 1.21 INDEMNIFICATION A. Any and all claims that arise or may arise against the successful Bidder or its agents, servants, or employees as a consequence of any act or omission on the part of the successful Bidder or its agents, servants, or employees while engaged in the performance of the contract shall in no way be the obligation or responsibility of the Owner. B. The successful Bidder shall indemnify, hold harmless, and defend the Owner and its officers and employees against any and all liability, loss, costs, damages, expenses, claims, or actions, including attorney's fees that the Owner, its officers, or its employees may hereafter sustain, incur, or be required to pay, arising out of or by reason of any act or omission of the successful Bidder, its agents, servants, or employees, in the execution, performance, or failure to adequately perform the successful Bidder's obligations pursuant to this contract. C. The Owner shall also be indemnified for any attorney's fees it incurs in enforcing this indemnification provision or any other indemnification provision in the contract. 1.22 DEFAULT A. Force Majeure: Neither party shall be held responsible for delay or failure to perform when such delay or failure is due to any of the following, unless the act or occurrence could have been foreseen and reasonable action could have been taken to prevent the delay or failure: fire, flood, epidemic, strikes, wars, acts of God, unusually severe weather, acts of public authorities, or delays or defaults caused by public carriers, provided the defaulting party gives notice as soon as possible to the other party of the inability to perform. B. Inability to Perform: The successful Bidder shall make every reasonable effort to maintain staff, facilities, and equipment to deliver the services to be purchased by the Owner. The successful Bidder shall immediately notify the Elert & Associates 00 20 00 — Instructions to Bidders 14 Cohunbia Heights Council Chambers Technology RFB Owner in writing whenever it is unable to (or reasonably believes it is going to be unable to) provide the agreed upon quality and quantity of services. Upon such notification, the Owner shall determine whether such inability requires a modification or cancellation of this contract. C. Duties to Mitigate: Both parties shall use their best efforts to mitigate any damages that might be suffered by reason of any event - giving rise to a remedy hereunder. 1.23 SAFETY A. The successful Bidder will comply with all State and Federal laws as they relate to employee safety, i.e., AHERA, OSHA, Confined Space Entry, Employee Right to Know, Respiratory Protection, NESHAP, Look -Out Tag Out, etc. B. Contractor(s) is subject to job site safety rules set forth by the Project Manager. 1.24 TOBACCO, ALCOHOL, AND ILLEGAL DRUG POLICY A. Owner's published rules regarding this matter shall apply to all workers related to this project and are available upon request. 1.25 AMERICANS WITH DISABILITIES ACT OF 1990 A. The successful Bidder shall have thorough and complete knowledge of the Americans with Disabilities Act of 1990. The successful Bidder also agrees to provide complete capabilities to meet or exceed all requirements of this Act for this project with regard to the products and services to be supplied by the Bidder e - Elert & Associates 00 20 00 — Instructions to Bidders 15 Columbia Heights Council Chambers Technology RFB SECTION 00 31 13 - PRELIMINARY SCHEDULES Owner reserves the right to adjust schedule. The Contractor shall work closely with other contractors, Owner's project managers and consultants to ensure proper schedule. Mandatory Pre -Bid Meeting: November 16 2010 2:00 PM in the Council Chambers Last Date for Questions: November 30 2010 5:00 PM Last Addendum Issued: December 1 2010 by 12:00 Noon Bids Due: December 6 3:00 PM Project Award /Contract: Excepted by December 15 2010 Pre - construction submittals due: December 31 2010 Installation to Commence: January 3 2011 Substantial Completion: January 14 2011 Punchlist Completion & Closeout Deliverables: Week of January 17 2011 User Training: Week of January 17 2011 First Council Meeting: January 24 2011. Elert & Associates 00 31 13 — Preliminary Schedules 16 Columbia Heights Council Chambers Technology RFB BID FORM To: Columbia Heights We, , a (joint venture) (corporation) (paitnership) (individual) [Cross out inapplicable] of Street City County State Zip Hereby agree to execute the proposed contract and to furnish a satisfactory Surety Bond in the amount specified within ten (10) days of offering, and to provide all labor and material required for the construction of the project designated above, for the prices hereinafter set forth, in strict accordance with the Contract Documents prepared by Elert & Associates, 140 Third Street South, Stillwater, MN 55082 for the City of Columbia Heights and dated October 28, 2010. A. Base Bid Package — Audio Visual Systems (Section 27 00 00, 27 40 00, 27 41 00, 27 47 00 & Subsections thereof) Our total base bid for the work of this project is: DOLLARS ($ ) B. Informational Bid #1 Contractor shall include in Base Bid (above) a trade -in credit (or disposal cost) for the existing equipment named on Appendix B. Indicate the amount of the credit /cost below: DOLLARS ($ ) Check one: this is a credit cost C. Alternates: may be added via addendum. 1. Alternate #1 DOLLARS ($ ) F AElert & Associates DO 31 13 — Preliminary Schedules 17 Columbia Heights Council Chambers Technology RFB 2. Alternate #2 DOLLARS ($ ) 3. Alternate #3 DOLLARS ($ ) Elert & Associates 00 31 13 — Preliminary Schedules 18 Cohumbia Heights Council Chambers Technology RFB COMMENCEMENT AND COMPLETION OF CONTRACT WORK The undersigned agrees, if awarded the contract, to commence the Contract work on or before a date to be specified in a written Notice to Proceed, and to complete the work within the time dictated in the Instructions to Bidders. ADDENDUM RECEIPT We acknowledge receipt of the following Addenda: Addendum No. Date Addendum No. Date Addendum No. Date SIGNATURE Prior to signing, Bidder's attention is directed to the Instructions to Bidders to avoid the possibility of invalidating this bid. By signing this bid form, such action certifies that the Bidder has personal knowledge of the following: A. That said Bidder has examined the drawings and specifications, carefully prepared the bid foiut, and checked the same in detail before submitting said bid; and that said Bidder, or the agents, officers, or employees thereof, have not, either directly or indirectly, entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bid in connection with this Bid. B. That all of said work will be performed at the Bidder's own proper cost and expense and that the Bidder will furnish all necessary materials, labor, tools, machinery, apparatus, and other means of construction in the manner provided in the applicable specifications and at the time dictated in the contract. (Firm Name) (Area Code & Telephone Number) (Seal, if bid is by a corporation) By: (Signature of Bidder) Date: Elert & Associates 00 31 13 — Preliminary Schedules 19 Columbia Heights Council Chambers Technology RFB SECTION 00 70 00 — GENERAL CONDITIONS PART 1 - GENERAL 1.01 GOVERNING CLAUSE A. The Governing General Conditions for the Contract of Construction (AIA Document A201 -1997 edition) shall be hereafter referred to as the "General Conditions." B. AIA Document A201 "General Conditions" are hereby made part of the Contract Documents to the same extend as if reproduced in full, except as modified, amended, revised, rescinded, or supplemented by the Supplementary Conditions. C. The Supplementary Conditions shall take precedence in all cases of conflicting requirements. D. Those portions of the AIA General Conditions that are not altered, modified, amended, or rescinded by the Supplementary Conditions shall remain in full force and effect as published. 1.02 SUPPLEMENTARY CONDITIONS A. The mention in writing or representation by depiction of materials, services, or operations within the specification documents and/or Bid package is binding upon the Contractor to provide and install such items, services, and operations without additional charge to Owner. Exceptions will be noted by the acronym NIC (for Not In Contract) or OFE (Owner Furnished Equipment). If this notation does not appear, then the Contractor shall assume the need to provide the item in question. B. The Contractor will receive no allowances because of omissions in work due to unfamiliarity or their misunderstanding of Bid package details or construction documents. C. The drawings and specifications documents fon,i a part of the contract and shall be considered as bound therewith. D. The submission of bids shall be deemed evidence of the Contractor's knowledge, review, and examination of construction documents, drawings, specifications, and addenda issued for this project. No allowances will be made because of unfamiliarity with any portion. E. A 20% retainage will be withheld from payments until completion of all punchlist items, submission of all closeout materials, and performance of all required training. Elert & Associates Section 00 70 00 — General Conditions 20 Columbia Heights Council Chambers Technology RFB F. Verbal direction will not be considered binding and in no event supersede or amend written documents, specifications, or contract documents. Only written direction will be considered binding on the Contractor, Owner, or Consultant. G. All reference to notifications required of the Contractor to the Owner or to the Consultant must be issued in writing. H. In the event of an inconsistency or discrepancy between parts of the bid package, the Contractor will be bound by the discrepancy clause herein. I. The Contractor has the responsibility for determining the completeness of the bid package contents provided in their specific bid package received. Example: Compare the table of contents against the package contents and look for missing page numbers in bid copy. J. The Bidder agrees not to hold the Owner or Project Consultant responsible for simple typos, minor omissions, misspelling of words, or other specification inconsistencies where reasonable persons, familiar with the type of work specified herein, would understand the scope as though such conditions did not exist. PART 2 - PRODUCTS Not Used PART 3 - EXECUTION Not Used Elert & Associates Section 00 70 00 — General Conditions 21 Columbia Heights Council Chambers Technology RFB SECTION 27 00 00 — GENERAL TECHNOLOGY REQUIREMENTS PART 1 - GENERAL 1.01 PROJECT SUMMARY A. Scope: Successful bidder shall provide, install, configure, and provide warranty service for audiovisual systems, including mounted flat -panel monitors, audio /video /graphics switching and distribution systems, cameras, touchpanel -based integrated control systems, operator control console, loudspeakers, equipment racks, lecterns and other equipment as described herein. 1.02 RELATED DOCUMENTS A. Documents: Provisions of General Conditions, Supplementary Conditions, and the sections included under Bid & Contract Requirements are included as part of this section as though bound herein. 1.03 DEFINITIONS A. Documents: The complete package of Bid and Contract Requirements, General Technology Requirements, related Division 27 sections, drawings, schedules, and addenda that make up this Request for Bid. B. Work: The provision of products and /or services to meet the requirements specified in these documents. C. Owner: Columbia Heights D. Consultant: Elert & Associates. E. NIC: Not in Contract. Item will be the responsibility of others. F. Approved or Approval: Where approval is called for, only persons with the authorized authority may grant approval. Owner reserves all rights to govern over and grant approval and will appoint authority of agents acting on their behalf. G. OFE: Owner Furnished Equipment. Item will be provided and integrated by Owner. H. OFCI: Owner Furnished Contractor Installed. Item will be provided by Owner and installed by Contractor. I. As Required: Contractor shall provide the quantity of said item that is necessary. Owner and Consultant reserve the right to make the final determination of necessary quantities to provide for a complete system. 1.04 REFERENCE STANDARDS Elert & Associates Section 27 00 00 — General Technology Requirements 22 Columbia Heights Council Chambers Technology RFB A. Standards and other procedures referenced by this bid package are as follows: 1. ADA — Americans with Disabilities Act of 1990 U.S. Department of Justice 950 Pennsylvania Ave., NW Civil Rights Division Disability Rights Section — NYAV Washington, DC 20530 Toll Free: (800) 514 -0301 Fax: (202) 307 -1198 2. AIA — American Institute of Architects 1735 New York Avenue. N.W. Washington, DC 20006 Toll free: (800) 242 -3837 Local: (202) 626 -7300 Email: infocentral @aia.org 3. ANSI — American National Standards Institute 1819 L Street, NW 6 Fl. Washington, DC 20036 Phone: (202) 293 -8020 4. ASTM — American Society of Testing and Materials 100 Barr Harbor Drive P.O. Box C700 West Conshohocken, PA 19428 Phone: (610) 832 -9500 5. BICSI — Building Industry Consulting Service International, Inc. (RCDD Standards) 8610 Hidden River Parkway Tampa, FL 33637 Phone: (813) 979 -1991 or 1- 800 - 242 -7405 Fax: (813) 971 -4311 Email: bicsi @bicsi.org 6. CFR — Code of Federal Regulations (Available from the Government Printing Office) 732 N. Capitol Street, NW Washington, DC 20401 Toll Free: (866) 512 -1800 Local: (202) 512 -1800 (Material is usually first published in the Federal Register) 7. EIA — Electronic Industries Alliance 2500 Wilson Blvd. Arlington, VA 22201 Phone: (703) 907 -7500 8. IACS — International Annealed Copper Standard CDA — Copper Development Association 260 Madison Avenue New York, NY 10016 Elert & Associates Section 27 00 00 — General Technology Requirements 23 Columbia Heights Council Chambers Technology RFB Phone: (212) 251 -7200 Fax: (212) 251 -7234 Email: questions @cda.copper.org 9. IEC — International Electrotechnical Commission 3, rue de Varembe P.O. Box 131 CH — 1211 Geneva 20 Switzerland Phone: 41.22.919.02.11 Fax: 41.22.919.03.00 Email: inmain @iec.ch 10. IEEE — Institute of Electrical and Electronics Engineers 3 Park Ave. 17 Fl. New York, NY 10016 Corporate Office: Phone: (212) 419 -7900 Fax: (212) 752 -4929 Standards Activities: Phone: (732) 562 -3800 Fax: (732) 982 -1769 11. ISO — International Organization for Standardization 1, rue Varembe Case Postale 56 CH -1211 Geneva 20 Switzerland Phone: 41.22.749.01.11 Fax: 41.22.733.34.30 12. ITU -T — International Telecommunication Union — Telecommunications Standardization Sector Places des Nations CH -1211 Geneva 20 Switzerland Phone: 41.22.73 0.51.11 Fax: 41.22.733.72.56 Email: tsbmail @itu.int 13. NEC — National Electrical Code (NFPA 70) maintained by NFPA — National Fire Protection Association 1 Batterymarch Park Quincy, MA 02169 Phone: (617) 770 -3000 Fax: (617) 770 -0700 14. NECA — National Electrical Contractors Association 3 Bethesda Metro Center, Suite 1100 Bethesda, MD 20814 -5372 Phone: (301) 657 -3110 Fax: (301) 215 -4500 Elert & Associates Section 27 00 00 — General Technology Requirements 24 Columbia Heights Council Chambers Technology RFB 15. NEMA – National Electrical Manufactures' Association 2101 L Street, N.W., Suite 300 Washington, DC 20037 Toll Free: (800) 321 -6742 Local: (202) 457 -8400 16. OSHA – Occupational Safety and Health Administration (U.S. Department of Labor, OSHA) 200 Constitution Avenue, NW Washington, DC 20210 Phone: (202) 219 -5000 17. TIA – Telecommunications Industry Association 2500 Wilson Blvd., Suite 300 Arlington, VA 22201 Phone: (703) 907 -7700 Fax: (703) 907 -7727 Email: standards @tiacomm.org 18. UL – Underwriters' Laboratories 333 Pfingsten Road Northbrook, IL 60062 -2096 Phone: (847) 272 -8800 Fax: (847) 272 -8129 B. Standards: Referenced standards and /or procedures shall be binding on the Contractor and work shall be judged against such standards and procedures unless otherwise stated in writing. 1.05 EXAMINATION OF EXISTING CONDITIONS A. Examination: Contractor shall examine the facility and construction documents to the extent necessary to plan for efficient installation strategies prior to the delivery of materials to the site or the commencement of work. Failure to adequately complete the examination shall not result in change order requests. B. Acceptance of Conditions: Commencement of work by Contractor shall indicate acceptance of existing conditions, unless a written notice of exceptions has been provided to Owner prior to commencement. C. Observation: If Contractor observes — during preliminary examinations or subsequent work — existing violations of fire stopping, electrical wiring, grounding, or other safety- or code - related issues, Contractor shall report these to Owner in a timely manner. D. Pre - Existing Damage: If Contractor observes damage to finished surfaces before they begin installation in any area, Contractor shall document by taking digital photos of the damaged area(s) and immediately notifying Construction Manager and Consultant via email, with attached photos. Elert & Associates Section 27 00 00 — General Technology Requirements 25 Columbia Heights Council Chambers Technology RFB E. Damage during Installation: Any damage caused by, or reasonably believed by the Construction Manager to be caused by the [AV] Contractor shall result in back - charges for said damages. 1 M6 DRAWING SYMBOLS A. General: Work, equipment, or material delineated on any drawing in this package will be expected to be provided by Contractor unless noted otherwise. B. Interpretation: Work shall be installed in accordance with the intent diagrammatically expressed on the drawings and described in the written specifications. Contractor shall not make limiting interpretation that provides for incomplete work or a non - functioning system. 1.07 PRODUCT STORAGE AND HANDLING REQUIREMENTS A. Storage: Storage of materials shall remain the full responsibility of Contractor until Acceptance. B. Protection: Contractor shall take all necessary precautions to protect materials from the following: 1. Theft 2. Vandalism/Tampering 3. Dents 4. Scratches 5. Dust 6. Temperature 7. Weather 8. Cutting 9. Paint 10. Other hazardous conditions C. Replacement: Contractor shall replace any damaged or lost material as required by Owner or Consultant. D. Installed Materials: Installed materials remain the responsibility of the Contractor until Acceptance. Contractor shall take necessary precautions to ensure the safety and security of installed materials. 1.08 CONTRACT MODIFICATION PROCEDURES A. Changes: Changes to the contract may be initiated by Owner, Consultant or Contractor. Elert & Associates Section 27 00 00 — General Technology Requirements 26 Columbia Heights Council Chambers Technology RFB B. Proposal Request (PR): If a change originates with Owner or Consultant, Consultant shall issue a Proposal Request to Contract. C. Change Proposal (CP): If a change originates with Contractor, or if Contractor receives a Proposal from Consultant, Contractor shall submit a Change Proposal to Consultant to review. D. Cost/Time Changes: A Change Proposal shall reference the work to be performed, and shall include the cost change to the project (if any) and the time change to the scheduled completion (if any). E. Additional Information: Consultant may request additional information to be supplied with the Change Proposal for consideration. F. Acceptance: Owner reserves the right to accept or reject Change Proposals. G. Change Order: A Change order is a modification of the contract: 1. If a Change Order is approved, Owner will issue a Change Order that references PR and/or CP. Change Order is not valid until it has been signed by Owner. 2. Work performed or equipment supplied outside of contract without a valid Change Order is done at Contractor's own risk. 1.09 OWNER - FURNISHED PRODUCTS A. Delivery: Owner is responsible for delivery of Owner - furnished products to the project site, unless otherwise specified in this document. B. Placement: Contractor is responsible for locating, inspecting, and moving Owner - furnished products to their final installation position. C. Inspection: Contractor shall report any damage, discrepancies in quantity, type, or function to Owner and Consultant immediately upon discovery. D. Warranty: Contractor assumes no responsibility for any material warranty for Owner - furnished products. Contractor shall be responsible for integrating, cabling, and installing Owner - furnished products under the same warranty conditions as other products furnished by Contractor. 1.10 CONSTRUCTION PROGRESS MEETINGS A. Attendance: Contractor is required to attend job progress meetings in accordance with requirements set by Owner or Consultant. B. Additional Coordination: Contractor shall request additional job construction coordination meetings it deems to be necessary to ensure coordination of their responsibilities with other parties. 1.11 CONSTRUCTION PROGRESS DOCUMENTATION F A Elert & Associates Section 27 00 00 — General Technology Requirements 27 Columbia Heights Council Chambers Technology RFB A. Completion: Contractor shall complete and submit all construction progress documentation as requested by Owner and Consultant. B. Failure to Complete: Failure to complete requested construction progress documentation may result in the withholding of payment by Owner. 1.12 SUBMITTAL PROCEDURES A. Provision: Contractor shall provide submittals of any corrections or additions to Consultant prior to the procurement of equipment or commencement of work. Blue -line drawings shall be prepared and submitted on 24" x 36" paper. Equipment lists, data sheets, etc., shall be on 8'/2" x 11" paper, punched and inserted in a three -ring binder. B. Prior to Work: Submittals shall be provided to Consultant within ten (10) days after the notice to proceed. Submittals are identified in section(s) following Section 27 00 00. C. Review: Submittals must be received and stamped "Reviewed" by Consultant prior to the procurement of material or the commencement of work. Any procurement or work performed prior to this approval is at Contractor's own risk. D. Project Timeline: Project timeline will not be altered due to lateness of submittals. Contractor will remain bound to deliver a timely, complete, and finished project as stipulated in their contract. E. Failure to Provide: The failure of Contractor to provide submittals as required herein may result in the withholding of payment for work and/or the cancellation of the contract. 1.13 CLOSEOUT PROCEDURES A. Notification: Contractor shall provide written notification to Consultant and Owner when Contractor is satisfied that the work has reached Substantial Completion and is ready for inspection. B. Punch List: Work or materials found to be incomplete, of unsatisfactory quality, failing to meet the specifications in these documents, and/or unacceptable to Consultant or Owner shall be documented by Consultant and provided to Contractor to rectify. Contractor shall provide written notification to Consultant and Owner when all punch list items have been completed. C. Closeout Submittals: Contractor shall provide closeout submittals to Consultant in accordance with the requirements found in these documents. Consultant shall receive the closeout submittals no less than three (3) business days prior to the scheduled Final Inspection. D. Final Inspection: Contractor may be required to be present for the Final Inspection by Consultant. Elert & Associates Section 27 00 00 — General Technology Requirements 28 Columbia Heights Council Chambers Technology RFB E. Re- Inspection: If more than one (1) re- inspection is necessary, the costs of the additional travel, time, and expenses of Owner and Consultant may be deducted by Owner from the contract amount due Contractor. F. Punch List Approval: Punch list shall be considered complete only after having been signed by Owner and Consultant. G. Payment Authorization: Final payment will be authorized only after all closeout procedures and requirements have been followed and fulfilled by Contractor and approved in writing by Owner and Consultant, including punch list(s) and/or re- inspection(s) and delivery of closeout deliverables. 1.14 PROJECT MANAGEMENT A. Project Manager: Contractor shall appoint a Project Manager who will be the main point of contact for Owner and Consultant regarding the project. B. Responsibility: Project Manager is responsible for the following: 1. Successfully completing the contract in a timely manner. 2. Overseeing work and performance of all employees and subcontractors who have been hired by Contractor and ensuring compliance with specification. 3. Completing and submitting required documentation. 4. Attending project coordination meetings as required by Owner, Consultant, and Contractor. Contractor is responsible for taking minutes of these meetings and distributing copies to all participants. 5. Coordinating with Owner, Consultant, Architect, General Contractor, and other contractors involved in the project to ensure smooth flow of work and on -time project completion. 6. Providing a written weekly progress update to the Owner and Consultant. 7. Reporting all unexpected conditions and problems that may result in delay or expense to Owner and Consultant immediately upon discovery. C. Changes: If Contractor seeks to change Project Manager during the course of the project, such change is subject to prior written approval from Owner. 1.15 QUALITY ASSURANCE A. Assurance: It is the intent of these specifications to describe and provide for a complete, professional, and reliable installation. B. Qualifications: Contractor employees who are engaged in installation shall be properly trained in the tasks they are expected to perform. C. Acceptability: Owner shall determine the acceptability of work. Elert & Associates Section 27 00 00 — General Technology Requirements 29 Columbia Heights Council Chambers Technology RFB D. Regulatory Requirements: Contractor shall comply with code requirements that apply to the work being perfoimed. E. Certifications: Where manufacturer certifications are required for warranty or for authorized resale, installation personnel shall have received such certification prior to the start of installation of those manufacturers' materials. 1.16 QUALITY CONTROL A. Installation: During installation period, when connections are made to the Owner's existing infrastructure, Contractor shall use care to ensure that no negative results occur that could reduce or hamper existing systems. PART 2 - PRODUCTS 2.01 BASIC EQUIPMENT AND MATERIALS REQUIREMENTS A. Standards: Equipment and materials used to accomplish the goals of this project shall meet standards for good engineering practice as defined within this document. B. Quality: Products specified in these documents are intended to establish a baseline or operational, functional, and perfoiuiance -based standards that all proposed products must meet or exceed by functionality and quality. 2.02 FACTORY - ASSEMBLED PRODUCTS A. Manufacturer: Reference to specific equipment manufacturers does not imply that all products produced by that manufacturer meet the specification requirements. B. Age of Equipment: Equipment shall be new and unused with full manufacturer's warranties. Contractor shall supplement such warranties as required by the specification. C. No Modification: Where a product is available from a factory/manufacturer to meet the needs as outlined, that product shall be used without modification to ensure the full factory warranty is maintained. D. Like Materials: Like materials used shall be of the same manufacturer, model, and quality unless otherwise specified. E. Software /Firmware: No software or firmware is to be used unless specifically authorized by Owner or its appointed representative. 2.03 RACKS, CABINETS, HARDWARE A. Equipment Racks and Cabinets: Provide racks and cabinets as specified herein and/or described in accompanying documents, appendices, or drawings. Verify that any existing racks and /or cabinets provided by others are g glElert & Associates Section 27 00 00 — General Technology Requirements 30 Columbia Heights Council Chambers Technology RFB complete, bringing any discrepancies to the attention of Owner and Consultant prior to beginning the installation. B. Shelves and Mounts: Contractor shall supply necessary mounting hardware to install rack - mounted equipment. Mounting hardware shall be a product of the manufacturer of the equipment to be mounted, or manufacturer of the rack system, or approved by either for use with their product. Provide supporting channels, shelves, rack mounts, and/or rack ears as recommended by equipment manufacturers. C. Screws and Washers: Contractor shall provide screw head types appropriate to the level of security required for the equipment and racking. Screws shall include polyethylene or nylon washer. 1. Public Access Areas: Star post security screws shall be used for hardware and equipment mounted in equipment racks and consoles in areas that are accessible to the public. 2. Restricted Access Areas: Philips head screws may be used where a secure room entrance or locked rack/console door prevents public access. 2.04 POWER DEVICES A. Power Strips: Unless otherwise specified, power strips shall be UL listed, surface mounted, rated for 15 amp continuous electronic loads. Outlets shall be 125 volt, 15 amp, three -wire, grounded, NEMA 5 -15R. Cords shall be 14/3 SJT with molded plug. B. Power Distribution Panels: Unless otherwise provided, power distribution panels shall be UL listed, rack mounted, rated for 15 amp continuous electronic loads with switch and pilot light. Up to eight outlets shall be mounted to the back, each rated 125 volt, 15 amp, three -wire, grounded, NEMA 5 -15R. Switch and pilot shall be mounted to the front. Cords shall be 14/3 SJT with molded plug. C. Contractor shall provide acceptable power distribution units as required in order to provide power to Contractor- furnished and Owner - furnished equipment indicated on drawings and equipment schedules. This may be in addition to any power distribution equipment indicated on equipment schedules. 2.05 CABLE AND CONNECTORS A. Cable: Cable shall be selected and applied in a manner defined by signal type, consistent with best industry practices. Highest quality products shall be used with attention given to transmission characteristics, teimination methods, resistive and complex impedance at operating frequencies, and insulating material characteristics. Where required by the NEC, substitutions of air handing plenum cable shall exactly match the normally applied product and Elert & Associates Section 27 00 00 — General Technology Requirements 31 Columbia Heights Council Chambers Technology RFB shall meet the standards of UL Standard #900 and the NEC Articles 800 and 820. B. Connectors: Highest quality products shall be used with attention given to transmission characteristics, termination methods, resistive and complex impedance at operating frequencies, and insulating material characteristics. Strain reliefs and cable clamps shall be sized for the connector and the cable. C. Color: Cable and connector color shall be coordinated with Consultant to maintain consistency with cable and connector color schemes used by other trades. 2.06 CABLE MANAGEMENT A. Plastic Cable Ties: Single use white nylon plastic cable ties, appropriate screw fittings, or mounting clips shall be used above ceilings for wire management. B. Velcro Cable Ties: Below ceiling level and within equipment enclosures, Velcro straps shall be used. Velcro straps shall be black, with no logo or decoration, except as authorized by Consultant. 2.07 ANCILLARY HARDWARE A. General: Contractor shall provide ancillary and required accessory items necessary to furnish a complete and fully functional system to Owner. B. Interpretation: Exclusion of or limitation in the language used in the drawings or specifications shall not be interpreted as meaning that ancillary or accessory items of work or equipment necessary to complete or make the installed system fully functional can be omitted. 2.08 GROUNDING HARDWARE A. Mechanical Connectors 1. Material: Mechanical connector bodies shall be manufactured from high strength, high conductivity cast copper alloy material. Bolts, nuts, washers, and lock washers shall be made of Silicon Bronze and supplied as a part of the connector body and shall be of the two bolt type. 2. Split Bolts: Split bolt connector types are not allowed. 3. Standards: Connectors shall meet or exceed UL 467 and be clearly marked with the catalog number, conductor size, and manufacturer. B. Compression Connectors 1. Material: Compression connectors shall be manufactured from pure wrought copper. Conductivity of this material shall be no less than 99% by IACS standards. Elert & Associates Section 27 00 00 — General Technology Requirements 32 Columbia Heights Council Chambers Technology RFB 2. Standards: Connectors shall meet or exceed the performance requirements of IEEE 837, latest revision. 3. Installation: Installation of the connectors shall be made with a compression, tool and die system, as recommended by the manufacturer of the connectors. 4. Labeling: Connectors shall be clearly marked with manufacturer, catalog number, conductor size, and required compression tool settings. 5. Protection: Each connector shall be factory filled with an oxide - inhibiting compound. C. Wire 1. Material: Stranded copper (aluminum not permitted). AWG #3 and AWG #6 2. Feeder and Branch Circuit Equipment Ground: Size as shown on drawings, specifications, or as required by NFPA 70, whichever is larger. Differentiate between normal ground and isolated ground when both are used on the same facility. 2.09 COMPATIBILITY OF RELATED EQUIPMENT A. Existing Equipment: Equipment and systems specified in these documents shall be assumed to be compatible with the systems already installed at Owner site(s) and as identified in this document as related to this project. B. Installed Equipment: Specified equipment and systems shall be compatible with all other equipment and systems as offered by Contractor, thus placing the responsibility on Contractor to ensure proper interaction. 2.10 SPARE PARTS A. Suggested List: Contractor is requested to submit a list of suggested spare parts with an offered price, allowing Owner to select appropriate parts. B. Means of Obtainment: Contractor shall state where spare parts can be obtained after the installation. 2.11 MAINTENANCE MANUALS A. Contractor shall produce a maintenance manual showing interconnection of equipment and any special procedures necessary for proper operation and maintenance of the systems. PART 3 - EXECUTION 3.01 GENERAL F A Elert & Associates Section 27 00 00 — General Technology Requirements 33 Columbia Heights Council Chambers Technology RFB A. Contractor shall provide, furnish, deliver, transport, erect, install, configure, and connect completely all of the material and equipment described herein or depicted on any bid package document or drawing, and shall leave all systems in first -class operating condition. 3.02 COORDINATION A. General: In the event of conflict on space requirements or location of devices, refer the matter to Owner and Consultant for decision. B. Related Work: References to the following related work do not limit or release Contractor from the responsibility of coordination with other trades or from having the necessary knowledge of other non - referenced work. 1. Work by General Contractor. 2. Work by other Technology Contractors. 3. Work by Electrical Contractor C. Delays: Contractor shall coordinate with all other trades to avoid causing delays in the installation schedule. D. AC Power: Contractor shall coordinate with General Contractor its requirements for proper AC power to service all equipment installed by Contractor. E. Low Voltage Sleeving: Contractor shall provide openings through walls as necessary, with sleeving and fire- stopping materials installed in a professional manner to meet local and national codes. F. Grounding: Contractor shall coordinate with General Contractor its requirements for proper ground system to their equipment. G. Surface - Mounted Raceway Coordination 1. General and Electrical Contractors: Contractor shall coordinate with General Contractor and Electrical Contractor the installation of surface - mounted- raceway where not provided but made necessary by non - penetrable wall. 2. Verification: Contractor shall field verify and coordinate the proposed use of surface - mounted raceway at any location with Consultant and Owner. 3.03 BASIC EXECUTION REQUIREMENTS A. General: Contractor is responsible for following industry standards of good practice for telecommunications and networking equipment. B. Aesthetic Factors: With the installation of equipment and cables, consideration shall be given not only to operation efficiency but also to overall aesthetic factors. Contractor shall redo, at no cost to Owner, any work deemed Elert & Associates Section 27 00 00 — General Technology Requirements 34 Columbia Heights Council Chambers Technology RFB by Owner to appear sloppy, hastily done, or unprofessional. Owner shall make final decision over whether work must be redone. C. Manufacturers' Recommendations: Manufactured items, materials, and equipment shall be applied, installed, connected, erected, used, and adjusted as recommended by the manufacturers or as indicated in their published literature unless otherwise noted herein. D. Protection of Work Area: Work shall be properly protected during construction, including the shielding of soft or fragile materials, protecting against dust and dirt, protecting and supporting cable ends off of the floor and from other traffic, protecting floor box lids, and temporarily plugging open conduits during construction. Upon completion, installation shall be thoroughly cleaned and all tools, equipment, obstructions, or debris present as a result of work shall be removed from the premises. E. Waste Materials: Contractor shall keep work area neat, orderly, and free from accumulation of waste materials. Remove trash and debris from the building and job site as required to maintain a clean work environment at all times. Rubbish shall be moved to a common trash point or receptacle on the job site as determined and directed by General Contractor or Owner. F. Ceiling Grid: Contractor shall not hang cable supports from ceiling grid wire. G. Roof Deck: Contractor shall not shoot into the roof deck for mounting cable hangers. H. Mounting: Equipment and enclosures shall be mounted plumb and square in relation to the structure. 3.04 PREPARATION A. Existing Equipment: Prior to any installation, the contractor shall prepare the site by removing any remaining debris, leveling equipment racks (where appropriate), and verifying information and systems stated to be in -place are ready for use. B. Equipment for Installation: Prior to installation, Contractor shall ensure that required major equipment has been secured and is ready for installation. 3.05 CLEANING A. Daily: At the end of each work period or day, Contractor shall remove excess packing, drilling remnants, and other non - equipment related parts, materials, or debris to ensure a clean, safe, and professional working environment. B. Carpet: Contractor shall ensure that no damage to carpeting occurs as a result of their work. Contractor shall cover carpets in areas of work to prevent wire debris from entering the carpet. Elea & Associates Section 27 00 00 — General Technology Requirements 35 Cohumbia Heights Council Chambers Technology RFB 3.06 FIRE STOPPING A. Contractor is responsible for applying fire- stopping material in and around any openings that it creates or are created for it where code or good engineering practice suggests or requires the use of fire stopping material. Contractor shall ensure that all fire- stopping materials meet appropriate codes and are applied according to good engineering practice. 3.07 WATERPROOFING A. Contractor is responsible for creating a waterproof seal in and around any openings to the outside environment that are created by Contractor or for systems being installed. Contractor shall ensure that all waterproof materials meet appropriate codes and are applied according to good engineering practice. 3.08 RACKS, CABINETS, AND HARDWARE A. Racks and Cabinets: Contractor shall assemble and install racks and cabinets. Furnishings shall be placed within the front reach limits for a seated user per instructions from the manufacturer. B. Installation Hardware: Install hardware in a secure manner. Screws shall be tightened to a torque just sufficient to secure equipment without deforming washers beyond their original diameter. C. Considerations: Rack mount equipment shall be secured as recommended by the manufacturer with consideration to airflow, power, and in/out connections. D. Cross Connections: Where cross connections are required between equipment, interconnections shall be installed using cable management technology to secure cables in a neat and orderly fashion, applying best industry practices. 3.09 GROUNDING A, General: Install products in accordance with manufacturer's instructions. Mechanical connections shall be accessible for inspection and maintenance. No insulation shall be installed over mechanical ground connections. Ground connection surfaces shall be cleaned and all connections shall be made so that disconnection or removal is impossible. B. Conduit Bonding: Separate ground wires shall be enclosed in rigid galvanized steel conduit and bonded at both ends to the rigid galvanized steel conduit with an approved fitting. Install conductor in separate rigid conduit. Bond conduit as described above. C. Contractor shall extend #6 green ground wire from AV rack to ground bus in EOC control room, and shall ground individual components as necessary to avoid inference with and from local transmitting and receiving radio systems. E Elert & Associates Section 27 00 00 — General Technology Requirements 36 Columbia Heights Council Chambers Technology RFB 3.10 CABLE A. Cable Treatment: Cable shall be stored and handled to assure that it is not stretched, kinked, crushed, or abraded in any way. Bend radiuses shall meet manufacturer specifications and/or recommendations. Cable should not be installed in ambient temperatures or moisture conditions above or below the rating of the manufacturer. B. Splicing 1. Length: No splices shall be installed in any multimedia /video cable less than five hundred (500) feet in length. 2. Voice and Data Cables: No splices are allowed in any voice or data cables. C. Lengths 1. Variations: Where cables are to be of the same length, variations in the length shall be less than plus or minus 1/2 inch. Lengths of cables are based on the length of the unterminated signal conductors. 2. Labeling: Cables, regardless of length, shall be marked with a labeling scheme approved by Consultant. 3. Grouping: Cables shall be separated into like groups according to signal or power levels. 4. Power Cables: Power cables shall be grouped to one side of the equipment rack while low -level cables to the other side. 5. Equipment Racks: Equipment rack wiring and cabling shall be neatly dressed. 6. Service Loops: Cables shall have service loops. 7. Fastening: Rack cabling shall be adequately supported with Velcro wire wraps and horizontal support cable managers fastened to rack frame. 8. External Wire Support: External wire and cables shall be supported at least every 5 feet from the structure or as required to maintain not more than 12" cable sag between supports and without over tensioning the cables. 9. Support Hardware: Cables shall be supported by J- hooks, cable tray, or ladder rack. 10. Right Angles: Cables are to run at right angles to the structure, placed above ceiling in halls or corridors. 11. Height: Cables shall not run above red iron joist. D. Concealment: Contractor shall make every effort to conceal wiring and other apparatus into walls, floors, and ceilings, assuming code and good engineering Elert & Associates Section 27 00 00 — General Technology Requirements 37 Columbia Heights Council Chambers Technology RFB practice allows and suggests. Cabling systems installed in public areas shall be installed within walls, ceiling, or floors or within surface wiring pathways, as dictated by codes and good engineering practice. E. Cable Ties and Velcro Straps: Ties and straps shall be installed snugly without deforming cable insulation. Ties shall be spaced at uneven intervals not to exceed 4 feet. No sharp burrs should remain where excess length of the cable tie has been cut. F. Obstruction: Contractor shall notify Owner immediately if any obstruction or hazard is discovered in a pathway provided by others. 3.11 CONNECTORS A. Preparation: Cables shall be carefully prepared and connectors installed as directed by the manufacturer. Proper stripping devices and crimping tools shall be used. B. Terminations: Connectors shall be carefully fitted to mating devices on equipment to avoid damage to mating contacts, inserts, or bodies. Specialized terminations shall be made in a neat and secure manner suited to the service of the wire and as directed by the manufacturer. Contractor shall use manufacturer specified terminations when those specifications exist. C. Soldering: A person skilled in that practice shall execute soldered terminations. Any excessive insulation displacement resulting from soldering shall be grounds to require the Contractor to reterminate the connector. D. Adapters: Adapters shall be used only where the identity of the necessary type of connector is unknown at the time of installation, such as for owner - provided equipment or in anticipation of future equipment upgrades, with Consultant's approval. 3.12 EQUIPMENT INSTALLATION A. General: Contractor shall make system properly operational and physically secure by mounting equipment and related accessories into furniture, consoles, and racks as required. Manufacturer's guidelines for installation shall be followed. Discrepancies in installation procedure or inability to complete a given task due to a shortage of materials or malfunctioning equipment shall be reported to Consultant immediately upon discovery. B. Equipment Placement: Contractor shall locate equipment as indicated on drawings and as specified herein. Where such infounation is not provided, follow industry practices and locate operable devices at convenient positions —heat generating devices at the top and seldom - accessed equipment below. Unless otherwise specified, end user - operable devices must be positioned within the range of front wheelchair access per ADA standards. F A & Associates Section 27 00 00 — General Technology Requirements 38 Columbia Heights Council Chambers Technology RFB C. Equipment Installation: Equipment shall be installed as directed by the manufacturer using equipment manufacturer's desktop mounting frames, equipment tubs, installation hardware, and techniques. Contractor shall be responsible for moving equipment from storage and for providing necessary personnel or devices to carry and lift equipment around obstacles and into operating position. 3.13 ROUGH -IN A. Scheduling: Contractor shall make every effort to install systems per this specification in a timely manner including rough -in of cabling and other apparatus where appropriate to stay on schedule. B. Protection of Environment: Where cabling and/or equipment is installed prior to other trades completing their work in an area, Contractor shall take necessary precautions to cover, wrap, or otherwise protect to reduce possible damage due to plastering, painting, cleaning, or other such work. 3.14 CUTTING, DRILLING, PATCHING, AND PAINTING A. Coordination: Contractor is responsible for coordinating the work when any cutting or drilling is required in the performance of installing the specified systems. B, Restoration: Contractor is responsible for returning all surfaces (including walls, floors, and ceilings) to their previous condition after any cutting. 3,15 LABELING A. General: Rack - mounted equipment and hardware shall be labeled as required herein. Connectors, jacks, receptacles, outlets, cables, cable terminations, terminal blocks, rack mounted equipment, active slots of card frame systems, etc. shall be clearly, logically, and permanently labeled in a manner acceptable to Consultant. B. Approval: Proposed wording and/or numbering schemes for labeling must be provided to Consultant for review and written approval prior to procurement or installation. C. Labels used must be permanent and secure. Provide labeling as follows unless otherwise noted in a specific section: 1. Like Size: Labels shall be sized to match other labels used for same purpose. Similarly, provide engraved labels of like size in other locations. 2. Equipment Racks: For enclosed racks containing equipment, provide labels on each equipment rack rear door or console rear panel reading "No user serviceable parts. Refer service to qualified technician." F A Elert & Associates Section 27 00 00 — General Technology Requirements 39 Columbia Heights Council Chambers Technology RFB 3. Installer and Consultant Identification: Position at the front top center section of each equipment rack a label that states the names of system Installer and Consultant. 4. Custom Panels: Custom panel nomenclature shall be engraved, etched, or screened. Markings are to be designed to ensure consistency and clarity within and without of system. Verify markings and placements by submitting label sample layouts to Consultant for approval prior to procurement. 5. Documentation: Labeling information shall appear on the as -built drawings. 3.16 ADDITIONAL ENGINEERING SERVICES A. General: Contractor is responsible for securing necessary engineering services where needed to meet the needs of the installation. B. Change Orders: Only when Contractor can show that additional engineering services are needed as a result of changes to the scope of the services being requested will Owner entertain a Change Order for these services. PART 4 - TESTING 4.01 GENERAL A. Supplies: Contractor shall supply testing equipment needed to verify compliance with specifications found in these documents. B. Program: Contractor shall complete required testing prior to the inspection by Owner and Consultant. C. Data: Test data shall be properly documented and recorded so that it is available for final inspection. D. Quality Control: Testing may be repeated during the inspection process at the request of Owner or Consultant. 4.02 TESTING A. Prior to energizing or testing the system, ensure the following: 1. Installation: Products are installed in a proper and safe manner per the manufacturer's instructions. 2. Cleanliness: Products are neat, clean, and unmarred and parts securely attached. Dust, debris, solder, splatter, etc., is removed. 3. Cables and Connections: Cable is dressed, routed, and labeled; connections are consistent with regard to polarity. 4. Grounding: Electronic devices are properly grounded. Elert & Associates Section 27 00 00 — General Technology Requirements 40 Columbia Heights Council Chambers Technology RFB 5. AC Power: Each AC power receptacle is tested with a circuit checker for proper hot, neutral, and ground connections prior to plugging in equipment. 4.03 GROUNDING A. General: Inspect grounding and bonding system conductors and connections for tightness and proper installation. Use suitable test instrument to measure resistance to ground of system SECTION 27 40 00 - AV /MULTIMEDIA GENERAL REQUIREMENTS PART 1 - GENERAL 1.01 REFERENCE A. Provisions of Section 27 00 00 and Construction Documents are included as a part of this section as though bound herein. 1.02 SCOPE SUMMARY A. This section contains general requirements for AV /Multimedia technology provision, installation, configuration, and documentation. Requirements apply to all following sections unless specifically noted. 1.03 DEFINITIONS A. XGA: Referring to extended Graphics Array, or a resolution of 1024x768 pixels, or a high - density 15 -pin D connector used for analog computer graphics. 1.04 REFERENCE STANDARDS A. As listed in Section 27 00 00. B. Giddings, G. H. Philip. Audio Systems — Design and Installation. Focal Press, 1990. Focal Press, Elsevier Inc. 30 Corporate Drive, Suite 400 Burlington, MA 01803 Phone: (781) 221 -2212 Fax: (781) 221 -1615 C. AV Installation Handbook. InfoComm International, 2007. 11242 Waples Mill Road, Ste. 200 Fairfax, VA 22030 Phone: (703) 273 -7200 Fax: 703 - 278 -8082 1.05 SUBMITTALS F „9 Elert & Associates Section 27 00 00 — General Technology Requirements 41 Columbia Heights Council Chambers Technology RFB A. General Information: As required by Section 27 00 00. B. There are three types of submittals required: 1. Preconstruction Submittals, including shop drawings. 2. Progress Submittals, including progress reports, work plans, and completion schedules. 3. Closeout Submittals, including as -built drawings, equipment manuals, quick reference guides, and custom software programming /configurations. C. Preconstruction Submittals: Submittals shall show the following: 1. Block Diagrams: Interconnection diagrams, including cable identification detail, notes to installers, and specific input/output port identification. 2. Mounted Elements: Structurally mounted elements, generally including monitors, and loudspeakers. This shall include both plan view of placement, as well as detail of structural mounting techniques to be used. 3. Identification: Layout and labeling /engraving of custom products, including wall plates and interconnection panels. 4. Furniture: Scale drawings of custom furniture and sample of finished surfaces for Consultant approval. 5. Cable: Make and model of bulk cable and connectors, cable labels and connector detail. 6. Changes: Proposed changes to block diagrams and elevations provided with the bid documents. Required changes are detailed in Section(s) to follow. D. Progress Submittals: Submittals shall include the following: 1. Weekly Report: Weekly written report to be submitted to Consultant via email by 5 PM each Monday, outlining progress from previous week, plans for progress in the current week, and any coordination issues that may require Consultant or Owner attention. E. Closeout Submittals: Shall include 1. Binders: A complete set of equipment manuals shall be kept and organized in 3 -ring binder(s) for each room system. 2. Quick Reference: Contractor shall write a quick- reference guide covering normal system operation and basic troubleshooting procedures for each room. Guide shall be a minimum of 1 page, front and back (may include pictures /illustrations). Subject to Consultant review /approval at least 3 days prior to final submittal. Elert & Associates Section 27 40 00 —AV /Multimedia General Requirements 42 Columbia Heights Council Chambers Technology RFB 3. Serial Numbers: Contractor shall also include a list of serial numbers for all supplied components which have serial numbers and a unit price more than $99.00. These will be provided on a per -room and per- system basis. F. As -Built Drawings: Contractor shall compile a set of as -built drawings, with all changes clearly marked in red. G. Additional Submittals: Contractor shall supply additional submittals, as required by subsequent sections. 1.06 CORRECTION PERIOD A. Length of Period: Contractor shall offer a one year correction period to Owner for this system. Contractor shall repair all equipment and cabling problems at no additional cost to Owner during the correction period. B. Commencement: Correction period shall begin at date of Final Acceptance. C. Final Acceptance: shall be defined as the date at which all contract work (save for a correction period) is complete, including punchlist completion & verification, closeout submittals, and written verification by the Owner is obtained by the Contractor that the systems have been accepted. D. Response: Contractor shall respond by phone within 4 hours to calls for service or assistance from Owner during normal business hours for the duration of the correction period. E. On -site Response: Contractor shall respond on -site within 8 business hours from the time of the initial phone contact in the event that the issue cannot be resolved over the phone. F. Equipment on Loan: Contractor shall loan equipment for any broken, defective, or non - functional equipment that cannot be repaired and returned within one week. Contractor shall provide shipping, delivery, and integration at no additional cost to Owner. Equipment shall be comparable in size, speed, brightness, and relevant performance specifications, as determined by Owner. G. Projection Lamps: Projection lamps are to be warranted by Contractor for a minimum of 90 days, or the rated life expectancy of the lamp, whichever comes first. H. Damaged Equipment: Equipment that is damaged due to intentional misuse, abuse or negligence is not covered under this warranty; however, Contractor shall assist Owner in putting the system back in working order in the shortest possible timeframe while charging normal service rates for labor and equipment. PART 2 - PRODUCT 2.01 PRODUCT REQUIREMENTS F-'- Elert & Associates Section 27 40 00 — AV /Multimedia General Requirements 43 Columbia Heights Council Chambers Technology RFB A. Substitutions: Contractor may propose substitutions during the bid process. B. Substitution Approval: Consultant and Owner reserve the right to govern over and determine whether proposed substitutions are equal to the product(s) named in the specifications. 2.02 PRODUCT SPECIFICATIONS A. Provisions: Product specifications are provided in subsequent sections to Contractor for the appropriate configuration and/or provision of accessories as well as for a guide to indicate key features for possible substitutions. B. Substitutions for Non - specified Products: Where no product specification is provided, Contractor may use manufacturer's specification for the identified product as a guide for suggesting appropriate substitutions. Substitutions are subject to prior approval by Consultant. C. Deviation: Products provided or installed that deviate from the products named herein in make, model, color, or other significant characteristic (i.e., non - approved substitutions) shall be removed and replaced with specified products at no additional expense to Owner. 2.03 MISCELLANEOUS MATERIAL A. Required Equipment: Contractor shall provide additional system components typically and reasonably required to make system operational even though not specifically indicated in Drawings, Appendices or Specifications including, but not limited to, cable, connectors, connecting accessories, adaptors, power supplies, power strips, rack mounting adapters and shelves, cover plates and closure panels, relays and switches, remote antenna mounts, terminal blocks, and related connector and termination hardware required by but not supplied with the equipment. B. Blank Fill Panels: Contractor shall provide blank fill panels to cover any openings in equipment racks. Fill panels shall match finish of specified rack hardware. C. Power Distribution Strips: Contractor shall provide power distribution strips as necessary for distributing power within equipment racks and consoles. Strips shall be UL listed, be securely mountable, and appropriate for professional installation. 2.04 CABLE A. Cable shall be provided and installed as detailed herein. Cable installed that does not conform to these standards or that has not been given prior approval by Consultant shall be removed by Contractor and replaced at Contractor's sole expense. Elert & Associates Section 27 40 00 —AV /Multimedia General Requirements 44 Columbia Heights Council Chambers Technology RFB B. Installed Video: Video signal coaxial cables shall have #18 solid copper center conductor, gas- injected high density Polyethylene or Fluorinated Ethylene Propylene insulation, copper braid shield of at least 95% coverage and 100% dual -sided foil and black PVC jacket unless color is otherwise noted. Cable shall be designed as a low loss serial digital video cable. Belden 1694A, WestPenn 6350, Canare L -5CFB, Liberty 18- CMR -SD, or equal. Plenum cable, Belden 1695A, WestPenn 256350, Liberty 18- CMP -VID- COAX, or equal. C. Flexible Video: Short video cables that are intended to be moved or adjusted on a regular, frequent basis may be constructed of a stranded bare copper center conductor RG -59 /equivalent cable with >94% copper braid shield and polyethylene dielectric. Canare LV-61S, Belden 1505A, WestPenn 819, or equal. Plenum cable, Belden 1506A, WestPenn 25819, or equal. D. High Resolution RGBHV Graphics/Video: Cable type and size shall be selected to provide a minimum of 250 MHz bandwidth ( -3dB) at over the length of each RGBHV signal path from source to display, including losses and gains through cable loss, signal processing, switching and distribution equipment. Manufacturer shall designate cable as suitable for high- resolution use. Extron MHR -5, Liberty RGB5C-CM or equal. Plenum cable, Extron MHR -5P, Liberty RGB5C- 25 -CMP, or equal. E. Installed Line Level and Microphone (single line): Audio signal cable shall have twisted pair #22 stranded tinned copper conductors, polyethylene conductor insulation, aluminum - polyester foil shield, #24 stranded tinned copper drain wire and chrome PVC jacket. Belden 8761, West Penn 291, Canare L -2T2S, Liberty 24 -2P -STAR, or equal. Plenum cable, Belden 88761 or equal. F. Portable Microphone, Exposed, Inter - Enclosure, and Breakout Line Level Audio: Cable shall have 4 conductors per channel arranged in star quad double- balanced pairing, #24 stranded conductors of at least 40 tinned annealed copper wires, 100% coverage wrap shield, tinned copper braid shield of approximately 50% coverage, uniformly round form and black PVC jacket. Canare L -4E6S, Belden 8723, WestPenn 355, or equal. Plenum Cable, Belden 88723, Liberty 24- 4P- PLCSH -WHT, or equal. G. Broadband Video Antenna Cable: For runs shorter than 15', RG -59. For runs 15' -50', RG -6. H. Wireless Antenna Extension Cable: 75 -Ohm or 50 -Ohm coaxial cable, as directed by microphone manufacturer. I. Loudspeaker Wire: 14 AWG minimum for runs over 50', 16 AWG minimum for runs under 50'. J. UTP Cable: Shall be consistent with Owner standards for UTP cable, unless otherwise noted in specification or recommended by hardware manufacturer Elert & Associates Section 27 40 00 —AV /Multimedia General Requirements 45 Columbia Heights Council Chambers Technology RFB for use with their equipment (example: Extron UTP23SF -4P for Extron UTP transmitters). K. Control: Shall be as recommended by equipment manufacturer, with the appropriate number of conductors for the application. L. Cable Construction: Contractor shall fabricate interconnecting cables using products defined in this section unless equipment manufacturer - provided cable is of a specialized or proprietary nature. Pre - manufactured cables are subject to prior approval by Consultant. M. Labels: Labels shall include a white paper or vinyl slip with typed or machine printed designations, secured in place with a wider section of clear heat shrink tubing or integral clear adhesive- backed plastic. N. Terminations: Provide specialized terminating hardware as required. 0. Schedule: Contractor shall submit schedule prior to installation for Consultant review indicating cable types that will be used on the project. 2.05 CONNECTORS A. Connectors shall be provided and installed as detailed herein. Connectors installed that do not confoim to these standards or that have not been given prior approval by Consultant shall be removed by Contractor and replaced at Contractor's sole expense. B. BNC (Video): Video signal BNC connectors shall be 3 -piece crimp -on type with insertion barrel and ferrule, and gold flashed crimp -on center pin. Barrel shall provide full circumferential contact with the braid. Fittings shall be sized to fit the cable. Canare BCP -C series or equal. Crimping and die tools shall be Canare TC -1 Hand Crimp Tool with appropriate TCD die sets or equal. C. RCA (Video): Video signal RCA connectors shall be 3 -piece crimp -on type with gold flashed center pin, Canare RCAP -C series or equal. Crimping and die tools shall be Canare TC -1 Hand Crimp Tool with appropriate TCD die sets or equal. D. F (Video): Video signal F connectors shall be 3 -piece crimp -on type with gold flashed crimp -on center pin. Canare FP -C series or equal. Crimping and die tools shall be Canare TC -1 Hand Crimp Tool with appropriate TCD die sets or equal E. BNC (RGBHV Graphics): Graphics signal BNC connector shall be crimp -on type with insertion barrel and ferrule, and gold flashed crimp -on center pin. Barrel shall provide full circumferential contact with the braid. Fittings shall be sized to fit the cable. BNC manufacturer, model and tools as recommended by the manufacturer of the RGBHV /graphics cable. Elert & Associates Section 27 40 00 — AV /Multimedia General Requirements 46 Columbia Heights Council Chambers Technology RFB F. XLR: Strain relief shall be sized to fit the cable. Connector shell shall be isolated from all contacts. Neutrik Inline: NC3FX, NC3MX or equal, Panel mount: Neutrik NC3FBV or NC3MBV. G. Mini -XLR: Strain relief shall be sized to fit the cable. Connector shell shall be isolated from all contacts. Switchcraft or equivalent. H. Phono (RCA): Phono /RCA connectors shall have gold contact and solid center pin with metal strain relief. Canare F -10 or Canare F -09 or equal. I. Phone (1/4 inch): Reinforced one -piece body shall have brass bar running length of handle. Canare F -15 (TS) or Canare F -16 (TRS) or equal. J. Mini (1/8 inch): Shall be Canare F -11 (TS) or Canare F -12 (TRS) or equal. K. DM: Shall be Crestron shielded RJ -45 and fiber connectors, as recommended by manufacturer of DM system. L. Schedule: Contractor shall submit schedule prior to installation for Consultant review indicating connectors that will be used on the project. 2.06 INTERFACE PANELS A. Finish: Interface plates and connector panels shall be as indicated on Drawings and as specified herein. Finish on custom wall interface plates shall match that of electrical and other work and shall be coordinated with Consultant prior to ordering. Connector panels in equipment racks shall match finish of rack frame and specified/provided blank panels unless called out otherwise in equipment schedules. B. Floor Boxes: Contractor shall provided floor box plates wherever connectivity through a floor box is indicated on drawings. C. Labels: Interface plates and connector panels shall be engraved to show connector functionality. Engravings shall be finished with a contrasting color to plate finish. Verify engraving detail in preconstruction submittal prior to fabrication. D. Connector Placement: Verify connector layout detail for custom panels in Preconstruction submittal prior to fabrication. E. Cut -ins: Where no box is provided, Contractor shall cut in appropriate opening for plate, and provide appropriately sized mud - ring /caddy to securely attach plate to wall. F. Rack Blank Panels: Contractor shall provide and install all blank rack panels necessary to fill openings in the front of AV equipment racks, whether specified in the equipment schedules or not. Elert & Associates Section 27 40 00 —AV /Multimedia General Requirements 47 Columbia Heights Council Chambers Technology RFB PART 3 - EXECUTION 3.01 EQUIPMENT A. As required by Section 27 00 00. 1. Safety: Contractor shall use proper structural installation techniques and maintain a minimum 5:1 safety margin. 2. Custom Mounting Finish: Custom mounting hardware shall be painted by Contractor to match either color of wall, ceiling or equipment, at Consultant's discretion. 3.02 INTERCONNECTION A. As required by Section 27 00 00. 1. Interpretation: Contractor shall make system interconnections as indicated on Drawings and specified herein. Contractor shall interpret Drawings using an understanding of the equipment and general system topology (both existing and future /specified). Contractor shall provide power and control lines to and from power supplies, remotely controlled equipment and other devices even though not explicitly indicated on Drawings or listed in equipment tables. 2. Additional: Contractor shall be responsible for associated equipment signals not specifically documented in provided drawings. These include synchronizing signals, transmitting and receiving antennas, and LAN connections to equipment provided and/or installed by Contractor. 3. Exceptions: Contractor shall not be responsible for unrelated low voltage wiring such as data and voice connections except as they pertain to interface boxes, interface plates, and integrated control systems. 3.03 CABLE MANAGEMENT A. As required by Section 27 00 00. 1. Above Ceiling: Cabling located above ceilings shall be tied off to and supported by ceiling supports or other structures at a minimum of eighteen (18) inches above the ceiling. 2. Not on Ceiling: Cabling shall not lie on the ceiling. 3. Wall Cabling: Cables installed in a horizontal fashion along wall surfaces shall be installed in surface raceway approved by Owner and Consultant. 4. Floor Cabling: Cabling placed at floor level such as microphones shall be installed on the floor in the shortest possible route to the nearest wall considering traffic patterns and in an enclosure designed for that use and offering protection from foot traffic. Elert & Associates Section 27 40 00 —AU /Multimedia General Requirements 48 Columbia Heights Council Chambers Technology RFB 5. Desk Cabling: Where a cable is installed inside desk furniture, a means of protecting the cables and holding cabling to a fixed surface shall be installed. 6. Grommets: Holes in horizontal furniture surfaces for cable pass - through shall be provided with appropriate sized grommet. Grommet shall be black unless otherwise specified or required. 7. Stub -ups: Where conduit is stubbed -up through the floor and exposed, Contractor shall wrap cables with black expandable sleeving and secure at least 3" below level of conduit top. 3.04 CONNECTOR TERMINATION A. As required by Section 27 00 00. 1. Video Connectors: Video connectors (BNC, RCA, and F) shall be terminated using a crimp tool or dies designed specifically for the connectors being applied. 2. XLR Connectors: Terminate XLR type connectors wired pin 2 high, pin 3 low, and pin 1 shield. 3. UTP: UTP cable shall be terminated with crimps tools or tools specified by manufacturer. 3.05 TRAINING A. General Information: As required by Section 27 00 00 and following section(s). B. Coordination and Personnel: Training shall be coordinated with Owner's schedule, and Contractor personnel who provide training are subject to Owner's approval. 3.06 PROJECT CLOSEOUT A. Completion: System shall be considered complete when all of the following has occurred: 1. Testing has been completed to the satisfaction of Owner and Consultant. 2. Punch- listed items have been addressed to the satisfaction of Owner. 3. As -built drawings and system documentation has been turned over to Owner and Consultant. 4. Complete operational training has been conducted with Owner's staff. B. Acceptance: Contractor shall secure written Acceptance of systems in the form of authorized Owner signature on Acceptance Document. This shall constitute the date of Acceptance. Elert & Associates Section 27 40 00 —AU /Multimedia General Requirements 49 Columbia Heights Council Chambers Technology RFB PART 4 - TESTING 4.01 TESTING & INSPECTION A. General Information: As required by Section 27 00 00. B. Notification: Prior to start of testing, provide a list to Consultant of test equipment make, model numbers and calibration dates that will be used. C. Testing: Contractor shall perform complete testing on system before inspection. Selected systems may be retested during inspection at Owner's discretion. D. Display /Output checks: Contractor shall verify that visual and audio outputs from the system are high - quality and without noticeable distortion or feedback at normal operating levels. E. Wiring and Labeling: Contractor shall check all inputs and outputs for correct wiring and labeling. F. Computer Graphics: Computer graphics shall be crisp and focused with respect to color alignment. If color alignment is not registered properly, Contractor shall identify source of problem and correct. Elert & Associates Section 27 40 00— AV/Multimedia General Requirements 50 Columbia Heights Council Chambers Technology RFB SECTION 27 41 00 — AUDIO VISUAL SYSTEMS PART 1 - GENERAL 1.01 REFERENCE A. The provisions of Sections 27 00 00, 27 40 00, Construction Documents, drawings and appendices are included as a part of this section as though bound herein. 1.02 SCOPE SUMMARY A. General: Provide, install, configure, train, and service for audio visual systems. B. Demolition: Contractor shall be responsible for removal of existing AV systems and wiring from chambers and control room. Contractor shall be responsible for restoring original surfaces where damage is caused by demolition. C. Disposal: Contractor shall remove equipment identified on Appendix B, as well as demolished cabling and related hardware, and provide Owner with a trade -in credit (or disposal cost) as part of the base bid. Contractor shall be responsible for all disposal /recycling fees for electronics and CRT monitors. This credit /cost shall be indicated in Informational Bid #1, found in the bid form. The City may elect to accept or reject the Contractor's offer of this credit /cost and dispose of the equipment separately, in which case the award amount will be adjusted and the Contractor shall be responsible for removing the equipment and demolished cabling to a location within City Hall as designated by the City. D. Location: The installation of MON6 and associated cabling/systems will occur at the City of Columbia Heights Library, 820 Constitution Blvd, Columbia Heights MN. 1.03 SUBMITTALS A. General Information: As required by Sections 27 00 00 and 27 40 00. B. Documentation: Block diagrams are intended to indicate general intent and scope of the design. Contractor shall provide shop drawing submittals in order to document details of installation. C. Shop Drawings: Shop drawing submittals shall show the following: 1. Wiring Diagrams: Wiring diagram(s) for interconnected components, showing cable designations and connector detail 2. Rack elevations Elert & Associates Section 27 41 00 — Audiovisual Systems 51 Columbia Heights Council Chambers Technology RFB 3. Custom Panels/Plates: Layout of custom connector panels and wall plates, with engraving detail 4. Plan View: Plan view of all structurally mounted and installed equipment (monitors, cameras, loudspeakers, etc.) 5. Mounting: Typical view of intended structural mounting techniques 6. Installation Notes: Notes to installers regarding installation detail. 7. Pin -Outs: All multi - conductor connectors shall be shown as a typical detail with detailed pin -by -pin termination information. 8. Cable and Connector schedule. 9. Final drawings of custom lectern, with finish sample. D. Preconstruction Submittal Review: 1. Contractor shall meet with Consultant via WebEx to review drawings together. Revised hardcopy set shall be sent to Consultant after meeting for final review. E. Closeout Deliverable Delivery: As -built drawings shall be delivered both in AutoCAD (or format acceptable to Owner) and in hardcopy (5 sets). Final record drawings shall show: 1. As -built Drawings: Entire set of shop drawings, updated with changes made during installation. 2. Review set shall be submitted to Consultant for review prior to final hard - copy and electronic sets being produced. 3. Hard -Copy Sets: Upon approval of Review set, Four (4) sets shall be produced for submission: Three (3) sets shall be delivered to Owner, one (1) set to Consultant. F. User Manuals: User manuals to be submitted by Contractor shall include the following: 1. Quick- Reference Guides: Quick- reference guide for system setup and operation for each room. 2. Organization: User manuals from each piece of equipment, alphabetized by manufacturer and in a 3 -ring binder. 3. Remote Controls: Equipment remotes shall be boxed and delivered to Owner, along with batteries, cables, duplicate manuals, and miscellaneous parts included with equipment from manufacturers. Contractor shall record dated signature from owner to indicate acceptance of these materials. 4. Serial Number List, organized by room. Elert & Associates Section 27 41 00 — Audiovisual Systems 52 Columbia Heights Council Chambers Technology RFB 1.04 CORRECTION PERIOD A. General Information: Products shall be covered by Contractor correction period as required by Sections 27 00 00 and 27 40 00. B. Correction Period: Contractor's obligation for correction period shall not abrogate manufacturers' warranty periods. PART 2 - PRODUCT 2.01 PRODUCT SPECIFICATIONS A. General Information: As required by Sections 27 00 00 and 27 40 00. B. Expanded Schedule: Products shall be provided in type and quantity as listed on Appendix A equipment schedule. Substitutions are subject to prior Consultant approval. C. Interconnections: Contractor shall be responsible for providing populated, grommeted, or blank cover plates for all wall and floor box openings intended for audiovisual systems. D. UTP Cabling: Contractor shall use UTP cable as recommended by manufacturer of transmission equipment for optimal bandwidth and signal timing. Cable type shall be detailed in shop drawing submittals. E. UTP Patch Panel: Contractor shall provide 24 -port CAT -5e patch panel in control room, compliant with Gigabit standards. F. Ethernet CAT -5e Cabling & Hardware: Contractor shall provide and install CAT -5e cabling to the following station drop /jack locations from the patch panel in the control room: five (5) on the inside of the lectern, one (1) each at the two monitor locations on the inside of the dais desk, one (1) each at the two wall- mounted monitors on the sides of the chambers, for a total of nine Ethernet jacks. Test results shall be submitted and shall be required to meet Gigabit standards. Contractor shall furnish three (3) patch cables. Owner will furnish and configure Ethernet switch. G. Mounts: Contractor shall fabricate mounts for loudspeakers, monitors, and cameras as necessary, and shall modify standard mounts as required for optimal mounting configurations. Intended hardware shall be detailed in shop drawing submittals. 1. Custom mounting configurations shall be submitted in shop drawings for review. 2. Contractor shall provide all hardware as necessary, including flanges, Unistrut, threaded pipe, column extensions, yokes, clamps, threaded rod, aircraft cable, and any other hardware required to securely mount equipment. Elert & Associates Section 27 41 00 — Audiovisual Systems 53 Columbia Heights Council Chambers Technology RFB 3. All ceiling tile penetrations shall be neatly finished with a plate, grommet and/or escutcheon ring. H. Equipment Schedule Details: The following custom/modified items are referred to in the equipment schedules. 1. CPL1: Shall consist of a Middle Atlantic BL1 blank panel assembly with connectors installed on front /through panel. Labeling shall be custom - engraved Lamacoid with white lettering. 2. DVV1: Contractor shall provide custom wood shelf for interior of lectern, to hold DVV1 unit. 3. PVR1: Contractor shall provide 1RU shelf with blank covering unused portion of shelf opening. 4. DSP2: Shall consist of 2RU blank panel, with sixteen (16) 10K Ohm potentiometers as required to communicate with the I/O ports of DSP1 to increase and decrease gain on each respective input channel. Knobs shall be furnished. Panel shall be engraved with input type (microphone number or input description), and 8 marks around each knob. Engraving shall be white on brushed aluminum black panel. 5. CAM2: mounting bracket shall be white and shall permit camera to have field of view of all seats at dais. 2.02 MISC. PARTS & MATERIALS A. General Information: As required by Sections 27 00 00 and 27 40 00. B. Laptop Cables Contractor shall provide all interconnection cables shown on the project drawings, including breakout cables for laptops. Laptop breakout cables shall have integrated audio, where applicable, and shall be equal or greater in quality to the Extron 26- 490 - series of cables. Substitutions are subject to prior Consultant approval. Digital (HDMI /DVI /DisplayPort) cable selection is subject to Consultant review. C. DOC1: VGA cable for DOC1 shall be 5xRG -59 assembly. 2.03 CABLE SLEEVING: A. Shall be white or black expandable sleeving, with ends neatly tie - wrapped and turned under, or heat - shrinked. Cables requiring sleeving include: 1, Service loops for racks /carts /credenzas. 2. Exposed cabling outside of wire management in desks & furniture. 3. Cable umbilicals connecting to wall, floor, or ceiling plates consisting of more than one wire. Elert & Associates Section 27 41 00 — Audiovisual Systems 54 Columbia Heights Council Chambers Technology RFB PART 3 - EXECUTION 3.01 EQUIPMENT LOCATION A. Coordination: Where device locations are not shown on rack/console elevations and project drawings, Contractor shall coordinate with Consultant to identify desired/optimal locations. B. Contractor shall verify all wall - mounted monitor mounting heights on preconstruction submittals. C. Loudspeakers: Precise location and of all ceiling- mounted devices shall be field- coordinated with Consultant. D. Contractor shall modify dais /lectern as follows: modify hole size of microphone shock mounts (as required), cut in hole for CNK1, cut grommet openings for dais - mounted monitors. E. Contractor shall run wiring under the dais as required. Access to raised floor is Contractor's responsibility. F. Cabling on ceiling shall be concealed to greatest possible extent. Contractor shall bundle cables within white expandable sleeving for runs from device to control room. Cable pathways shall follow ceiling structure (may not go under beams). G. Cable connection to Monitor Cart (MON2) shall be via RJ -45 plate at front of platform (Contractor to provide and install plate). Plate to be brushed stainless steel finish. H. MONS bracket to be attached to top of turret rack on FRN1. I. FRN1: Final configuration subject to Consultant direction. J. FRN1: Winsted part # 56981 may require Contractor to field- modify for clean installed appearance. K. Contractor shall remote wireless microphone antenna, if necessary for adequate coverage in the chamber. L. SPB1 shall be mounted on wall in control room, facing console. M. USB cables shall be extended to each keyboard/mouse location on console desktop from KVM1 location in adjacent rack (cables shall follow normal egress path from RCK1). 3.02 EQUIPMENT CONFIGURATION A. Integrated Control System (ICS): Refer to Section 27 47 00 for ICS configuration. Elert & Associates Section 27 41 00 — Audiovisual Systems 55 Columbia Heights Council Chambers Technology RFB B. Labeling: Contractor shall configure all equipment for normal use, including setting of levels and presets. Small adhesive labels shall be affixed to equipment indicating nominal levels and settings. C. DSP1: Audio system shall be configured with mix -minus matrix for all zones with live microphones. Contractor shall coordinate gain structure with Consultant prior to programming. D. LOGI : Coordinate with Owner for graphics to be loaded into Graphic Still Store. Contractor shall load graphics and verify operation. E. CLR1: shall be configured for same output level as B /C /D outputs from DSP (refer to Bid Drawings for B /C /D reference). Shall be used for monitoring levels only and shall be labeled accordingly. 3.03 TRAINING A. General Information: As required by Sections 27 00 00 and 27 40 00. B. Contractor shall provide two training sessions: 1. One session, three (3) hours of training for Owner technology staff on overall system operations, including production switcher and broadcast character generator. 2. One session, four (4) hours of training for Owner technology staff on use of VSS equipment. Training to be provided by manufacturer of VSS equipment. C. Scheduling: Training shall be scheduled with Owner and Consultant at least fifteen (15) days in advance. D. Quick- Reference Guides: Contractor shall compile quick- reference guide for system operation and basic troubleshooting. Quick- reference guide shall be provided at the training session, and training shall include walking through quick - reference guide steps. PART 4 - TESTING 4.01 SYSTEM TESTING A. Contractor shall check that all cables are properly labeled and secured prior to substantial completion inspection. B. Contractor shall ensure that all work areas are clear of all debris, tools, empty boxes, and extra parts prior to substantial completion inspection. C. Contractor shall ensure that all standard functions of equipment are functional prior to substantial completion inspection. Elert & Associates Section 27 41 00 — Audiovisual Systems 56 Columbia Heights Council Chambers Technology RFB D. Contractor shall check all input and outputs of the system for signal quality prior to substantial completion inspection. This includes verifying signal quality from each floor box HDMUVGA/audio input location. g riElert & Associates Section 27 41 00 — Audiovisual Systems 57 Columbia Heights Council Chambers Technology RFB SECTION 27 47 00 — INTEGRATED CONTROL SYSTEMS PART 1 - GENERAL 1.01 REFERENCE A. The provisions of Sections 27 00 00, 27 40 00, 27 41 00, the Bid and Contract Requirements, drawings and appendices are included as a part of this section as though bound herein. B. Additional Reference Standards 1. Copyright Act of 1976 U.S. Copyright Office 101 Independence Ave. S.E. Washington, DC 20559 Phone: (202) 707 -3000 1.02 SCOPE SUMMARY A. Contractor Responsibility: Provide, install, program and configure fully functional Integrated Control System (ICS). B. Software: All versions shall be current as of date of substantial completion. C. iPad App: Contractor shall provide application for Owner - furnished iPad to provide identical control capabilities to wired ICT1 panel in Control Room. 1.03 AESTHETIC REQUIREMENTS A. Printing: Button labels shall be engraved. Handwritten labels are not acceptable. B. Graphics: Icons and graphic representations of equipment and functions shall be crisp, sharp, and easy to identify. Icons shall be used wherever possible. C. Text: ICS screens shall not use uncommon abbreviations. Text shall be sans serif and shall be sized to be clearly readable. 1.04 IT COORDINATION A. General: Where connection between components or control features are accomplished over the Owner's LAN, Contractor shall coordinate with Owner's IT department for IP /MAC addresses, firewall access, and other issues pertaining to successful integration. B. Permission: It is Contractor's responsibility to obtain necessary information and permissions to implement their system. Any delays or problems with gathering information or coordinating access to the LAN or WAN shall be brought to Consultant immediately for resolution. - Elert & Associates Section 27 47 00 — Integrated Control Systems 58 Columbia Heights Council Chambers Technology RFB 1.05 OWNERSHIP A. General: Upon completion of the project, all programming and configuration of control hardware, touch panels, and other devices shall be property of Owner. B. Property Rights: Contractor assigns to Owner any and all intellectual property rights and applications made by Contractor, or its agents or employees in connection with the performance of this contract. Contractor also acknowledges and agrees that services rendered in connection with the performance of this contract shall be a "work made for hire" within the meaning of Section 201 inventions of the Copyright Law of 1976. C. No Passwords: Contractor shall not use any passwords to prevent access to code files except as specified herein. 1.06 DELIVERABLES A. Pre - Installation Submittals: 1. Button layouts for each ICS /ICT /ICB device. 2. Descriptive write -up of function(s) of each button. 3. Labeling detail for buttons. 4. Contractor shall make changes as requested by Consultant in pre - installation ICS review. 5. ICS review shall be done via WebEx conference with Consultant. B. Closeout Submittals: Contractor shall submit the following to Consultant prior to final inspection: 1. Three (3) copies of all project ICS programming on CD. 1.07 UPGRADES A. Firmware: Firmware upgrades shall be dated the same as Date of Acceptance. Contractor shall upgrade firmware and software as necessary during project so that latest versions are installed as of Date of Acceptance. PART 2 - PRODUCT 2.01 PRODUCT SPECIFICATIONS A. General: Contractor shall provide product as identified in Appendix A. B. Hardware: Contractor shall supply equipment, accessories, cable, and connectors necessary for system to operate according to stated functional requirements, whether or not said products are named in Appendix A. If Elert & Associates Section 27 47 00 — Integrated Control Systems 59 Columbia Heights Council Chambers Technology RFB Contractor wishes major additions to be given special consideration, part numbers, quantities, and line item pricing may be listed under Bid Exceptions. C. Contractor shall provide heavy -duty IR emitter boots on all IRP devices. D. CNK1 shall be provided with custom - engraved bezel. PART 3 - EXECUTION 3.01 EQUIPMENT LOCATION A. ICS equipment shall be housed with equipment detailed in Section 27 41 00. 3.02 CONFIGURATION A. Contractor shall configure software to meet all functional requirements. B. Contractor shall make adjustments to programming as required by Consultant up to issuance of substantial completion punchlist at no additional charge, so long as changes relate to equipment in this bid package. C. PAC 1: power on/off for sequencing strip (for high - current devices such as AMP1). D. DVV1: Transport controls. Note that DVV1 in control room will be manually controlled. E. SWS 1: Input selection F. SWS2: Input selection for each switcher section separately. G. MXV1: Input /output matrix selection (inputs /outputs to be named) H. DOC 1: Zoom in, zoom out, autofocus I. PVR1: Transport controls, record start/stop, onscreen menu control. J. MON 1 /MON2 /MON3 /MON4: On/Off K. DSP1: Overall room volume control, fine gain adjustment for output channels to broadcast system 3.03 SHUTDOWN FEATURES A. Shutdown: When any `system off' is pressed, page shall appear asking if user wishes to shut system down. B. Automatic Shutdown: System shall automatically shut down monitors after three hours of touch panel inactivity. Warning page shall appear five minutes (5) before shut down saying "System will turn off in 5 minutes." Audible warning tone shall come through all applicable touchpanels. N Elert & Associates Section 27 47 00 — Integrated Control Systems 60 Columbia Heights Council Chambers Technology RFB PART 4 - TESTING 4.01 TESTING A. General: Contractor shall check the functionality and programming of system prior to substantial completion inspection. Any programming bugs shall be fixed prior to that inspection. B. Demonstration: Contractor shall demonstrate all system control functions during substantial completion inspection Elert & Associates Section 27 47 00 — Integrated Control Systems 61 Columbia Heights Council Chambers Technology RFB APPENDIX A - EQUIPMENT SCHEDULES AUDIOVISUAL Desig Description Manufacturer Model Qty Unit Price Ext. Price MICI Modular Microphone Element AKG CK47 13 MIC1 Gooseneck Section AKG GN30E 13 MIC1 Shock Mount AKG 11500 13 MIC2 Modular Microphone Element AKG CK31 1 MIC2 Gooseneck Section AKG GN30E 1 MIC2 Shock Mount AKG 11500 1 WMS1 Wireless Mic Combo Audio Technica ATW -3131b 1 WMH1 Wireless Handheld Audio Technica ATW -T371b 1 DSPI DSP Mixer Lectrosonics DM1612F 1 DSP2 Mixer Control Interface Custom See Specification 1 AMP1 Power Amplifier QSC CX108V 1 SPB1 Loudspeaker 70V ElectroVoice 301045 -004 11 ALS1 Assistive Listening Transmitter Williams Sound PPA T35 1 ALS1 Wall Mount Antenna Williams Sound ANT 024 1 ALS1 Rack Mount Williams Sound RPK 005 1 ALS2 Assistive Listening Receiver Williams Sound PPA R35 -8N 4 ALS3 Headphone Williams Sound HED 026 4 ALS4 Neck Loop Williams Sound NKL 001 1 ALS5 Sign Williams Sound IDP 008 1 CLR1 Compressor Limiter Behringer MDX1600 1 DVC1 Divider /Combiner Radio Design Labs STD -10K 1 MON1 40" LCD Monitor Sharp LC- 40LE810UN 2 MON1 Mount Bracket Chief Mfg LSMU 2 MON2 40" LCD Monitor Sharp LC- 40LE810UN 1 MON2 Monitor Cart Chief Mfg PFQUB 1 MON3 40" LCD Monitor Sharp LC- 40LE810UN 2 MON3 Mount Bracket Chief Mfg MWRUB 2 CAMl PTZ HD Camera Vaddio 999 - 6907 -000W 4 SWB1 Switcher & Cam Controller Vaddio 999 - 5200 -000 1 MIP1 Multi -image Processor Roland MVS -12 1 MON4 Control Room Monitor Sharp LC- 40LE810UN 1 SCN1 Scan Converter TVONE C2 -1100 2 SCN1 Rack Mount Kit TVONE RM -220 1 SCAT Scaler TVONE C2 -1200 1 SCA1 Rack Mount Kit TVONE RM -220 1 VDA1 Video DA Extron 60- 439 -01 6 VDA1 Rack Shelf Extron 60- 190 -01 2 VDA2 Video DA Extron 60- 446 -01 1 LOG1 Graphic Still Store Extron GSS100 1 LOGI Rack Shelf Extron 60- 190 -01 1 CGE1 Character Generator Compix ConverGl 1 PVR1 Video Recorder MVIXUSA MX- 880HD1500GB 1 tI Elert & Associates Appendix A — AV Equipment Schedule 62 Columbia Heights Council Chambers Technology RFB PVR1 1RU Custom Rack Shelf Custom As Required 1 MON5 CG Monitor Viewsonic VG2028wm 1 MONS Monitor Bracket Chief Mfg KCD100B 1 CAM2 Video Camera Panasonic WF -CF284 1 CAM2 Mounting Bracket Panasonic As Required 1 CAM2 Power Supply As Required As Required 1 VSS1 Broadcast Controller Tightrope Media CBL- Cablecast- Bundle 1 VSSI Cablecast Bundle Warranty Tightrope Media SA -Gold 1 VSS2 Video Server Tightrope Media CBL -SXLE 1 VSS2 SXLE Warranty Tightrope Media SA -Gold 1 VSS3 Character Generator Tightrope Media CBL -CG310 1 VSS3 SDI Card Tightrope Media CBL -CGSDI 2 VSS3 CG310 Warranty Tightrope Media SA -Gold 1 VSS4 Onsite Training Tightrope Media SVC -ONH -TRAIN 4 VSS5 Onsite Service Tightrope Media SVC- ONH -INST 4 MXV1 Video Matrix 8x4 Extron 60- 554 -31 1 MOD1 Modulator Owner Furnished Contractor Installed 2 OFCI OFCI SW S 1 System Switcher Extron 60- 569 -01 1 SWS2 System Switcher Extron 60- 532 -01 1 UTX1 UTP Transmitter Extron 60- 669 -01 1 UTR1 UTP Receiver Extron 60- 690 -02 1 DOC1 Document Camera Wolfvision EYE -12 1 CNK1 Flip Top Interface Crestron C2N- FT- TPS4 -B 1 HDAI Cable Adapter mini -DP to HDMI Monoprice 5311 1 HDA1 Cable Adapter mini -DP to VGA Monoprice 5107 1 HDA1 Cable Adapter DVI to HDMI Monoprice 2029 1 HDAI Cable Adaptor DP to HDMI Monoprice 4826 1 HDAI Cable Adapter DP to VGA Monoprice 5135 1 DVV1 DVD/VCR Combo Unit Panasonic DMR- EZ48VK 2 DVV1 Custom Shelf Custom See Specification 1 DVV1 Rack Shelf Middle Atlantic U2V 1 XDAI VGA DA Extron 60- 506 -03 1 UTX2 UTP Transmitter Extron 60- 652 -01 1 UTX2 Rack Shelf Extron 60- 190 -01 1 UDA1 UTP DA Extron 60- 686 -01 1 UTR2 UTP Receiver Extron 60- 735 -01 5 CPL1 Connector Panel Custom See Specification 1 KVM1 KVM Switcher NTI UNIMUX- USBV -40 1 ICS1 Control Processor Crestron CP2E 1 ICS 1 Power Supply Crestron PW- 2420RU 1 ICE1 IR Emitter Crestron IRP2 2 IPD1 Wireless Touchpanel Apple iPod 16GB WiFi 1 IPD1 Mobile App Crestron Mobile Pro G 1 RCKI Equipment Rack Winsted V8801 1 FRN1 Double Bay Stringer Winsted 56004 1 Q Elert & Associates Appendix A — AV Equipment Schedule 63 Columbia Heights Council Chambers Technology RFB FRN1 6RU Rack Cabinet Winsted 56032 1 FRN1 Single Bay Hinged Cover Winsted 56042 1 FRN1 27" ABS Filler Winsted 56981 1 FRN1 End Frame (pr) Winsted 56061 1 FRN1 Bottom Shelf Winsted 56082 2 FRN1 CPU Can Winsted 56220 1 FRN1 Work Surface Bracket (pr) Winsted 56262 2 FRN1 Vented Door Winsted 56302 4 FRN1 Side Panels (pr) Winsted 56520 1 FRN1 Work Surface for 56220 Winsted 56620 1 FRN1 48" Work Surface Winsted 56624 1 FRN1 2 Pole Monitor Mount Winsted W5690 1 FRN1 Rack Kit for Sight Line Winsted W5642 2 RKB1 Rack Blank Middle Atlantic BL1 22 RKB2 Rack Blank Middle Atlantic BL2 3 PAC1 Power Sequencer Middle Atlantic PDS -615R 1 PAC2 Power Distribution Middle Atlantic PD- 1415C -NS 1 PAC3 Power Distribution Tripp Lite 602 -15 4 UPS1 UPS APC SUA3000RM2U 1 MON6 40" LCD Monitor Sharp LC- 40LE810UN 1 MON6 Wall Mount Bracket Chief Mfg LSMU 1 PLT6 Input Plate Custom Custom 1 LIB1 Camcorder Canon HF -S20 1 LIB1 SDHC Card 16GB PNY P- SDHC16G4 -EF 1 _ LIB2 Tripod Smith- Victor 700005 1 LIB3 Camcorder Case LowePro Edit 140 1 LIB4 Microphones Adapter Beachtek DXA -2T 1 LIB4 Mic Cable Shure C25B 1 LIB4 Microphone Shure VP64A 1 Misc. Parts /Cabling/Wire 1 Installation Labor 1 Control System Programming 1 All Other Costs 1 Sales Tax 1 Subtotal Elert & Associates Appendix A — AV Equipment Schedule 64 Columbia Heights Council Chambers Technology RFB APPENDIX B - EXISTING EQUIPMENT Control Room Description Manufacturer Model Qty Monitor Panasonic CT -110MA 1 Monitor Panasonic WV -5350 1 Stereo Tuner Catel KT -900 1 Monitor Panasonic CT- 1384VY 2 Monitor Mount Panasonic WV -BM503 2 Wireless Receiver Shure L4 8 Mixer Shure M267 1 Mixer Mackie CR1604 -VLZ 1 Amplifier TOA P- 906MK2 1 Equilizer EV EQ -215 1 Wireless Receiver Shure L3 5 Camera Controller Panasonic WV -CU254 1 Camera Controller Panasonic WV -CU101 1 Video Switcher Panasonic WJ -22R 2 Broadcast Switcher Panasonic WJ -MX50 1 ALS Transmitter Telex AAT -2 1 Equipment Rack - 40U Emcor unknown 2 Tape Recorder Yamaha KX -W582 1 Audio Processing IRP System 41 1 Integrated Controller Leightronix Pro8 1 Monitor ViewSonic G70fmb 1 VCR JVC SR -VIOU 1 VCR JVC HR- S3600U 3 VCR JVC HR- S3910U 2 Video CG/Bulletin Board Server Alpha Video #606527 -00 1 Video DA Panasonic WJ -300C 1 Equipment Rack - 35U Emcor unknown 2 Chambers Ceiling Speaker unknown unknown 4 Monitor Panasonic WV -BM500 1 Camera Panasonic WV -CS304 5 Gooseneck Microphone - Cardioid Shure unknown 12 Monitor JVC AB -27920 4 Monitor Mount Peerless Jumbo Mount 4 EA Elert & Associates Appendix B — Existing Equipment 65 1. OAV g E i i ,..,.... a i ail E 5 1 > 0 8 co — — ',5 6 c 0 E Csi 0 . e- = CD za .;: a; bo 2 2 c) u) 0 0 0 ' 0 1 M 12 E P ... .2. 1 11 w o I- : i 1 ` + ,,,...-, I F Zi 8 a — w / 1 . 0 CD 0 CO -• ..„,„ 15 ® 0) •k ,,,, _ _ — 0 _ • ___,,,, ' . 1 a 1 1 LON 11 0 E==21219 0 0 rsm E3 1 i 1 I 11 i I i 1 1 1 ma ®8 E3 1 1 1 1 1 i ... „.....„.., '•,, comma, f p 0 0 8 0 5 6 g 1,1 = g g § 3 I> 26 c c cm o .s. t8 s I LuP .2 - 0 tr. 0 cx• CO 1.." — ca 0 Es .c 13 •-• co c ct = c3 en2cq 0 0 0 0 o • �Il 000 .— c 2 co 11 HO (/) CO 111 cu .o 3 a. 1- D - o < • 0 cu 0 0 c > o abm <cum 0 o 7108.121 c C C rsj ur:Bmn_,w.R O 0 .0 "0 8 8 C <meMg.PQ 2 g g n lipitli> DWCOMPD (1) 0 .0 — CO 0 CO • 0. w " CO * to C (j) Orl > 1111 0 > P„ CD _ 2 -t 0 0. 0 o 'a@ In c -0 Cs9_ in 5. 4( :E 0 al— c6 0. � 0 a) > (.9 - 0 PCDZIWCIS > E co .td, 11 > O 0u30.__ 4- " re 0 II 0 II lI < ZOAV1PA 1 MI G & G p a _ _ UW� UW� f: @ o g4 ® 111117 =m :F +!� O LL O LL '4 o I .2 ® I ®I) m �O Um ti m y E 1 x x T 1 ! i ] tJ ® ® "l ri > - t I 7111111 a 0111 > ® m _ 1 NN > a w Iiiii 0 1 ` 33 x i ffL 1 Z x > > 1I 1 ® U fT '� > E if MN > f i __ . > > x > > x > > > a - E R p p J > > > > > x 7 1 I I I ME 0 i al I : ° Y 1 1 g x > E S d ' -c 0 O 11; 'O o U Ec- U U 1�j11 ,I, COATI -14. 3 2 E Z-2E 81 -)_ ,r1 La • • .4 j E Ea o t I 8 o 2 . 0: 2 ° • g § r I ea 3 p 1 '2 CI 2 7; E I 1 01 111 12- . - 011 6 [H 1‘• '61 1101 i° IMATI L- ri if 5 u g 0 - E . 2 & Q , •oC Et I . 0 * 5 6 1 .t •g g t; ft 4 E Vg g 5 N a i • 0 0 0 Co co t .0 . 0 .0 •0 •0 •0 •0 > ,?,. g a) a a a 0 ti a 0) .c R e o ,.> o>, • 0 8 1 - F; g ' 1 L m < 0 M 2:100:101000 0 0 tS? 1 i i E. 0 0 0 0 1 11 1 Z 2 2 2 2 2 E. 1 1 1 . a II SOAV 1 LIIL11 1 MMM I , a , r — 1 " E -PE Ei so ai t 1 g 013 . 1 3t 6 ce x x w c e in al 03 I Ill? 11:fl III [11 gill e 9 I a t o i i 8 1 lig m D <4 g re •• tc'. D Lis i 3 2 h i ig 1 0 0 0 0 0 15 c 0, c — e o 01 ..i. , 0 i 1 E , 0 a. —7.--.- --:-.-- 5 D M CL CL :1-3 111 III ie, () 00 60 s ? a: f= I. 7 • -. v n D D ..N.'4WW,M , -N.V . WO,W er,Ifl e-NV,VWW,W 1. z Aeia8 leMeS/211 zs 0 0/1 s 5 (1 9 A N Ai Vi u 3 VI 90Attirl to i L. 5= g 0 e 0 E 4 0 o 0 . g c4 o w s ai 2.w 2U 22 t L I 6 0m 1= E 0 0 0 g i i 80 0 o..E & 2 i t cit a g t5g. E WQ wre. .:1 IS iI 6 2 0 I.., 0 M us 0 0 V B 16- ... ( . 3 6 c.z 0 0— (a igl 0 0> co I-0 ,T,Lic 0 g 4 15 2i; c g° c 3" co . ,... a .5!POMRIRA2P47,2gAWAW4MM1R'"""'""°c... ii > w ..... LI z7, z, •._Ir 8 T 8 co .coLco 0 ::.10 g E it i i 5 E 'oi C G 9 - is ix is 2 LE 2 tt ) 4 g i E3 tjg EL re 2 CC 5 25 5 >) et 8 g 1: Et E 0 , 0 0 . 0 g . 6 i Z m p x 9 D 1 6 AM al 26666 re ea cc re re < x 1111 1 1 1 A e C x ELERT & ASSOCIATES 140 Third Street South, Stillwater, MN 55082 ADDENDUM #_1 ISSUE DATE: DECEMBER 1, 2010 Addendum to drawings and specifications entitled: City of Columbia Heights Request for Bid: Council Chamber Technology Replacement PUBLICATION DATE: OCTOBER 28, 2010 The additions, revisions, omissions, corrections and clarifications contained herein shall be made to drawings and specifications for the project and shall be included in scope of work and proposals to be submitted. References made below to specifications shall be used as a general guide only. Proposers and Contractors shall determine for themselves the work affected by Addendum items. CONTRACTUAL ITEMS 1. Pre -bid meeting shall not be considered mandatory due to the City's interest in receiving competitive bids. 2. Section 27 41 00 Article 3.01 Paragraph E: Contractor is not required to access raised floor. 3. Paragraph F: Cable connection to Monitor Cart (MON2) shall be via RJ45 plate at front of lectern, with location to be coordinated onsite with Consultant. 4. Section 27 47 00 Article 1.02 Paragraph C: iPad device to be Contractor - furnished, not Owner - furnished. Additionally, Contractor shall provide "GoodReader" app on iPad and load all as -built drawings and closeout submittals in PDF format (in addition to other submittal requirements). 5. Section 27 47 00 Article 1.07 Paragraph A: replace word "dated" with "current ". EQUIPMENT SCHEDULES 1. IPD 1 shall be "iPad ", not "iPod ". 2. MONS mount to be KCB 110B, not KCB 100B. QUESTIONS AND ANSWERS Q: Referencing PAC2, do you have a different part number as this one is not available? A: According to Middle Atlantic's local representatives, PD- 1415C -NS should be a current part number. A quick Google search also reveals plenty of available sellers who have this product. Q: Are there any alternates? A: Not at this time. Q: Can we substitute Kramer for Extron? 1/5 A: Not without providing specific part numbers and specification information to demonstrate that the proposed product is equivalent or superior to the specified product. There are a number of Extron items in the design and not all of them have equivalent Kramer counterparts. Q: HD cameras specified for CAM1. Entire video path for these cameras is composite video. Suggest to install composite video cameras. HD cameras are 16:9 aspect ratio and the display devices are 16:9 but the entire signal path is 4:3. This will make all images from the camera appear smaller within the 4:3 screen. A: Specified cameras have selectable 4:3 output setting. Q: Listed cameras specified as wall mount cameras. Wall mount to ceiling mount adaptors or brackets not specified or listed. Suggest change model to ceiling mount cameras or add drop -down from ceiling brackets. A: Image inverse for inverted mount of specified camera is selectable. Camera can be mounted inverted to the bottom of wall mount bracket, providing mounting possibility. Otherwise, any /all structural mounting hardware is responsibility of Contractor and to be included in base bid under "Misc. Parts ". Q: Rack elevation drawing: Missing MONS, VGA monitor for Tightrope and CG setup monitor. Could be positioned above the turret add on to the console. This would require the 40" LCD to be mounted to the right of this console and there would be a space requirement between the standing rack and the console. A: MONS is not to be rack - mounted, therefore not shown on rack elevation. Mount is adjustable; location to be field- coordinated with Consultant. Q: Need to add rear door for standing rack cabinet A: No. Q: Delete Winsted 56220 CPU holder from equipment list — not shown or used in this design — delete 56620 work surface for CPU carrier A: No. This is a necessary part of creating the console width required for the monitors. Q: Rack mount tray in RK2 RUI 1 will require 1 /4 wide 1RU blank panel. A: This is included with the specified rack shelf product. Q: Rack mount tray in RK2 RU1 will require 1/4" wide 1RU blank panel/ A: Contractor is responsible for providing rack shelves and blank panels. Q: DVV1 — Panasonic DVD /VCR unit should be 3RU. A: No. Use flangeless blank panel above. Q: PVR1 — MVIXUSA appears to be 2RU in height not 1RU. A: No. Use flangeless blank panel above. Q: PVR recorder is NTSC input with MPEG 2 recording. Any other format would require network connectivity. A: Network connectivity, if desired, will be handled by Owner IT staff. Q: Assume not all items in equipment room racks will go to UPS. Items to be on UPS not detailed within the bid specification document. A: Not necessary for bidding purposes - to be coordinated in preconstruction submittal phase. Anticipate TRMS, DSP, and Crestron devices to be on UPS. 2/5 Q:Tightrope bundle: requires a network switch not listed or mentioned in bid specification. A: Requires Ethernet connections, either to local switch or to remote switch in telecommunications closet, to be provided by Owner. Q: Reuse of microphone mute switching not listed or mentioned in bid specification. Please detail this requirement and the device to reuse with the remote audio volume control. A: Appendix B covers existing equipment to be taken on trade -in by successful bidder. Since these switches are to be reused and do not need to be removed, they were not listed in Appendix B. Site inspection should be sufficient to determine the wiring necessary to re- integrate these switches with the new microphones. Does not directly interface with manual microphone gain control panel. Q: APC UPS specified in the bid specification power connector is twist lock 30A connector L5 -30P — not a NEMA- 5 -15R, this does not meet this stated requirement will this be acceptable? A: Yes. Q: Definitions of which areas are plenum air space are not detailed nor noted within the Bid Documents. A: Contractor is responsible for using plenum -rated cables in any spaces where plenum -rated cabling is required by code. Site visit highly encouraged for ascertaining existing conditions. Q: 2E. Which standards are being referred to her [sic], 1000Base -T (IEEE 802.3ab)? A: Assuming you are referring to 27 41 00 2.01 (E): this is commonly referred to as 1000 BASE -T, or as gigabit Ethernet. Q: CAT -5e patch panel is not with in the scheduled drawings provided by the Consultant. What devices (sources and destinations) will be used on this panel? A: Not necessary for bidding purposes. City will use several for Ethernet to lectern; remaining cables are for future use, likely HDMI or IP content delivery to chamber display monitors. Q: F notes Ethernet switch will be furnished by Owner. Best performance operation would suggest that this switch will be a Gigabit Ethernet switch with a minimum of 6 ports. A: Not necessary for bidding purposes. Q: G appears to require Contractor to make all mounts. May Contractor purchase fabricated mounts for speakers and monitors and cameras? A: Yes, subject to approval in preconstruction submittals. Intent is to make clear that all mounting hardware and equipment is the responsibility of the Contractor. Q: 3G. Monitor Cart not described enough to be able to ascertain the connectivity. Is the Monitor cart OFE? A: Monitor cart is called out under "MON2" on Appendix A, as Chief PFQUB. This is to be furnished by the Contractor, with the UTP receiver attached to the rear of the monitor and cabling routed to the input location on the reverse of the lectern. Power connection to monitor will be via existing electrical duplex outlet at cart location. Q: Assuming that the software mentioned is the control surface functions, the Functional requirements are lacking in detail. Or As listed below? A: Specification provides list of desired control functions for each piece of controlled equipment via Crestron system. Q: Part B No reference as to reasoning for added changes and time line too open ended and vague beyond the implementation of C thru K and 3.03 3/5 A: Timeline is defined in 27 47 00 3.02 as "up to issuance of substantial completion punchlist ", which project schedule defines as January 14 2011 (assuming Contractor completes on time). Q: 27 40 00 2.04: The suggested Extron part number is not recommended for typical Cat 6 cabling , only for the Extron UTP. There are no other specifications listed. A: Refer to 27 40 00 2.04 Paragraph J: "UTP Cable: shall be consistent with Owner standards for UTP cable, unless otherwise noted in specification or recommended by hardware manufacturer for use with their equipment (example: Extron UTP23SF -4P for Extron UTP transmitters)." Q: 204.Q. Contractor submitted schedule to differ from posted schedule of events in Section 00.31.13 ? A: The first definition in the American Heritage Dictionary, is "A printed or often written list of items in tabular form." This is the "schedule" of cable types to which the specification refers. Q: 205.D Canare RF connectors center pin are thinner than the dia of RG59 cable center conductor. Canare RF connectors work best with new equipment RF connections. Proper connectivity with repurposed equipment is predicated upon the prior use of the Canare connectors. Previous use of center conductor coax wire may deform the equipment's RF connector not allowing subsequent use of Canare connectors. A: All connector use is subject to confirmation using the "schedule" referenced above. Q: 206.A Finish samples need to be clarified. A: "Samples" are not referenced in this paragraph. As discussed at pre -bid meeting, finish for custom shelf for interior of lectern (27 41 00 2.01 (H.2)) may be subject to finish sample review, albeit informally. Q: 3.01A.2 Color palette needs to be specified. A: Existing ceiling structure where mounts will be located is white -ish. Equipment mounting hardware need to be white -ish so as not to clash. Precise color matching with existing undocumented paint type will not be required. Q: 27.41.00 1.02.0 Trade in and disposal of hardware and cabling appears to be a concern. A: Not the concern of the Owner, if the Owner accepts the successful bidder's trade -in offer (informational bid #1). Note that 1B#1 can be a credit or a cost. Q: 2.01.E. 24 port Cat 5e patch panel specifications need more details. With the Face RJ45 connectors for cross connections, what are requested for the rear connectors of this panel? 110 punch down or RJ45 pass thru connections? A: As this will be used for Ethernet, a traditional punch -down patch panel would be preferred. Q: 2.01.F This should be 10 panels. Dais Monitor Cart is missing from this list as noted in Section 27.40.00.3.01.G A: No. Dais cart monitor "future" jacks are included in the lectern count. Q: 2.01.G. Appears to require Contractor to fabricate and not source manufactured materials. A: No. "shall modify standard mounts as required" allows Contractor to use standard mount unmodified, or be responsible for modification of "standard" mounts, if necessary for "optimal mounting configurations ". Q: 2.01.H.2. Supplied shelf Surface treatments and color palette need to be specified. A: As discussed at pre -bid meeting, shelf needs approximate match to existing wood finish of unit. 4/5 Q: 27 47 00 1.02.C. The download of Application software to a iPad is done on the actual device. This would require the Owner to allow the Contractor to operate the device to download the required app. I'm not sure how this will be accomplished with a third party account. A: Successful Contractor will have several weeks to work through the available options with the Consultant and Owner to find the optimal solution. This can, and has been, managed successfully on other projects. Q: 3.02.D Remote control for DVV1 agreed in the Lectern only. Drawing of Video, DVV from Control Room lists this as DVV1 as well as the DVVI in the Lectern. Control Room should be listed as DVV2. A: Lectern DVV1 is remote - controlled; control room DVV 1 is not to be remote - controlled. Designations in the RFB distinguish between equipment types: make /model within a given product category, or to separate by use to facilitate substitution or deletion due to changes or program or design. Designations within the RFB do not distinguish quantities of equipment and should not be relied upon for quantity calculations. Q: Will the City be performing an official bid opening on Dec. 6 A: That is the current intent. END OF ADDENDUM # 1 5/5 ,fzic,irtiaL, VSI A/V Systems City of Columbia Heights Council Chamber Technology Replacement l I 1 * ig . --= '-- , '" 4 - 4 '"C 4 1 ;." ' .i...., : ' ' . - ',..tt;zri -.4 - --i. intim 11 • 25 Years of Technology Solutions Corporate Office 1227 Caledonia Street Mankato, MN 56001 507-625 1650 • 1 800 642 4085 wvvvv.videosercom THE AMERICAN INSTITUTE OF ARCHITECTS 1 - AIA Document A310 Bid Bond KNOW ALL MEN BY THESE PRESENTS, that we (Here insert full name and address or legal title of Contractor) Video Services, Inc. of Mankato, 1227 Caledonia Street, Mankato MN 56001 as Principal, hereinafter called the Principal, and (Here insert full name and address or legal title of Surety) AMCO Insurance Company Des Moines, Iowa a corporation duly organized under the laws of the State of Iowa as Surety, hereinafter called the Surety, are held and firmly bound unto (Here insert full name and address or legal title of Owner) City of Columbia Heights 590 40th Ave NE, Columbia Heights, MN 55421 as Obligee, hereinafter called the Obligee, in the sum of Five percent of bid amount Dollars ($ 5% of bid mount for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for (Here insert full name, address and description of project) Audio /Visual - Council Chamber Technology Replacement NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 6th day of December , 2010 ( Terry Dahl (Seal) (Witness) ( President (Title) ( AMCO Insurance Company .fit ( (Seal) fitness) J is Dontje Jo son Attorney -in -Fact AIA DOCUMENT A310• BID BOND • AIA ® • FEBRUARY 1970 ED • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D.C. 2006 1 9/93 vil Power of Attorney KNOW ALL MEN BY TI IESE PRESENTS That AMCO Insurance Company, a corporation organized under the laws of the Stale of Iowa, with its principal office in the City of Des Moines, Iowa, hereinafter called "Company ", does hereby make, constitute and appoint JANIS DONTJE JOHNSON ROBERT R. RICHTER • MANKATO MN each in his individual capacity, its true and lawful Attorney -In -Fact with full power and authority to sign, seal, and execute in its behalf any arid all bonds and undertakings arid other obligatory instruments of similar nature (except bonds guaranteeing the payment of principal and interest of notes, mortgage bonds arid mortgages) in penalties not exceeding the suns of THREE MILLION AND NO /100 DOLLARS (S 3,000,000.00 ) and to bind the Company thereby, as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Company; arid all acts of said Attorney pursuant to the authority hereby givers are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the following By -Laws duly adopted by the Board of Directors of the Company. ARTICLE 7 EXECUTION OF CONTRACTS "Section 7.4 Instruments Issued by the Corporation. Bonds, undertakings, and other obligatory instruments of similar nature, other than insurance policies and insurance endorsements, issued by the Corporation shall be validly executed and binding on the Corporation when signed by the President or a Vice President or by the Attorney(s) -In -Fact appointed by the President or by a Vice President." "Section 7.5 Appointment. of Agents. 'The President or a Vice President shall have the power to appoint agents of the Corporation, or other persons, as Attorneys) -In -Fact to act on behalf of the Corporation in the execution of bonds, undertakings, and other obligatory instruments of similar nature, other than insurance policies and endorsements, with full power to bind the Corporation by their signature and execution of any such instrument. The appointment of such Attorney(s) -In -Fact shall be accomplished by Powers of Attorney signed by the President or the Vice President." This Power of Attorney is signed and sealed by facsimile under arid by the following By -Laws duly adopted by the Board of Directors of the Company. ARTICLE 7 EXECUTION OF CONTRACTS "Section 7.6 Verifications . The Secretary, or any Assistant Secretary, is authorized to certify that any such Power of Attorney signed is validly executed and binding on the Corporation and to certify that any bond, undertaking, or obligatory instrument of similar nature, other than insurance policies and endorsements, to which the Power of Attorney is attached is and shall continue to be a valid and binding obligation of the Corporation, according to its terms, when executed by Attorney(s) -In -Fact appointed by the President or Vice President." "Section 7.7 Use of Corporate Seal. It shall not be necessary to the valid execution and binding effect on the Corporation of any bond, undertaking, or obligatory instrument of similar nature, other than insurance policies and endorsements, signed on behalf of the Corporation by the President or a Vice President, or Attorney(s) -In -Fact appointed by the President or a Vice President, or of any Power of Attorney executed on behalf of the Corporation appointing Attorney(s) -In -Fact to act for the Corporation, or of any certificate to be executed by the Secretary or an Assistant Secretary, as hereinabove in Sections 7.4, 7.5, and 7.6 provided, that the corporate seal be affixed to any such instrument, but the person authorized to sign such instrument may affix the corporate seal. A facsimile corporate seal affixed to any such instrument shall be as effective and binding as the original seal." "Section 7.8 Other Facsimile Signatures. A facsimile signature of the President or of a Vice President affixed to any bond, undertaking, or obligatory instrument of similar nature, other than policies and endorsements, or to a Power of Attorney signed by such President or a Vice President, as herein in Sections 7.4 and 7.5 provided, or a facsimile signature of the Secretary or of an Assistant Secretary to any certificate as herein in Section 7.6 provided, shall be effective and binding upon the Corporation with the same force and effect as the original signatures of any such officers." "Section 7.9 Former Officers. A facsimile signature of a former officer shall be of the same validity as that of an existing officer, when affixed to any insurance policy or insurance endorsement, any bond or undertaking, any Power of Attorney or certificate, as herein in Sections 7.1, 7.2, 7.4, 7.5, and 7.6 provided." IN WITNESS WHEREOF, the Company has caused these presents to be signed by its Vice President and its corporate seal to be hereunto affixed this 29 day of J444 ,2009 '' ... �aa AMCO INSURANCE COMPANY STATE OF IOWA 0 cSEAL' I By: � 1 ' ,.._ ---- Vice President COUNTY OF POLK ss ∎� On this 29 day of JANUARY ,207ST before me personally came Brett Harman, to me known, who, being by me duly sworn, did depose and say that he is Vice President of AMCO Insurance Company, the corporation described in and which executed the above instrument; that he knows the seal of said corporation, that the seal affixed to said instrument is such corporation seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he has signed his name thereto pursuant to like authority, and acknowledged the same to be the act and deed of said corporation. , fir SANDYALITZ Sandy Alitz / / RA C co on Number l�x ms Notary Public in and for the Seof Iowa 1w4 March 24, 201 CERTIFICATE I, the undersigned, Assistant Secretary of AMCO Insurance Company, a corporation organized under the laws of the State of Iowa, do hereby certify that the foregoing Power of Attorney is still in force, and further certify that Sections 7.4 through 7.9 inclusion of Article 7 of the By -Laws of the Company set forth in said Power of Attorney are still in force. IN TESTIMONY WHEREOF, t have subcib�d my name and affixed the seal of the company this 6 day of December , 1 03772 .4.,...-...:,,-q,* This Power of Attorney expires ` :SEAL? 0 Assistant Secretary 04/15/11 Bda 1 (03 -08) 00 �4 Columbia Heights Council Chambers Technology RFB BID FORM To: Columbia Heights �/ \/ ``� .\^/ \�n ~`r)��` ~/ �,[/u�r�� ^�,�[- , ' — ~^~ ^-`- ~~"\ - ) (corporation) [Cross out inapplicable] of 1 ) /~ ^ ' ^ � �Kl//� } - 8^6E~u^ C08 Street City County State Zip Hereby agree to execute the proposed contract and to furnish a satisfactory Surety Bond in the amount mpccificdwithin ten (|O) days o[ offering, and to provide all labor and material required for the construction of the project designated above, for the prices hereinafter set forth, in strict accordance with the Contract Documents prepared by Elert & Associates, 140 Third Street South, Stillwater, MN 55082 for the City of Columbia Heights and dated October 28, 2010. A. Base Bid Package - Audio Visual Systems (Section 27 00 00, 27 40 00, 27 41 00, 27 47 00 & Subsections thereof) Our total base bid for the work of this project is: �/ A +woct �����y �1 |_A*� ~w ^� 0��0 ,TY �^� ��DQLL/\RS($ (F4 50 B. lnformational Bid #1 Contractor shall include in Base Bid (above) a trade-in credit (or disposal cost) for the existing equipment named on Appendix B. Indicate the amount ofthe cn:dit/oostbclovv: 1 - 7 o v/ � ~ m` \Jw�O1,-/ () K\�u"�� / (" DOLLARS ($ ��� ---) /cost Check one: this is a credit ~ C. Alternates: may be added via addendum. 1. Alternate #1 w/ R DOLLARS ($ —"") - ) Ele,/'&Associates 003//3- Preliminary Schedules 17 Columbia Heights Council Chambers Technology RFB 2. Alternate #2 / 00- DOLLARS ($ — ) 3. Alternate #3 t`1f/`f- DOLLARS ($ c. ) Elert & Associates 00 31 13 — Preliminary Schedules 18 Columbia Heights Council Chambers Technology RFB COMMENCEMENT AND COMPLETION OF CONTRACT WORK The undersigned agrees, if awarded the contract, to commence the Contract work on or before a date to be specified in a written Notice to Proceed, and to complete the work within the time dictated in the Instructions to Bidders. ADDENDUM RECEIPT We acknowledge receipt of the following Addenda: Addendum No. 1-- Date / 2 Addendum No. / /f Date /VA,- Addendum No. /1/1/ Date /Wit- SIGNATURE Prior to signing, Bidder's attention is directed to the Instructions to Bidders to avoid the possibility of invalidating this bid. By signing this bid form, such action certifies that the Bidder has personal knowledge of the following: A. That said Bidder has examined the drawings and specifications, carefully prepared the bid form, and checked the same in detail before submitting said bid; and that said Bidder, or the agents, officers, or employees thereof, have not, either directly or indirectly, entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bid in connection with this Bid. B. That all of said work will be performed at the Bidder's own proper cost and expense and that the Bidder will furnish all necessary materials, labor, tools, machinery, apparatus, and other means of construction in the manner provided in the applicable specifications and at the time dictated in the contract. I/E0 (! S 0`i e j — r✓ L . (Firm Name) (Area Code & Telephone Number) (Seal, if bid is by a corporation) By: (Signature of Bidder) Date: / - % Elert & Associates 00 31 13 Preliminary Schedules 19 —VS City Of Columbia Heights - RFB — Exceptions ICT1 not listed in unit prices and VSI did not include in base bid VSI Proposes the Following Voluntary Alternate Options: Option 1 Reference: ICT1 wired touch screen 1 - Crestron TPS-4LB Touch Screen — 1 — FSR customized touch screen tabletop box — 1 — Installation — programming — engraving - ADD $1,175.00 Option 2 Reference: ICT1 wired touch screen 1 - Crestron TPS-6-B-T Touch Screen — 1 — Installation — programming — engraving - ADD $2,196.00 See spec sheets in "Appendix D" VSI Proposal for City of Columbia Heights, RFB - Council Chamber Technology Replacement — City of Columbia Heights Attn: Ms Linda Magee 590 40th Ave, NE Columbia Heights, MN 55421 Re: Council Chamber Technology Replacement RFB Opening Date: 12/6/10 RFB Opening Time: 3:00 pm VSI Company Introduction VSI (Video Services, Inc) is a technology solutions company headquartered in Mankato, Minnesota. With over 30 years in the industry, our experienced engineers and installers provide audio - video - automation -video conferencing solutions across the country with projects throughout the upper Midwest, Florida and Central America. Corporate office is located at 1227 Caledonia Street, Mankato MN. Company Mission Statement VSI provides clients eco- friendly technology solutions to include commercial design, engineering and installation services. VSI offers superior value to our clients in order to exceed their expectations. VSI promotes a positive and ethical team environment for our employees. VSI provides outstanding support after installation to all clients. Company Vision Statement VSI will be the most progressive technology solutions integrator in the industry. VSI will expand to a national and international level by providing cutting edge eco - friendly technology with professional design engineering and installation. VSI Proposal for City of Columbia Heights, RFB - Council Chamber Technology Replacement Page 2 I. Qualifications Company Profile VSI (Video Services, Inc) is a premier audio video technology solutions firm with offices and operations in Mankato, MN, operations in Moorhead, MN and Miami, FL. VSI has been in business over 30 years and in that time we have had the unique experience to take projects from concept, through detailed engineering all the way through to installation, training and "after service - care." As a progressive and growing company, VSI prides itself in providing technology solutions that are based on clients needs in numerous technology arenas to include integrated multimedia presentation systems, audio systems, automation, security - surveillance, audio -video conferencing and access management. VSI engineers are recognized for integrating complex technology on "easy to use" control platforms. Within the industry, VSI is one of the few integrators to earn national "green builder" accreditation. Our company is proud to offer "green" solutions respective of both the environment and the reduction of energy costs. Company locations and staffing levels Corporate Office, Mankato MN. Staffed at corporate are two engineers, two project managers /lead installers, four technicians, accountants, one purchaser, one certified "Green" Technician and various support and sales personnel. Supported by two Crestron programmers (subs). Southern Regional Office, Miami, FL. Supported by corporate office engineers and support personnel, two project managers (sub), twelve installers (sub), one Crestron programmer (sub), security - surveillance engineer (sub) and corporate sales staff. Management Staff Resumes Terry Dahl, President/Owner Twenty -nine (29) years of integrator experience to include engineering design for over 300 commercial projects and management of company's new product - service research and development division. Commercial project design includes extensive audio - video - automation experience. E.T. Electrical Technician, South Central College P.L.T. Minnesota State Board of Electricity certified ICIA Certified Technology Specialist NSCA CST Instructor ISCET Certified Electronic Technician TCE Five -year Quality Service Award from Thompson Consumer Electronics Biamp Manufacture Training TEF Manufacture Audio EQ Training Crestron DMC —E Training - Commercial & Residential Design Polycom Manufacturer Design Training Da -Lite Screen Manufacturer Training Shure Manufacturer Training VSI Proposal for City of Columbia Heights, RFB - Council Chamber Technology Replacement Page 3 Paul Erickson, Sales Engineer/Technician Three years audio systems design and installation experience. Three years audio -video conferencing set up and client training. B.S. Minnesota State University - Mankato. A.A. Minnesota State University- Mankato. RTI Level 2 Advanced Programmer Java Programmer Python Programmer Tim Suedbeck, Systems Engineer /Purchaser 3 years of industry audio systems design and installation experience. B.S. Minnesota State University - Mankato. A.A. Minnesota State University- Mankato. Travis Dahl, Senior Project Manager/Technician Install & balance RF systems, commercial audio and video, video conferencing and integrated control systems, Fourteen years rigging and industry experience. P.L.T. Minnesota State Board of Electricity certified Polycom Audio & video systems installation & programming NSCA EST Certified. Crestron Certified in Crestron configuration and Crestron essentials of programming. Mike Kimes, Project Manager/Technician Live sound engineer. Stage and roof setup for a local production company including 120K lighting rigs. Specializing in design and installed sound systems for churches, schools and live sound. Factory trained in DSP programming and experience with Cobra -net system at Alltel Civic Center ballroom in Mankato. Ten years rigging and industry experience. Biamp Manufacture Training with extensive systems programming Smaart Live 6.0 Manufacturer training Audio Master Commercial audio calibrator and engineer. Tom D. Barna, Director, Marketing & Sales B.A. New Mexico State University. 15 Years of Sales Management and Client Service Management. 22 years of logistics, project management and planning experience. Project experience includes concept development and project management on current large projects in Miami, Florida and Belize incorporating wireless audio, video, access management and security - surveillance. G.B.C. Certified. Green Builder College, Seattle Washington. Crestron Certified in Crestron Residential Design. Gwen Moon, Operations, Scheduling, Executive Assistant 4 years in the audio video industry, ranging from scheduling 10 technicians on a daily basis, working directly with purchasing and technicians to assure jobs are kept on schedule, assisting clients with service call requests and scheduling with clients, accounts payable, accounts receivable, human resources and payroll. VSI Proposal for City of Columbia Heights, RFB - Council Chamber Technology Replacement Page 4 — VS l Unit Prices. • See "Appendix A" Project References. • See "Appendix B" Power Limited Contractor – Technician License – Crestron Certification • See "Appendix C " 11. Sub - Contract Information. Advanced Control Systems Design, Inc Palmer Harbison • Project responsibilities include the design of Crestron programming solutions and systems design programming engineering based on VSI engineering and client expectations. • Qualifications include certification as a Crestron Authorized Independent Programmer (CAIP) for VSI. Recent large programming projects include Minnesota State University, Mankato – Ostrander Auditorium, Minneapolis Library Auditorium, Lake Crystal High School Auditorium and DSU. I11. System Implementation. VSI provides a complete audiovisual system and solution, including equipment, materials, testing, training, warranty, and service. The services include engineering, installation labor, and programming of the audio /visual and control systems. VSI is sure to meet the needs of this project based on other similar systems that it has designed, installed, and serviced in the past. As a local contractor we are able to be flexible in our scheduling to meet the demanding schedule of the project and tight timelines with other contractors. The different steps are detailed as follows: System Engineering: • Review design with consultant/owner. • Programming scope creation, review with owner, implement during installation and make final revisions for owner acceptance at completion. • Provide necessary drawings for submittal approval. • Verify all quality control checks after install completion. • Provide necessary drawings for as -built finals. Project Management: • Coordinate all activities and installation with client and other contractors. • Responsible for security of equipment and safety of staff. • Implementation of control system programming. • Quality control • Training presentation and manual creation. • Responsible for end -user training seminar. • Delivery of support materials and project documentation. Pre- Installation Labor: • Staging equipment and verifying functionality. • Off site system equipment assembly and testing. VSI Proposal for City of Columbia Heights, RFB - Council Chamber Technology Replacement Page 5 f Installation Labor: • Cabling and terminations for equipment. • Tech plate installation and termination for various locations in the room. • Installation of all components, speakers, racks, interconnects listed in this proposal. • Adjusting, balancing, and calibration of all video and audio settings. • Testing of system inputs and outputs. • Configuration of all control system components. • Quality control. • Daily removal of all trash and site clean up. IV. Quality Assurance • VSI will meet or exceed all specified requirements of RFB. • Video system to be tested and aligned with video generators. • VSI prides itself in providing the client with detailed training by supplying essential operating manuals, maintenance schedules, hands -on client training and periodic follow up. Likewise, VSI requires all associates to maintain their credentials, product training and encourages "leaning forward" in staying ahead of the technology curve. V. Payment Terms • As per RFB. VI. Warranty VSI warrants the system fumished to be free from defects in workmanship (i.e. cables, connections, structures) failure for a period of one (1) year from the date of acceptance. Warranty period on equipment shall start on the day of system acceptance by the Owner. Manufacturer warranties on equipment are of varying lengths. Equipment warranty after 365 days shall be in accordance with individual manufacture factory warranty. Warranty applies only to equipment sold on contract through VSI and does not include existing or owner furnished equipment, Warranty does not apply to any product that has been subject to misuse, neglect, accident or operational error. VII. Telephone Support Telephone support is available during normal business hours, 8:00 am — 5:00 pm, Monday through Friday @ 507 - 625 -1650. Emergency 24 Hour telephone support Mike Kimes @ 507 - 420 -6142 (project manager /technician) Travis Dahl @ 507 - 995 -1169 (project manager /lead technician) VIII. On -Site Support . VSI can offer quick response on normal on -site service calls. Every attempt will be made to conduct repair on -site without removal of critical equipment. VSI will provide loaner equipment when available. VSI Proposal for City of Columbia Heights, RFB - Council Chamber Technology Replacement Page 6 ifn) * * 03C-0 Zi*Mg< "IC -- 0 00CD * * Ci) K CD W 0 C° cx) r c a) a) 0) - 0 0 9 0 5 0 - a - * 9_ . - 0 5 FD ---- c) (17 Fp c (1) c (f) c a ' ) 0 : 0 " F., 7- CD = a) -, (,) st) = a) fl) 0 0 a) a• --.- co - co - - c c = Efi (.2 0 'es, ,< 5- 0 0 m ? = g 0 ao - a) - a) g 0 =Z c K t g g g R. (1) o fir 1 i c .,... 0" X' (0 X' z - "'"••• ' - ,.... CD CD CD CD -- (n m Z 4 0 -• SD D" a) Z -.- gKg zco - cn =.• 7- --- -.- = a) al 7j• ( < 0 ° n) '" CD I c It W O ZI CD 0 Z 5 = o 0 - », CO D 0 .-4. 0 D 0 c- --. 0 - = _ < • = ... CD CO C •:<"'`' 0" 0 a) ,. a) 0 0 0 = K = - 0 ( D a = - = = ..< o (D < ,-.0. (D CO - -1 - CD Z (/)>Z KWZ>Z CnZFP Z -100)C0 cuU)Z0Z> < < (nZ03Z>0 10Z 10> o c (1) 0 0 CD C 0 < 0 - 0 0 0 < < CU < (D 11) (D c a a C a 4.. * ol °- (D (D a- m 5 CD c F 'Ci CD s - 0.. (i g ( a 00 Z 03 3 (fl g (1) u =-° 3 .--.- 3 ( D (D " 3 w u) Eli co 5 9 9 a) 3 D C) 0 CO ci) C ,... C 0 0 0 (1) CD 0 03 03 --- __. 9 . c- CD D" ° (1) I I =C =.....• , , . Z C C , CU = ,,,, ea C .. Q. 0 ( 7 ) s< -3 1--, "1 0 D 0 ---• 0 0 0 0 ..... --■ D - 0 u '' -• 3 a) 0_00 04.5- >on,o (au)0%-'aT 07 a) a 0- 0-> o o 3 (0 c t 5 = , --4 , a .- (1) 0 . 0 . n 0) c 3 , -I , a. ' -4- ' co CD -1 7.4. - ' 0 1 0 3 0 0 ‘< 0 Q.) • 3 5c a) > "I) "< (n - tu a) - 0 0 a) c 74' OaTri") 0 0 CD 7, p ..< C U) 0 u w C CD 3 0 CO N. . 3 a i . m _ (,) 0 *3a. cf) >430 ,(/), c , ) 8 0 CO 0 • 30 0c2.00 00 E r ., - 5 5 0 > E a , ,.. ,..< c 0 m c n . a ,.... ,.., 0 -, 0 S 0 Z - g a 0. cn u) 0. ] ,-, a) a ("3 o r" a . 3 .... 7 CD _ -• u) 0 -••• ,•-••• .--. 1/4 . ,D „, . = 3 5_ c - o -, SI) "> --, -t --t ---•• a) 5 -, - 0. C 5 = (n 0 ii. = o , 0 0 ,,., o oco a. -, (D (1) 0 o 3 0 CD .< x.". 4 CD CD * 40 732W O. 3(D acCia 'a- .....' - 0> 0 D CO 0. > 3 cn -0 tu > 0 ...< > 0. = -, -.' 5 ° -, - 0 .< c 0 - 0 - 6 , 0 '(".i3 c 0 0 En c Cn o' ,....- 3 9_ w 9_ 90 -4, 0 0 0. ta a c co cf) 0. SD_ .---• CD cn Q. 3 5 co ct. '..< ' ( I ) ,•••• - • = ,,, 7.,. 2: co ,,,.. o 41) cry Qo -i a 0 6 = - < 0 (D 6 a v,5 o a o H 3 .....• LJ -•••• -, 0 0 < c = CD 17- 3 - ...< CD ■•••• Qt. 3 -4. a) • f n o ..1 c ,)- a n) = c -.. -• c a) c a u) 0 (D CD 0 0 Cl) 3 0 = - 0. (D > 3 3 3 0 a 30 3 .11IMM. ert 0.- IV i 3 cn CO 0 C (f) X Cn o 3 13 a) G) o __Q: 0 0 o u) ...< - c 0 c o c 23 3 c o_ = a. 3 c o. 0 73 M C3 U) * 03 13 03 U) < CO cn co w < < < co cn < - a cn < *ri *m C- o cu o '..< ci) o ....< 0 ..< U) (f) (/) 0'< (I) CD D'' (/) = a 5 = F•D- m 0- D - ct 0 0 0 - - CS D - 4 I 1 1 CD CI) > cn (D CD CD -°=" a a (1) C 0 i 0 0 -, 0 -, CD 0 0 0 , n , = 0 0 90 0 9 -A 9° a .- r o > _ 3 , cD„ . .- cn cri c i ) 1`j CO (D) CD a) CI) 0 CO CD 0 K CD 3 > > 3 , 0 En - U) • - % * En * * ( 7 ) cn cn * 6 (1) = - 0) _ ...., .... owl ii) 9- 3 " 0 = ( ( c co 53 ( or-:'.( - o (6 " 0000= D = 00= 0 = CO 0)0 "DI u ); 0 0 Z CD C c C CD CI) 0 0 e -g . w a 0 CO 0-0 03 CO 0 - 0 cf) 3 03 , - 5 5 m .....1. (0 (fl cl) P. 0 (D c (D D < C ,..., ,..... c CD U) Cn 0 U) 0 U) -- U) (fl= ' U) Z < ' CD CD •in 0. 0 --) . c o- a cp a. 0 5. ( E-, E. a. E. ( 5. _ = " u) 0 0 0 9. CD CD 5 m = > m > ro 7) - > > c - 0 to u) co co u) • u) co co co m 0 o o o 0 m o 0 0 ID • ' ' < Z o. --4 C) 0) "V 0) or) 0) 0) col col (7) 0) 0 01 01 0) 0 o -.a o al - _, a -4. -.4. o c) o --4. o o CD (7) al m co _. col no -.1 NJ IV V 'V V Ni V --.1 --, - 7 4 '7' . '0 ci) V' . . . . . . , , . 0) V V 6) 0) CD 'V 0) 01 0) 4). .1),. Z" CD 01 r..) co 00 n.) oo op Ni Ni Iv op Ni Ni Ni 03 (A) 0 4 (J) (A) 4 --' Cr1 ). -.. 01 (11 01 -- 01 - -.1 Cr) C) CD = 6, _ at 1 . . - t . I . . 1 .* ' -P. CD -..,. c) 0 -a -.A. -. C) --a --a --, ND Ni CO 0) 00 CD 0) 0 CD 0) 0) 0) 0 0) Cn 0) --..1 --.1 4t 0) o 4 (rE CA) al (.3 c.,.) al Cri CT CA) 01 .. C71 V V CP CD 0) CO 0) CD (.) CA) (3 0 CD CA) 0 C71 0 Ni ND CO > 0 CO 73 0 (/) 0 g cp c- c- 0 (/) 0 0 m - cp (D a) a) o o o cu c a 0) a o =.- CD ....• ...... CS fir -, c 0 -, < 4 „u) < o rIr so cr, CD 1 cn c_ Q . i = 7:i o G) a) w 0 CI) CD 0 CD a) a) co 0 e 1:3 3 ...... co CD Pc" "0 - w (0 ))•' a) o -, (0 5 sx., CD CD 3 (D 0 D = c " cr CD 0 c ...< 3 o re* = 0) 0) rs.) 01 CA) CI) CO CA) Cr) CO CO 4 al (.31 cri 01 (71 0) Ni C) --I CD Ni a Cr) Ni 0 01 01 CD 0 0 0 0 CD 01 03 n) V C) V IV 0 "V NJ Ni - '• V - 4 V V V Cn ...., 0 1 1 -.1. 1 1 1 1 1 1 (.11 ■ 1 i 1 P I .• Ni 03 03 cz) Ni 01 6 CO CA) 0) 00 N.) co 0) 03 03 (A) oa Ni 7 cri co Iv c....1 o 03 01 . . 0.1 0) 4 V CO 0) CO 03 .1). 03 01 0 0) _.„ .4 IV 0) ^-4 01 CA) CP GO Ni 01 OD CO CA) -1). CO 0) . c 1). ■ CD ..., 1 I 4 03 1 t ■ I i 11 i CD 'V 4 C.)1 -4 CA) - •••••‘ (31 V V 01 CD V 0 0) 4 0) 0) 0) 'V C) (P 4 0) V 03 0.) Ni IV 4 (0 'V _., -). 0 CO 0 CO --, Cn 03 CD 0) CO .4. --, Ni O 01 CD - CD 0) C) --, --). 0) 0) 01 0) 0 N.) 0) ND IV NJ Ni Ni IV Ni N.) Ni Ni Ni IV Ni Ni Ni Ni Ni Ni -< co o a o a a o o c) o a o o c) c) c) 0 0 c, t0 0 0 0 a c) o o a o o c) o -» _., _, 0) 4 4 0) -V CO CO CO 00 CO CO CO CO CO CO 0 0 0 60 V) if) tA 69 69 64 4,9 EA 6f) -CF) EA 69 Ef) -4. --a __, IV _, _, IV N.) Ni __, Ni < oo 0) o 0) _ o col a oa --, Ni Iv co 07 00 0) o) CA) CO - -4 4 N) --4 03 (A) Cr) --. Ni 0) 0 03 0) )). 07 "'""' .. .. _ .. - C MO 0 CD CT) C..) CD a) o o co 44. a -tb. o co c..) -D. co o a.) CD CD -a oo CO 0 0) 0 CD CD CO CO 0 NJ 0 CD 0 0) 0 0 o co co CD CD CD Pc9C;NX It MINNESOTA. DEPARTMENT OF '., LABOR 84 INOUsTRy TECHNOLOGY SYSTEMS CONTRACTOR LICENSE Construction Codes and Licensing Division Licensing and Certification Services PO Box 64227 St. Paul, MN 55164-0227 VVebsite: www.doli.state.mn.us E-mail: DLIALcAL.._@1se .g.ge-,914' Telephone: 651-284-5031 Company Name: VIDEO SERVICES INC OF MANKATO Address: 1227 CALEDONIA ST MANKATO , MN 56001 License Number: TS00648 Effective Date: 08/01/2010 Expiration Date: 07/31/2012 STATE OF MINNESOTA POWER LIMITED TECHNICIAN STATE OF MINNESOTA i POWER LIMI .;'11-9irst6-, i' 4 ?''''' TED TECHNICIAN Licen # PLO 1575 ---)11kr''''.---. ....t 9 , -•,_, „*. t Expiration Date 05/19/2011 ' 'k ) License # PLO 1573 ''.- • "1,, ii . I Effective Date 05/14/2009 k:4-i," Expiration Date 04/10/2011 Effective Date 05/01/2009 TRAVIS N DAHL 108 SPYGLASS DRIVE TERRY G DAHL MANKATO, MN 56001 1227 CALEDONIA STREET MANKATO, MN 56001 0 m m n.� x, r yy p+ pig of n � . 'g , T Thousand `° h S N Sl Td y { r i ron E '' � [CAL `It ; c hi a 1 el of .,,,f'',' -i T 2 t ,; 4� Cy ` Y r .}�3 f I t D { l ' f I N E _ l "Eh4. - -i 5' 5 "J ,, • a Columbia Heights Council Chambers Technology RFB APPENDIX A — EQUIPMENT SCHEDULES AUDIOVISUAL Desig Description Manufacturer Model Qty Unit Price Ext. Price MIC Modular Microphone Element AKG CK47 13 df) -7) 3 )'/,0 MIC1 Gooseneck Section AKG GN30E 13 / 6 E'It, 2 1Z -Sb N./11C1 Shock Mount AKG HSO0 13 35.ts `f6b.oc MIC2 Modular Microphone Element AKG CK31 1 & •5S & • Sf, MIC2 Gooseneck Section AKG GN30E 1 1 P, . G 6 . j &e ,16 MIC2 Shock Mount AKG HSO0 1 `3c b 3S 5 WMSI Wireless Mic Combo Audio Technica ATW -3131b 1 3 -/5 , SI 3 S - S i WMHI Wireless Handheld Audio Technica ATW -T371b 1 Z L, I I Zbt, • 11 DSP1 DSP Mixer Lectrosonics DM1612F 1 303 & . cx - c 2 )() .Q L DSP2 Mixer Control Interface Custom See Specification 1 SUS , S5 AMP1 Power Amplifier QSC CX108V 1 1 Z Z)S SI t 2_3S - CI SPB 1 Loudspeaker 70V ElectroVoice 301045 -004 11 i 1 -1. 6 1 0 I 9 13 - `I© ALSI Assistive Listening Transmitter Williams Sound PPA T35 1 L i`j y.)u z1639 . 70 ALSI Wall Mount Antenna Williams Sound ANT 024 1 ( I - 3y (31 . 3y ALSI Rack Mount Williams Sound RPK 005 1 3 6 1 .(e0 3`1 - h c ALS2 Assistive Listening Receiver Williams Sound PPA R35 -8N 4 1 0 3 ' 1 1 q13 -I b ALS3 Headphone Williams Sound HED 026 4 I 5^4 S '0 t t' ALS4 Neck Loop Williams Sound NKL 001 l 5)- 34 3 . 3(-1 ALS5 Sign Williams Sound IDP 008 1 Z ""f . (✓ Z CLR 1 Compressor Limiter Behringer MDX1600 1 fj ). L ?A) Z `1 DVC 1 Divider /Combiner Radio Design Labs STD-10K 1 'i cc) 3`1 • TO MONI 40" LCD Monitor Sharp LC- 40LE810UN 2 7 10 115 - 1 - MON 1 Mount Bracket Chief Mfg LSMU 2 1 1 • Z1 Z j (Q ." MON2 40" LCD Monitor Sharp LC- 4OLE810UN 1 6 - 5 , - 90 & 7 E `( b MON2 Monitor Cart Chief Mfg PFQUB 1 U u°1 •Z 1 L-10q - MON3 40" LCD Monitor Sharp LC- 40LE810UN 2 6 B to 15 - 7- to MON3 Mount Bracket Chief Mfg MWRUB 2 z By • 53 ` CAM1 PTZ HD Camera Vaddio 999 - 6907 -000W 4 3!S) I S 3/., c SWBI Switcher& Cam Controller Vaddio 999 - 5200 -000 1 79 (,C -7 0 1L9 6h :76 MIP1 Multi -image Processor Roland MVS -12 1 19‘;7-1Z. 1 `152 1Z MONO Control Room Monitor Sharp LC- 40LE810UN 1 € b •90 31g '10 SCNI Scan Converter TVONE C2 -1100 2 0 j • I Z-uT ,)-y SCN I Rack Mount Kit TVONE RM -220 1 ( - )-7 qt Z7 SCAT Scaler TVONE C2 -1200 1 C Iy5.1,7> c(' -(S13 SCA 1 Rack Mount Kit TVONE RM -220 1 U18 . 2_1 y g )--1 VDAI Video DA Extron 60- 439 -01 6 t 1 0 ©o (p (gyp ,0,; VDA I Rack Shelf Extron 60- 190 -01 2 `J (•So H3 . VDA2 Video DA Extron 60- 446 -01 1 13")...uo ( c• LOGI Graphic Still Store Extron GSS100 1 Sib -70 Pj to ,10 LOGI Rack Shelf Extron 60- 190 -01 1 1 1- c0 - 1150 CGE 1 Character Generator Compix ConverG l 1 1p Gj q 5 ■oo (q (2y S -c 3 PVR1 Video Recorder MVIXUSA MX- 880HD1500GB 1 7 c l - 7fl J FA Elert & Associates Appendix A - AV Equipment Schedule 62 Columbia Heights Council Chambers Technology RFB PVR I 1 RU Custom Rack Shelf Custom As Required 1 C ?' < L.,. Gu MONS CG Monitor Viewsonic VG2028wm 1 I `!t. C.`1 [ 7 V/ MONS Monitor Bracket Chief Mfg KCD100B 1 I Z,% z ci / Zc - 2 CAM2 Video Camera Panasonic WF -CF284 l L "I S c C, Z'/S- VC CAM2 Mounting Bracket Panasonic As Required 1 7 L - e /5 76 '1` CAM2 Power Supply As Required As Required 1 IC c, 4 • S6 VSSI Broadcast Controller Tightrope Media CBL- Cablecast- Bundle 1 `/`7O& . `� 100 . 0" VSSI Cablecast Bundle Warranty Tightrope Media SA -Gold 1 f,zs - L e2 T.---- VSS2 Video Server Tightrope Media CBL -SXLE 1 6' t)( `/ - i- ( VSS2 SXLE Warranty Tightrope Media SA -Gold 1 / £ /s "- () (() IS. ; VSS3 Character Generator Tightrope Media CBL -CG310 1 ZY.t; . ' 2 t) ( - ) " 0 VSS3 SDI Card Tightrope Media CBL -CGSDI 2 7eV. 0 / S 7 3 LL, VSS3 CG310 Warranty Tightrope Media SA -Gold 1 55(_: .: 336 .cO VSS4 Onsite Training Tightrope Media SVC -ONH -TRAIN 4 1 V-1 - c 646 0o VSS5 Onsite Service Tightrope Media SVC- ONH -INST 4 1 St{. ci,.; l6_ MXV 1 Video Matrix 8x4 Extron 60- 554 -31 1 S SG < ,.) S S v MODI Modulator Owner Furnished Contractor Installed 2 OFCI OFCI SWSI System Switcher Extron 60- 569 -01 1 j 013 `le i C 1:3 -50 SWS2 System Switcher Extron 60- 532 -01 1 y6Z. ,- L I&Z ao UTX 1 UTP Transmitter Extron 60- 669 -01 1 1.-Z 7 - 7e3 Z Z 7. 70 UTRI UTP Receiver Extron 60- 690 -02 1 (--01 10 Y%6 (0 DOCI Document Camera Wolfvision EYE -12 1 c i 27z `is - /27Z `ls CNK 1 Flip Top Interface Crestron C2N- FT- TPS4 -B 1 l o /C , l0 HDA l Cable Adapter mini -DP to HDMI Monoprice 5311 I L° 73 ( ° HDAI Cable Adapter mini -DP to VGA Monoprice 5107 1 I (.. G 3 E .� - HDAI Cable Adapter DVI to HDMI Monoprice 2029 1 2 i 1 I It HDAI Cable Adaptor DP to HDM1 Monoprice 4826 1 6- • `1; C HDAI Cable Adapter DP to VGA Monoprice 5135 1 f G `7 It 1 DVV 1 DVD /VCR Combo Unit Panasonic DMR- EZ48VK 2 Z 7& - z z f ) - 5 - 2` - ft./ DVV 1 Custom Shelf Custom See Specification 1 I 1 c0 . c 1( 0 . v0 DVVI Rack Shelf Middle Atlantic U2V 1 -'; 7 4 S 37 i` 5 - XDAI VGA DA Extron 60- 506 -03 1 i 2 (a co 1 Z, -SC. UTX2 UTP Transmitter Extron 60- 652 -01 1 z-t • o) Z br -_ CSC) UTX2 Rack Shelf Extron 60- 190 -01 1 7 1 . Sc 7/ -S UDA1 UTP DA Extron 60- 686 -01 1 01/ 3e 6L// 30 UTR2 UTP Receiver Extron 60- 735 -01 5 3 52.20 Ito 1 o'u CPL 1 Connector Panel Custom See Specification 1 C o ao 6G o SL) KVMI KVM Switcher NTI UNIMUX- USBV -40 1 667 v7 06'1'17 ICS I Control Processor Crestron CP2E 1 '-'/() 0,. c /1� 0) ICS1 Power Supply Crestron PW- 2420RU 1 / 37 S - 3 1 so ICE1 IR Emitter Crestron IRP2 2 Z7•s,_"= 5S t-u IPDI Wireless Touchpanel Apple iPod 16GB WiFi 1 5 ? 599,`77 IPD1 Mobile App Crestron Mobile Pro G 1 10`1 ( 7) / O`% 4 RCK I Equipment Rack Winsted V8801 1 6 `%U 67.6`i 1e FRNI Double Bay Stringer Winsted 56004 1 7(b- /0 7 / t 10 Elert & Associates Appendix A — AV Equipment Schedule 63 Columbia Heights Council Chambers Technology RFB FRNI 6RU Rack Cabinet Winsted 56032 1 Z 31 • w Z 3 FRNI Single Bay Hinged Cover Winsted 56042 1 7F,59 7i: S FRNI 27" ABS Filler Winsted 56981 1 S `7o' 5 c FRNI End Frame (pr) Winsted 56061 1 iy. Z i 5 2 FRN l Bottom Shelf Winsted 56082 2 t'. & S 1C-1 - )0 FRNI CPU Can Winsted 56220 1 ' - L''t `-1 qc m`2.% FRN I Work Surface Bracket (pr) Winsted 56262 2 7 > -1 I Si . FRNI Vented Door Winsted 56302 4 Z Z « 3 • 12 -- FRNI Side Panels (pr) Winsted 56520 1 ccS. 12 5c- S . ) 2 FRNI Work Surface for 56220 Winsted 56620 1 L, 7 "76. . 7C, FRNI 48" Work Surface Winsted 56624 1 Z g c L 7 c - - 0 ) FRNI 2 Pole Monitor Mount Winsted W5690 I 775 3`i 775 3'1 FRNI Rack Kit for Sight Line Winsted W5642 2 ZS'(. - 0 CO 5Y, RKBI Rack Blank Middle Atlantic BL1 22 ( /- I3 ZSI `I 0 RKB2 Rack Blank Middle Atlantic BL2 3 i 2, CO LI0 Liz PAC] Power Sequencer Middle Atlantic PDS -615R 1 7 -7 7- 76 Z - 77 .L; PAC2 Power Distribution Middle Atlantic PD-14 I 5C-NS 1 i t ` ///,-1-2 • PAC3 Power Distribution Tripp Lite 602 -15 4 2'1. cry 4 - 7 /L. UPS1 UPS APC SUA3000RM2U 1 !I ', c //3 MON6 40" LCD Monitor Sharp LC- 40LE810UN 1 5 i 7Lr ` ic MON6 Wall Mount Bracket Chief Mfg LSMU 1 / 1 6., 7/ i/ t 2( PLT6 Input Plate Custom Custom 1 f / c , i (0 . 0 - LIB 1 Camcorder Canon HF -S20 1 `7 3 /, )% 7 S L 1 % 7 LIB I SDHC Card 16GB PNY P- SDHC16G4 -EF I % )6 `l. lc LIB2 Tripod Smith - Victor 700005 1 - L 0 S . `7 5 c>i. . yS" LIB3 Camcorder Case LowePro Edit 140 1 (ts 5 / 6. !c s LIB4 Microphones Adapter Beachtek DXA -2T 1 1 / - / `% l L k' LIB4 Mic Cable Shure C25B 1 (5- 'c- / 9 66 LIB4 Microphone Shure VP64A 1 (e -7x) 0,c /, 70 Misc. Parts /Cabling/Wire 1 S I3 7/ `)I :S5. 1 Installation Labor 1 ) L l ZL . ") 15 , ©(l Control System Programming 1 5 coa '),- (. All Other Costs 1 - 7o9 75& i8 Sales Tax 1 0 5'J$ -/.35 6-5S 3`: Subtotal 1 7N,2 56 IN Elert & Associates Appendix A - AV Equipment Schedule 64 TPS -4L IsysTM 3.6" Wall Mount Touchpanel Graphic Engine TPS/TPMC -4L -FPBT: Engravable Faceplate, Butter Isys engine; 16 -bit non - palette graphics; 65,536 colors; Synapse image TPS/TPMC -4L -FPCR: Engravable Faceplate, Cream rendering algorithm, multi -mode objects, dynamic graphics, PNG TPS/TPMC -4L -FPEC: Engravable Faceplate, Ecru translucency, full- motion (60 fps) animation TPS/TPMC -4L -FPMS: Engravable Faceplate, Mustard TPS/TPMC -4L -FPSM: Engravable Faceplate, Smoke Ethernet TPS/TPMC -4L -FPST: Engravable Faceplate, Stone 10BaseT /1O0BaseTX, auto - switching, auto - negotiating, auto - discovery, full/ TPS/TPMC -4L -FPW: Engravable Faceplate, White half duplex, TCP /IP, UDP /IP, CIP, DHCP TPS/TPMC -4L -FPWH: Engravable Faceplate, Wheat BB -4L: Pre - Construction Wall Mount Back Box Audio PMK -4L: Pre - Construction Wall Mount Kit Hardware Features: Built -in amplified speaker (rear), internal volume control TMK -4L: Trim Ring for BB -4L and PMK -4L Audio Feedback (WAV): 8 -bit PCM, mono, 8 kHz sampling rate MMK -4L: Mud Ring for BB -4L and PMK -4L Amplification: 1 Watt for built -in speaker WMKT -4L: Post - Construction Wall Mount Kit w/Trim Ring Connectors WMKM -4L: Post - Construction Wall Mount Kit w /Mud Ring WMKB -4L: Replacement Wall Mount Clips NET: (1) 4 -pin 3.5mm detachable terminal block, Cresnet slave port; CRESNET- NP- TL- SP500: Cresnet® Control Cable, non - plenum, teal, 500 ft Connects to Cresnet control network spool LAN: (1) 8 -wire RJ45 with 2 LED indicators; CRESNET- NP- TL- SP100O: Cresnet® Control Cable, non - plenum, teal, 1000 10 /100BaseT Ethernet port; if spool Green LED indicates link status; CRESNET-NP-TL-B250: Cresnet® Control Cable, non - plenum, teal, 250 ft Yellow LED indicates Ethernet activity box Power Requirements CRESNET -NP -TL -8500: Cresnet® Control Cable, non - plenum, teal, 500 ft box Cresnet Power Usage : 5 Watts (0.21 Amp Q 24 Volts DC) CRESNET -NP -BK -8500: Cresnet® Control Cable, non - plenum, black, 500 ft Environment box al Temperature: 32° to 104 °F (0° to 40 °C) CRESNET- NP- OR -B5O0: Cresnet® Control Cable, non - plenum, orange, 500 Humidity: 10% to 90% RH (non - condensing) ft box CRESNET -NP -YL -8500: Cresnet® Control Cable, non - plenum, yellow, 500 ft Enclosure box Construction: Injection- molded plastic, flush- mountableusing clips provided CRESNET P TL SP5O0: Cresnet® Control Cable, plenum, teal, 500 ft spool (additional mounting kits available) CRESNET- P- TL- SP100O: Cresnete Control Cable, plenum, teal, 1000 ft Faceplate: Injection - molded plastic spool CRESNET- P- BK- SP500: Cresnet® Control Cable, plenum, black, 500 ft spool Dimensions CRESNET- P- OR- SP5O0: Cresnet® Control Cable, plenum, orange, 500 ft Height: 4.54 in (116 mm) spool Width: 6.19 in (158 mm) CRESNET- P- YL- SP5O0: Cresnet® Control Cable, plenum, yellow, 500 ft Depth: 2.13 in (54 mm) spool CRESNET- HP- NP- TL- SP5OO: Cresnet® "High- Power" Control Cable, non - Weight plenum, teal, 500 ft spool 15.0 oz (0.43 kg) CRESNET- HP- NP- TL- SP1OOO: Cresnet® "High- Power" Control Cable, non- plenum, teal, 1000 ft spool Avaiiahle Models TP -4LA: Is a 3.6" Wall Mount Touchpanel, All ' 1d TPS -4LB: Isys® 3.6" Wall Mount Touch lane) Black TP ": sys® 3.6' all Mount Touchpanel, White Included Accessories TPS/TPMC -4L -FPA Engravable Faceplate (blank), Almond [Included Quantity for TPS -4LA: 1] TPS/TPMC -4L -FPB Engravable Faceplate (blank), Black [Included Quantity for TPS -4LB: 1] TPS/TPMC -4L -FPW Engravable Faceplate (blank), White [Included Quantity for TPS -4LW: 11 Available Accessories TPS/TPMC -4L -FPA: Engravable Faceplate, Almond TPS/TPMC -4L -FPB: Engravable Faceplate, Black Contain ics Volvo 0xivctRoc " 7, 41 F .7672400IFa� 20'.7671905 N 414 tr-ib . _ . . . . . , - - .. .... ... .. * , f DSKB- 10 G TOP VIEW ACCESS HOLES FOR SURFACE-MOUNTING TOP VIEW WALL PLATE SCREWS (BOTTOM PAN NOT SHOWN) 294 OPENING SURFACE VIEW , et* 01 10 WALL PLATE 294 OPENING SURFACE VIEW ACCESS HOLES FOR 111 1 11 --- SURFACE-MOUNTING F•33., 3. (2 9*37 MOUNTING HOLE eg g SCREWS (BOTTOM PAN 040 / )*1' . NOT SHOWN) 0 ) N3 3 41 - I 0 ply4p, 5 22 — (4)46-37 MOUNTING HOLE 7...(y . REAR VIEW 41) • / 2 25 REAR VIEW 1 / , 4. _ 406 OPENING i 3 73 WITH OPENING 1 OPTIONAL 3 64 •; BUMPERS 3 1 3 73 WITH OPTIONAL 3 64 BUMPERS i 1 1\ P5 80200 PROVIDED -- END VIEW --.-- 4 48 --.- P5 80200 PROVIDED END VIEW (PASS THRU 2 312 D BUSHING) (PASS THRU, 2 x 312 ID BUSHING) , x ; BOTTOM VIEW (41 SUPPLIED BUMPERS USED AS ANTI-SKID FEET BOTTOM VIEW 0) SUPPLIED BUMPERS USED AS ANTI-SKID FEET (NOT USED WHEN SURFACE-MOUNTING) (NOT USED WHEN SURFACE-MOUNTING) ' I ' 3-3/8 SURFACE- / 31- 1 I 33/8 SURFACE- , MOUNTING HOLES / / - F. 1 MOUNTING HOLES //) I ' I i - w , / 4 9/ -C 7 . 5 4 8 ' —111 / t -3F„„, / L 58 gip' I-518 •,, -..,,, 1 20 -----.-1 -.-- --- 123 ----•- -7.-- —123 1 20 1 00 SURFACE I MOUNTING HOLES ( 0068-1G SHOWN L2)3/4 SURFACE 05413)20 SHOWN WITH WALL PLATE MOUNTING HOLES WITH WALL PLATE (NOT PROVIDED) (NOT P00010001 - REMOVE SCREW AND BOTTOM PAN - REMOVE SCREW AND BOTTOM PAN TO USE SURFACE-MOUNTING HOLES 00 003 SURFACE-MOUNTING HOLES DSKB-3G DSKB WALL PLATE 294 OPENING SURFACE VIEW WALL PLATE 311 ----3, • • OPENING SURFACE VIEW TOP VIEW 'FOP VIEW 0 3 t o ACCESS HOLES FOR 1 11 11-1-ssxy 8 0 t to ACCESS HOLES FOR SURFACE-MOUNTING N...... ..' ----08 8 __ SURFACE MOUNTING SCREWS (BOTTOM PAN NOT SHOWN) SCREWS (BOTTOM PAN /, NOT SHOWN) 1 es se • es x ze - ffi) 06 MOUNTING HOLE - *106-32 MOUNTING HOLE / , -.-- 7 03 ."-1 7 , ----------___ 1 — – 8 84 -- 1 i 1 / P5 80000 PROVIDED . • / IPS-80000 PROVIDED . • • 769 (DOUBLE SPACE BLANK) / - OP5E8N7ING (DOUBLE SPACE BLANK) / i ' t OPENING REAR VIEW i / REAR VIEW 1 / 373 WITH f / .„ 3 73 WITH BUMPERS OPTIONAL 3 64 / OPTIONAL 3 64 r---,,, 58 j BUMPERS t-0-0! ri i 58 END VIEW END VIEW ' -- 4 48 --,-- 4 48 -,-- - ---,.-- I) IPS-8020D PROVIDED PS 80700 PROVIDED (PASS THRU, 2 x 317 ID BUSHING) (PASS THRU, 2 x 31210 BUSHING) BOTTOM VIEVV 14) ANTI 0410 FEET BOTTOM VIEW (4) SUPPLIED BUMPERS USED AS ANTI-SKID FEET (NOT USED WHEN SURFACE-MOUNTING) leeniMEMESINIMEM • " ----- 1 1 i 3-3/8 SURFACE- / ...,,....., 3-3/8 SURFACE / - --,,, i ' MOUNTING HOLES MOUNTING HOLES Ilir --,.,.. I , , ■ , .....,--- --.-------, . . ■ir ..... ...,. ...„.„..,„,,, e „. 1 L5/8 -,,,,.......-„,, . L518 1 27 --.- -.--1 27 1 30 -----1 30 \_4-1/2 SURFACE SURFACE- MOUNT HOLES MOUNTING HOLES -- D5KE3G SHOWN WITH WALL PLATE REMOVE SCREW AND BOTTOM PAN D L REMOVE SCREW AND BOTTOM PAN (NOT PROVIDED) TO USE SURFACEMOUNTING HOLES TO USE SURFACE-MOUNTING HOLES (NOT PROVIDED) EE ;Ss ' 1E11- * tE 1,1313 F E. 7,3 E H 3 X * st - )3 " "Se 4" 1 3.• 13, 34c1- 1*73') '1r 30 **0 Es F11572:33 MADE IN 7 244 Bergen Boulevard, Woodland Park, NJ 07424 THE USA GREEN '1V Phone: 973.785.4347 • Fax: 973.785.4207 Web: www.fsrinc.com - E-mail: sales tofsrinc.com Specifications are subject to change without notice. TPS -6 s sT 5.7" Tilt Totichpariet The IsysTM TPS -6 Tilt Touchpanel delivers high -end style and performance in a striking tabletop design. Sleek and compact, the TPS -6 does away with piles of remotes and cryptic control panels, affording true "one- touch" control over a broad range of complex — devices and systems. Featuring a bright, beautiful, high- contrast color touchscreen, and a smart array of backlit tactile r► pushbuttonsili the TPS -6 offers an ideal user - interface for 0 controlling multimedia presentations, home automation, and a host of uses. v yv IsysTM Color Touchscreen The TPS -6 provides a wide open canvas for the creation of custom '� " "... control screens tailored to each unique application. Its brilliant 5. 7 1. " active - matrix display and powerful Isys engine combine to produce stunning 16 -bit color graphics with extreme versatility and lightning -fast performance. Dynamic graphics and text capability enable the display of all kinds of useful data and alluring eye candy —from audio settings, TV channels, and lighting levels —to changing icons, photos, and logos —to digital media playlists complete with album cover art. communications and video capability. Both high -speed Ethernet and Cresnet connectivity are available. The screen tilt can be freely Crestron exclusive DNav and SynapseTM technologies enable system adjusted or locked down at up to a 45 degree angle for optimal viewing programmers to produce amazing graphics faster and easier using and operation. A single cable exits the rear of the base, extending advanced dynamic control menus and 3D effects. Additional capabilities to a wall or surface mounted TPS -6X -IMCW Interface Module[ The like animations, multimode objects, PNG translucency, and full - motion cable can also be repositioned to exit the bottom for a very clean, video[ enhance the palette for creating GUIs that are both cordless appearance. A swivel mount kit is also available for eye- catching and easy to use. fixed -mount applications that require the ability to rotate the touchpanel during use. Tactile Pushbuttons In addition to its touchscreen, the TPS -6 features illuminated tactile pushbuttons for quick access to volume adjustment, channel selection, > Sleek, contoured design for tabletop use and on- screen menu navigation functions. Eight additional pushbuttons, elegantly trimmed by illuminated button dividers, flank > Full wired touchpanel operation the edges of the touchscreen to support additional programmable > Elegant high gloss black or white, or matte black finishes functions. > illuminated buttons and engravable backlit text('] High - quality backlit laser- engraving lends a crisp, legible appearance to button text in both darkened and fully lit roomsi'l. The > 5.7" active matrix color touchscreen display pushbufons come pre- engraved with labeling suited to a typical home theater or multimedia presentation application. If needed, customized > 16 - bit Isys graphics 640 x 480 resolution engraving can be attained simply using Crestron Engraver software. A no -button front bezel is also included with the TPS -6, which may be > Dynamic graphics & text capability installed in place of the button bezel for a very clean appearance > DNav dynamic menu objects with no front panel pushbuttons. > Synapse image Rendering Algorithm Two additional "trigger" style buttons are positioned on top of the TPS -6 for easy control of the display brightness and other > Full motion video display programmable functions. > High - speed Ethernet and Cresnet communications Full- Motion Video The TPS -6 displays full- motion video, providing the ability to monitor > Crestron Nor CATS video connectivity a security camera, or preview a DVD or television channel, right on > Up to 45 degree tilt adjustment the touchscreen display. The video image is fully scalable for viewing in any sized window or full screen. The choice of balanced or > Low profile single - wire connection unbalanced composite inputs allows compatibility with both conventional coaxial and Crestron Home® Balanced AV distribution > No button front bezel option included systems. TableTop Tilt Base With its sleek and innovative tilting base, the TPS -6 functions as a stylish tabletop tilt touchpanel, providing full -time wired m µ utviivr.crestran-com =237 { $ ° TPS-6 � ��xm Tilt ��������eU ^ ~ ~~ `° ^~��"~ ~~~" " ""^ Touchpanel Cresnet Power Usage: 16 Watts (0.67 Amps @ 24 Volts DC) including SPECIFICATIONS TPS-6X-IMCW module] Touchscreen Displav Note: May be powered by power pack or Cresnet network power, not both. Display Type: TFT Active matrix color LCD All power connections are made via the TPS-6X-IMCW interface module Size: 5.7 inch (14.48 cm) diagonal Aspect Ratio: 4:3 VGA Environmental Resolution: 640 x 480 pixels Temperature: 32° to 112°F (0° to 45°C) Brightness: 350 nits (cd/m2) Humidity: 10% to 90% RH (non-condensing) Contrast: 400:1 Heat Dissipation: 30 BTU/hour Color Depth: 18-bit, 256k colors Enclosure Illumination: Backlit fluorescent Viewing Angle: -±80° horizontal, +80°/-70° vertical Construction: Injection-molded plastic, 0° to 45° adjustable friction clutch Touchscreen: Resistive membrane tilt mechanism, low-profile base, integral cable assembly, swivel mount kit available separately Buttons & Switches Front Bezels: Button and no-button bezels included; button bezel includes Trigger: (1) Programmable top-mounted pushbutton (left); resets touctipanel white translucen illuminated Up/Down and Ttiumbpad buttons s and 8 if held for 5 seconds hardkey buttons with illuminated dividers and default backlit text engraving, BhONm«»»(1)PmgmmmaU|otop-muuntedpuuhbutton<riOhV.nonnu||y»eta optioflal custom backlit text engraving sold separately[ display brightness level Hard Keys: (8) Optional programmable pushbuttons, engravable backlit text Dimensions nm Hoigh�: O21in(158 mm) maximum ' (default � ' � ����O� 00in(20Omm) U�Down:C�O�ionu| programmable pushbuttons, � � ' m' Depth: engmvNebuoN���/ unUeza|N��u|�nngmvingino|uded) i � � mm), 6.53 without Tkumbpad: (5) Optional programmable pushbuttons for 4-way directional w eight navigation and "enter", backlit 2.9|b(13kg) Connectors Integral 8ft<275m> cable with 10'pinRJ58 male connector; Connects to TPS-6X-IMCW interfac module] Available Models TPS-6: a`�s7 na| Gloss Black See �oTP8'OX-|MCVVi���oo module apooi���un�r�horoonnoc�m ' Processor -"-`,`S:u'^T-a., Tilt Touchpanel, Gloss White CPU: 32-bit maao�uCo|UFi ���i � � Microprocessor Memory Inchdedxcce.ssnnes SDRAM: 32 MB PW-2407WU 24 Volt Power Pack, Universal {lncluded Quantity for TPS-6, Flash: 32 MB ! TPS-6-B-T, TPS-6-W-S: 1] Maximum Project Size: 28 MB TPS-6X-IMCW lnterface Module [Included Quantity for TPS-6, TPS-6-B-T, TPS-6-W-8: 1] Graphic Engine TPS-6X Backlit Engravable Button Bezel Kit w/Default Isys engine; 16-bit non-palette graphics; 65,536 colors; Synapse image Engraving, Gloss Black [Included Quantity for TPS-6: 1] rendering algorithm; multi-mode objects, DNav dynamic menu objects, TPS-6X-FP-NB No-Button Bezel Kit, Gloss Black [Included Ouantity for dynamic graphics, PNG translucency, full-motion (60 fps) animation, color / TPS-6: 1] key video windowing Backlit Engravable Button Bezel Kit w/Default Engraving, Matte Black [Included Ouantity for TPS-6-B-T: 1] Communications TPS-6X-FPB-T-NB No-Button Bezel Kit, Maffe Black [Included Quantity for Ethernet: 1 OBaseT/1 OOBaseTX, auto-switching, auto-negotiating, auto- / TPS-6-B-T: 1] discovery, full/half duplex, TCP/IP, UDP/IP, CIP, DHCP TP8fX-FPW'S_ENGRAVED Backlit EngmvaWe Button Bezel Kit w/Dofauk Cresnet: Supports Cresnet slave mode Engraving, Gloss White [Included Quantity for TPS-6-W-S: 11 TPS-6X-FPW-S-NB No-Button Bezel Kit, Gloss White [Included Quantity for Video TP8-64N-8:1] Signal Types: Composite Formats: NT8C48Oior PAL 570i Color Depth: 1V'bi\;202.144colors ' Available Accessories Windowing: Single-window, deinterlaced and scatable up to full-screen TPS-6X-FPENGRAVED: Backlit Engravable Button Bezel Kit w/Custom � Engraving, Gloss Black Audio TPS-6X-FP BLANK: Backlit Engravable Bufton Bezel Kit (blank), Gloss Black Internal transducer for keyclick sound TPS-6X-FPB-T_ENGRAVED: Backlit Engravable Button Bezel Kit w/Custom Engraving, Matte Black Power Reauirements TpS-OX'Fp8-T]]UANK: 8aoNitEngmwub|oBuUonBnzo|Ki1(Nonk).Matte Power Pack: 075 Amps @24 Volts DC; Black 100-240 Volts AC, 50/60 Hz power pack, model PW-2407WU included TPS-6X-FPW-S_ENGRAVED: Backlit Engravable Button Bezel Kit w/Custom Engraving, Gloss White TPS-6X-FPW-S_BLANK: Backlit Engravable Button Bezel Kit (blank), Gloss White SMK-6X: Swivel Mount Kit Cream Electronics, In. 15 **a !Mae Rockleigh, NJ 07647 cam is . a 800.237.2041 201.7671400 I Fax: 201167.1005 Ft sw TPS-6 IsysTM 5.7" Tilt Touchpanel CRESNET-NP-BK-0500: Cresnet® Control Cable, non-plenum, black, 500 ft Typical TPS-6 Application box CRESNET-NP-OR -B500: Cresnet® Control Cable, non-plenum, orange, 500 Tr""mcw ft box Interface Module CRESNET-NP-YL-B500: Cresnet® Control Cable, non-plenum, yellow, 500 ft TPS box Toothpse CRESNET-P-TL-SP500: Cresnet® Control Cable, plenum, teal, 500 ft spool CRESNET-P-TL-SP1000: Cresnet® Control Cable, plenum, teal, 1000 ft CONTROL t spool SYSTEM CRESNET-P-BK-SP500: Cresnet® Control Cable, plenum, black, 500 ft spool „-- CRESNET-P-OR-SP500: Cresnet® Control Cable, plenum, orange, 500 ft spool VIDEO CRESNET-P-YL-SP500: Cresnet® Control Cable, plenum, yellow, 500 ft .:.,SOURCES: spool CRESNET-HP-NP-TL-SP500: Cresnet® "High-Power" Control Cable, non- plenum, teal, 500 ft spool CRESNET-HP-NP-TL-SP1000: Cresnet® "High-Power" Control Cable, non- plenum, teal, 1000 ft spool CRESCAT-NP-SP500: Crestron Home® CAT5 AV Cable, Single CAT5e & Cresnet, non-plenum, 500 ft spool TPS-6 CRESCAT-D-NP-SP500: Crestron Home® CAT5 AV Cable, 2x CAT5e & Cresnet, non-plenum, 500 ft spool CRESCAT-D-HP-NP-TL-SP500: Crestron Home() CAT5 AV Cable, 2x CAT5e & / PW-2407W11 CONTROL Power 5rppy Cresnet "High-Power", non-plenum, teal, 500 ft spool SYSIEM Notes. VIDEO 1 Text engraving is not backlit on the TPS-6 W-S white model SOURCES Color Key ■nformation video Cresnet .6 LAN Creston lectronics, Inc. 15 Volvo Olive !Rockligh, R.110541 Aiminimiummumineemiaaniu let ano2372txt /201167.3400 Far 251.761.1905 immorw wwfroLcOm TPS IsysTM 5.7" Tilt Touchpanel 7 •,,,,- p ,,„, \,,,,_„ (20 53 cm) t 1 , ' I f . '13 1 i ,r ; 1,_ i —,--______,, (''' ‘., ,.. . . , 0 , ' / 1 1i l', 7 03 in (17.84 cm) 6 98 in (17 73 cm) - vk 1 -----"--' \ 1 `)‘ :---------„ -- .,_. Creston Electroitics, Inc 15 naive Oliva I Rockleigh, NJ 07847 All !titian names, protitict nalitet atilt trademarks are the rimperty of their inspects*/ mints= Tat 1100.237M/41 / 201.76I3400 I Ras: 201.787,1905 - ©2010 Cat:gran Eiecironin In. inincrestroncom Specification sideect to thane without notice, 12/3/2010 eert & associates technology consultants r.. 140 third street south, stillwater, mn 55052. phone . 6651.430,277), fax . 6514302661 www.elercwrn December 6, 2010 Columbia Heights Council Chamber Technology Request For Information (RFI) #1 In order to evaluate your bid for the Council Chambers Technology Replacement project, we would appreciate your prompt response to the following questions. We need your response by 8:00 AM Wednesday, 12/8/10. 1) Please provide a price to substitute one (1) Vaddio 999 -5600 -000 switcher /controller for the specified 999 -5200 -000 switcher /controller. In your price, include breakout cables 440 -5600 -000 for each composite input /output of the 999 -5600 -000. 2) Please provide a price for ICT1 control room touchpanel system, consisting of Crestron TTK -4SM- B-S, TPMC- 4SM -B -S, PWE- 4803RU, custom - engraved front bezel, and programming. 3) Owner requests that contract be based on the AIA A105 (small projects) document rather than the A207 document. Does your company agree to abide by the un- amended A105 rather than the A207? 4) Your bid includes $280.50 for the CBL -CG310 character generator. This model is not available from the manufacturer yet; the current substitution is the `CBL -CG250 with TV1 option ". Please clarify your price for the substitute system. Note that the SDI card listed under designation VSS is also discontinued and will not be substituted. 5) Warranty: RFB requires one -year contractor correction period that includes equipment sold under this contract. VSI bid seems to indicate that manufacturer warranties take precedence over contractor correction period if manufacturer warranty is shorter than one -year. Please clarify whether VSI will honor a correction period covering all contractor - furnished equipment for one year from date of acceptance. We appreciate your bid and hope to receive your responses to this RFI soon. Best Regards, Will Craig Elert & Associates minneapolis i st. paul austin chicago dallas Lynchburg kansas city new haven milwaukee e ert & assocrates technology consultants 140 third street south, s011water> run 55082 4 phone . 651.430 2772, fax , 651,430 2611 Lw'tw,elert. December 7, 2010 Columbia Heights Council Chamber Technology Request For Information (RFI) #2 In order to evaluate your bid for the Council Chambers Technology Replacement project, we would appreciate your prompt response to the following questions. We need your response by 8:00 AM Wednesday, 12/8/10. 1) Owner has decided that contract should be based on the AIA A201 2007 edition rather than the A201 1997 edition referenced in the specifications. Does your company agree to abide by A201 2007 edition rather than the 1997 edition? (this question replaces #3 in RFI #1). We appreciate your bid and hope to receive your responses to this RFI soon. Best Regards, Will Craig Elert & Associates minneapolis i st pawl austin chicago dallas Lynchburg kansas city new haven milwaukee 25 Years of Technology Solutions [1227 Caledonia Street Mankato, MN 56001 VSI 507-625-1650 • 1-800-642-4085 www.videoser.com December 9, 2010 Columbia Heights Council Chamber Technology RE: Request For Information (RFI) #1 & #2 VSI is pleased to present the following responses for your consideration. QTY MFG MODEL # DESCRIPTION EA TOTAL NOTE 1 — VADDIO CONTROLLER CHANGE -1 VADDIO 999-5200-000 SWITCHER & CAM CONTROLLER $ 2,966.70 -$ 2,96670 1 VADDIO 999-5600-000 _ SWITCHER & CAM CONTROLLER $ 7,144.50 $ 7,144.50 5 VADDIO 440-5600-000 HD15 TO Y/C ADAPTER CABLE $ 38.50 $ 192.50 SUBTOTAL $ 4,370.30 TAX $ 311.39 TOTAL $ 4,681.69 NOTE 2— ICT1 — CRESTRON TOUCHPANEL ADDITION 1 CRESTRON TTK-4SM-B-S TABLE TOP MOUNT $ 114.00 $ 114.00 1 CRESTRON TPMC-4SM-B-S 3.7" WALL MOUNT TOUCHPANEL $ 627.00 $ 627.00 1 CRESTRON PWE-4803RU POWER SUPPLY $ 57.00 $ 57.00 1 CRESTRON 4SM-BTNO BEZEL - CUSTOM ENGRAVING $ 28.50 $ 28.50 SUBTOTAL $ 826.50 TAX $ 58.89 LABOR, INSTALLATION, PROGRAMMING $ 200,00 TOTAL $ 1,085.39 NOTE 3 VSI takes no exception to using the AIA 201 — 2007 edition contract and standards. NOTE 4 Using the current available option (CBL-CG250 & TV1) there would be an additional $2811.00 to the bid submitted on 12-6-2010. Tightrope has made available two SDI cards, in the event they are not able to fulfill VSI will source direct from OEM (Matrox — Convert DV) for no additional cost. NOTE 5 VSI will honor a correction period of one year covering all contractor-furnished equipment and workmanship from date of acceptance. Equipment manufactures' warranties apply after one year. Sincerely, Terry Dahl President 7 �' AC�'R�' CERTIFICATE OF LIABILITY INSURANCE DATE (MM /DD/YYYY) 12/16/2010 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Phone: (507)345 -4587 CONTACT Janis Johnson Fax: (507)345 -4515 NAME: AX Willard and Williams insurance Agency (AC No. Ext): ( ( A N (507)3454515 P.O. Box 1297 ADDRESS: janis@hickorytech.net Mankato, MN 56002 PRODUCER VIDE00 CUSTOMER ID #: INSURER(S) AFFORDING COVERAGE NAIC # INSURED INSURER A : Allied Insurance Company 36528 Video Services Inc. of Mankato INSURER B : SFM 11347 1227 Caledonia INSURER C Mankato, MN 56001 INSURER D : INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR .INSR WVD POLICY NUMBER (MM/OD/YYYY) (MM /DD/YYYY) GENERAL LIABILITY ACP BPR 7190320470 1/1/2010 1/1/2011 EACH OCCURRENCE $ 1,000,000 DAMAGE TO A I/ COMMERCIAL GENERAL LIABILITY PREMISES (Ea occurrence) $ 300,000 CLAIMS -MADE ✓ OCCUR MED EXP (Any one person) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP /OP AGG $ 2,000,000 ✓ POLICY ECT I LOC $ AUTOMOBILE LIABILITY ACP BA 7190320470 1/1/2010 1/1/2011 COMBINED SINGLE LIMIT $ (Ea accident) 1,000,000 A 1- 1 I ANY AUTO BODILY INJURY (Per person) $ ALL OWNED AUTOS BODILY INJURY (Per accident) $ SCHEDULED AUTOS PROPERTY DAMAGE ✓ HIRED AUTOS (Per accident) ✓ NON -OWNED AUTOS A ✓ UMBRELLA LIAB ✓ OCCUR ACP CAA 7190320470 1/1/2010 1/1/2011 EACH OCCURRENCE $ 3,000,000 EXCESS LIAB CLAIMS -MADE AGGREGATE $ 3,000,000 DEDUCTIBLE $ RETENTION $ $ WORKERS COMPENSATION 012869.213 1/1/2010 1/1/2011 ✓ TORY LIMITS O FR B AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER /EXECUTIVE Y / N N / A E.L. EACH ACCIDENT $ 100,000 OFFICER/MEMBER EXCLUDED? (Mandatory in NH) E.L. DISEASE - EA EMPLOYEE $ 100,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $ 500,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space is required) City of Columbia Heights is an additional insured. CERTIFICATE HOLDER CANCELLATION Holder's Nature of Interest : Additional insured SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Columbia Heights ACCORDANCE WITH THE POLICY PROVISIONS. Ms. Linda Magee 590 40th Ave. N.E. AUTHORIZED REPRESS A Columbia Heights, MN 55421 © 1988-2009 ACORD CORPORATION. All rights reserved. ACORD 25 (2009/09) The ACORD name and logo are registered marks of ACORD PERFORMANCE BOND AMCO Insurance Company Nationwide Mutual Insurance Company Bond Number: BDA 718900 Allied Property & Casualty Insurance Company 1100 Locust St., Dept 2006 Des Moines, IA 50391 -2006 (866) 387-0457 CONTRACTOR: SURETY: Video Services, Inc. of Mankato AMCO Insurance Company 1227 Caledonia Street 1100 Locust St., Dept. 2006 Mankato MN 56001 Des Moines, IA 50391 -2006 OWNER: City of Columbia Heights 590 40th Ave. NE Columbia Heights, MN 55421 CONSTRUCTION CONTRACT 1 Date: December 6, 2010 (One hundred thirty -eight thousand, one hundred forty -two dollars) Description: Audio - Visual - Council Chamber Technology Replacement BOND Date: December 6, 2010 Amount: $138,142.00 (One hundred thirty -eight thousand, one hundred forty -two dollars) Modifications to this Bond: 121 None 0 See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) .ttlr",) AMCO Insurance Company °""°""'t Video Services, Inc. of Mankato SEAL; ink Signature: l t Signature: � •'. Name Terry Dahl Name Ja s Dontje Johnso And Title: President and Title: , Attorney -in -Fact (Any additional signatures appear on the last page of this Performance Bond) (FOR INFORMATION ONLY — Name, address and telephone) AGENT or BROKER: OWNERS REPRESENTATIVE: Willard & Williams Insurance Agency (Architect, Engineer or other party.) 220 East Jackson Street Elert & Associates Mankato MN 56001 140 Third Street South (507) 345 -4587 Stillwater MN 55082 (651) 430 -2772 This document conforms to American Institute of Architects Document A312, 2010 edition § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provide in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default: .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for perfoi niance and completion of the Construction Contract, arrange for a contract to be prepared for the execution by the Owner and the contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. § 7 If the Surety elects to act under Section 5.1, 5.2, or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for This document conforms to American Institute of Architects Document A312, 2010 edition .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non - performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3, or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors, and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontractors, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be a Subcontractor and the term Owner shall be deemed to be Contractor. This document conforms to American Institute of Architects Document A312, 2010 edition § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name Name And Title: and Title: , Attorney -in -Fact Address Address This document conforms to American Institute of Architects Document A312, 2010 edition PAYMENT BOND AMCO Insurance Company Nationwide Mutual Insurance Company Bond Number: BDA 718900 Allied Property & Casualty Insurance Company 1100 Locust St.. Dept 2006 Des Moines, IA 50391 -2006 (866) 387-0457 CONTRACTOR: SURETY: Video Services, Inc. of Mankato AMCO Insurance Company 1227 Caledonia Street 1100 Locust St., Dept. 2006 Mankato MN 56001 Des Moines, IA 50391 -2006 OWNER: City of Columbia Heights 590 40th Ave. NE Columbia Heights, MN 55421 CONSTRUCTION CONTRACT Date: December 6, 2010 Amount: $138,142.00 (One hundred thirty -eight thousand, one hundred forty -two dollars) Description: Audio - Visual - Council Chamber Technology Replacement BOND Date: December 6, 2010 Amount: $138,142.00 (One hundred thirty -eight thousand, one hundred forty -two dollars) Modifications to this Bond: A None ❑ See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Services, � rew Video er vices Inc. of Mankato ±P .... AMCO Insurance Company > ' " O R A rt r • -- :SEAL 1 • Signature: .r� "- -� L . �-.-� - _._.. Signature: ! " Agikii 'Ili 474.40 Name Terry Dahl Name Jani fDonje Johnson And Title: President and Title: , Attorney -in -Fact (Any additional signatures appear on the last page of this Performance Bond) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNERS REPRESENTATIVE: Willard & Williams Insurance Agency (Architect, Engineer or other party.) 220 East Jackson Street Elert & Associates Mankato MN 56001 140 Third Street South (507) 345 -4587 Stillwater, MN 55082 (651) 430 -2772 This document conforms to American Institute of Architects Document A312, 2010 edition § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien, or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non - payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13) § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non - payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non - payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall 'indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of e Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. This document conforms to American Institute of Architects Document A312, 2010 edition § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this bond or shall pe„nit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment' that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. This document conforms to American Institute of Architects Document A312, 2010 edition § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be a Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name Name And Title: and Title: , Attorney -in -Fact Address Address This document conforms to American Institute of Architects Document A312, 2010 edition USE ONLY FOR ACKNOWLEDGEMENT OF INDIVIDUAL, PARTNERSHIP, OR LIMITED LIABILITY PRINCIPAL STATE OF ) SS. County of ) On this day of , 20 , personally came to me well known to be the identical person described in and who executed the foregoing bond and he acknowledged the same to be own free act and deed. (SEAL) Signature of Notary Public USE ONLY FOR ACKNOWLEDGMENT OF CORPORATE PRINCIPAL STATE OF Minnesota ) Bl Earth ) ss. County of ) Upon this 6 day of December , 2010 , before me personally appeared Terry Dahl , to me personally known, who being by me duly sworn, did say that he is the President of Video Services, Inc. of Mankato a Minnesota corporation; that the seal affixed to the foregoing bond is the Corporate Seal of the corporation, and that said instrument was executed in behalf of the corporation by authority of its Board of Directors; that he acknowled.ed said i d -,_ ,, ;_ he free act an. deed of the corporation. ` °, ' „ r . BONNIE L MURPHY (SEAL) dr . �' _ 1° -; Notary Public - Minnesota My Commission txpires Jan 31, 2015 Signature o d Not Public ACKNOWLEDGMENT OF CORPORATE SURETY STATE OF Minnesota B lue Earth ) ss. County of ) On this 6 day of December , 20 10 . before me personally appeared Janis Dontje Johnson and to me personally known, who being by me duly sworn, did say that he is the attorney in fact, of the AMCO Insurance Company , the corporation whose name is affixed to the foregoing instrument; that the seal affixed to the foregoing instrument is the corporate seal of the said corporation; and that said instrument was executed in behalf of said corporation by authority of its board of directors and said Janis Dontje Johnson acknowledged that he executed said instrument as attorney in fact as the free act and deed of said corporation. (SEAL) y°"�` "' BONNIE L. MURPHY I - N otary Publ Min neso t a Signature of Notar Pub ' ° +` i;;; " My Commission Expires Jan 31, 2015 LI Power of Attorney KNOW ALL MEN BY THESE PRESENTS That AMCO Insurance Company, a corporation organized under the laws of the Stale of Iowa, with its principal office in the City of Des Moines, Iowa, hereinafter called "Company ", does hereby make, constitute and appoint JAMS DONTJE JOIINSON ROBERT R. RICHTER MANKATO MN each in his individual capacity, its true arid lawful Attorney -In-Fact with full power arid authority to sign, seal, and execute in its behalf any arid all bonds and undertakings and other obligatory instruments of similar nature (except bonds guaranteeing the payment of principal and interest of notes, mortgage bonds and mortgages) in penalties not exceeding the suns of THREE MILLION AND NO /100 DOLLARS (s 3,000,000.00 ) arid to bind the Company thereby, as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Company; and all acts of said Attorney pursuant to the authority hereby given are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to arid by authority of the following By -Laws duly adopted by the Board of Directors of the Company. ARTICLE 7 EXECUTION OF CONTRACTS "Section 7.4 Instruments issued by the Corporation. Bonds, undertakings, and other obligatory instruments of similar nature, other than insurance policies and insurance endorsements, issued by the Corporation shall be validly executed and binding on the Corporation when signed by the President or a Vice President or by the Attorney(s) -In -Fact appointed by the President or by a Vice President." "Section 7.5 Appointment of Agents. The President or a Vice President shall have the power to appoint agents of the Corporation, or other persons, as Attorney(s)-In-Fact to act on behalf of the Corporation in the execution of bonds, undertakings, and other obligatory instruments of similar nature, other than insurance policies and endorsements, with full power to bind the Corporation by their signature and execution of any such instrument. The appointment of such Attorney(s) -1n -Fact shall be accomplished by Powers of Attorney signed by the President or the Vice President." This Power of Attorney is signed and sealed by facsimile under and by the following By -Laws duly adopted by the Board of Directors of the Company. ARTICLE 7 EXECUTION OF CONTRACTS "Section 7.6 Verifications . The Secretary, or any Assistant Secretary, is authorized to certify that any such Power of Attorney signed is validly executed and binding on the Corporation and to certify that any bond, undertaking, or obligatory instrument of similar nature, other than insurance policies and endorsements, to which the Power of Attorney is attached is and shall continue to be a valid and binding obligation of the Corporation, according to its terms, when executed by Attorney(s) -In -Fact appointed by the President or Vice President." "Section 7.7 Use of Corporate Seal. It shall not be necessary to the valid execution and binding effect on the Corporation of any bond, undertaking, or obligatory instrument of similar nature, other than insurance policies and endorsements, signed on behalf of the Corporation by the President or a Vice President, or Attorney(s) -In -Fact appointed by the President or a Vice President, or of any Power of Attorney executed on behalf of the Corporation appointing Attorney(s) -In -Fact to act for the Corporation, or of any certificate to be executed by the Secretary or an Assistant Secretary, as hereinabove in Sections 7.4, 7.5, and 7.6 provided, that the corporate seal be affixed to any such instrument, but the person authorized to sign such instrument may affix the corporate seal. A facsimile corporate seal affixed to any such instrument shall be as effective and binding as the original seal." "Section 7.8 Other Facsimile Signatures. A facsimile signature of the President or of a Vice President affixed to any bond, undertaking, or obligatory instrument of similar nature, other than policies and endorsements, or to a Power of Attorney signed by such President or a Vice President, as herein in Sections 7.4 and 7.5 provided, or a facsimile signature of the Secretary or of an Assistant Secretary to any certificate as herein in Section 7.6 provided, shall be effective and binding upon the Corporation with the same force and effect as the original signatures of any such officers." "Section 7.9 Former Officers. A facsimile signature of a former officer shall be of the same validity as that of an existing officer, when affixed to any insurance policy or insurance endorsement, any bond or undertaking, any Power of Attorney or certificate, as herein in Sections 7.1, 7.2, 7.4, 7.5, and 7.6 provided." IN WITNESS WHEREOF, the Company has caused these presents to be signed by its Vice President and its corporate seal to be hereunto affixed this 29 day of J4 JARY ,2009 '` "' " "` AMCO INSURANCE COMPANY STATE OF IOWA 0 •SEAL') By: £ Vice President COUNTY OF POLK ss 1 1 � ,. ar On this 29 day of JANUARY , 20a. before me personally carne Brett Harman, to me known, who, being by me duly sworn, did depose and say that he is Vice President of AMCO Insurance Company, the corporation described in and which executed the above instrument; that he knows the seal of said corporation, that the seal affixed to said instrument is such corporation seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he has signed his name thereto pursuant to like authority, and acknowledged the same to be the act and deed of said corporation. "" ,�+r SANDYALITZ Sandy Alitz ffi C.Qrt on Nu 167705 Notary Public in and for the St e of lows , IAi' Ma 24, 1 E' W lr°' CER'T'I FICATE 1, the undersigned, Assistant Secretary of AMCO Insurance Company, a corporation organized under the laws of the State of Iowa, do hereby certify that the foregoing Power of Attorney is still in force, and further certify that Sections 7.4 through 7.9 inclusion of Article 7 of the By -Laws of the Company set forth in said Power of Attorney are still in force. IN TESTIMONY WHEREOF, I have subscribed my name and affixed the seal of the company this 6 day of December , 2010 .4 03772 I :. This Power of Attorney expires 0 :SEAL: 0 A ssistant Secretary 04/15/11 t .. .5vo∎∎• • • ; Bda 1 (03 -08) 00 \■so' 25 Years of Technology Solutions Change Order 1227 Caledonia Street Mankato, MN 5001 507-625-1650 •6 -800- 642 -4085 Form # 1 www.vldeoser.com V 1 This form to be completed whenever a project change is greater than $50.00. Customer: Columbia Heights Reason For Change Contact: Error/ Omission Phone: _X_ Changed Condition Job: Design Improvement Date: 12/23/2010 Completion Date, Schedule Change Salesperson: _X _ Modified Scope Tech on Site: Travis Dahl Non - Project Change Customer Request Change Requested & Location Deduct Exton VGA DA #XDA1 60- 506 -03 Notes & Justification Not needed Responsible for Cost: VSI Customer_ X Impact: Product Cost Yes X _ No Tech Time: Yes_X_ No Hours If yes, attach cost estimate. Engineer Time: Yes X_ No Hours Materials: ($126.50) Sales: echnical Time: Engineering: Programming Credit Trips - Travel Scheduling: Freight -Misc: Technician: Tax: ($9.01) Project Mgr: Travis Dahl TOTAL: ($135.51) Billing: Project Manager Approval: Travis Dahl Date: 12/23/10 Customer Approval: Date: 1 /30 / /GJ CCH Change Order #1 Page 1 ' 25 Years of Technology Solutions Change O rd e r 1227 Caledonia Street Mankato, MN 5001 507 - 625 -1650 •6 -800- 642 -4085 Form # 2 www.videoser.com — V This form to be completed whenever a project change is greater than $50.00. Customer: Columbia Heights Reason For Change Contact: Error/ Omission Phone: _X_ Changed Condition Job: Design Improvement Date: 1/12/2011 Completion Date Schedule Change Salesperson: _X _ Modified Scope Tech on Site: Travis Dahl Non - Project Change Customer Request Change Requested & Location Add Electrical requirements for equipment rack and displays to VSI scope of work. 2 - 120 volt circuits to displays 1- 120 volt 30 amp circuit to equipemnt rack 1- 120 volt circuit to display - library Notes & Justification All new additional recepticals to use local circuit with in 35' Electrical inspections /permits /taxes included Responsible for Cost: VSI Customer X Impact: Product Cost Yes_X_ No Tech Time: Yes_X_ No Hours If yes, attach cost estimate. Engineer Time: Yes No Hours Materials: Sales: echnical Time: $130 Engineering: Sub -Prgmg $1,127 Credit Trips - Travel Scheduling: Freight -Misc: Technician: Tax: Project Mgr: Travis Dahl TOTAL: $1,257.00 Billing: Project Manager Approval: Travis 10 ahl Fie. d Approved Date: 1/12/10 1 Customer Approval: Date: ` / a f CCH Change Order #2_2 Page 1 ."` 25 Years of Technology Solutions Change Order 1227 Caledonia Street Mankato, MN 56001 507-625-1650 • 1-800-642-4085 Form # www.videoser.com This form to be completed whenever a project change is greater than $50.00. Customer: Columbia Heights Reason For Change Contact: Error/ Omission Phone: _X_ Changed Condition Job: Design Improvement Date: 1/18/2011 Completion Date Schedule Change Salesperson: _X _ Modified Scope Tech on Site: Travis Dahl Non-Project Change Customer Request Change Requested & Location Eliminate in design: TRMS SDI Cards Deduct (-2) Tightrope Media SDI Cards -CBL-CGSDI ($1573.00) Notes & Justification Per Will Craig Responsible for Cost: VSI Customer Impact: Product Cost Yes _X_ No Tech Time: Yes __X_ No Hours If yes, attach cost estimate. Engineer Time: Yes No Hours Materials: ($1,573.00) Sales: echnical Time: $0 Engineering: Sub -Prgmg $0 Credit Trips-Travel Scheduling: Freight-Misc: Technician: Tax: ($112.08) Project Mgr: Travis Dahl TOTAL: ($1,685.08) Billing: Project Manager Approval: Travis Dahl Field Appjoved Date: 1/17/1p Customer Approval "1.1 (7-- / A 5 r1 Date: / —/ I CCH Change Order #3_1 Page 1 25 Years of Technology Solutions Change Ord e r 1227 Caledonia Street Mankato, 1-800-642-4085 Form # 7 547 -625 -15 -1 654 50 • 1 -844- 642 -4485 / 1 www.videoser.com This form to be completed whenever a project change is greater than $50.00. Customer: Columbia Heights Reason For Change Contact: Error/ Omission Phone: Changed Condition Job: Design Improvement Date: 2/2/2011 Completion Date Schedule Change Salesperson: _X _ Modified Scope Tech on Site: Travis Dahl Non - Project Change Customer Request Change Requested & Location #1- eliminate mic pop by adding ST-I0 with additional wiring and programming #2- mute all microphones and have flashing indicator on all panels that says mic mute to unmuted #3- control audio levels on outputs for recording / broadcast / LED audio levels on control rm. TP #4- add a 1 in and 2 out composite DA to view on 40" TV with control of inputs of control rm. TV, and the tightrope will be controlling what is being sent out of switcher to the display,the DA will be installed on the output of the switcher Notes & Justification Per Will Craig parts, wiring, labor, programming, and travel for all changes included Responsible for Cost: VSI Customer X Impact: Product Cost Yes_X_ No Tech Time: Yes_X_ No Hours If yes, attach cost estimate. Engineer Time: Yes No Hours Materials: $770.32 Sales: echnical Time: $1,760 Engineering: Sub -Prgmg $600 Credit Trips - Travel Scheduling: Freight -Misc: $88 Technician: Tax: $56.81 Project Mgr: Travis Dahl TOTAL: $3,275.13 Billing: Project Manager Approval: Travis Dahl Date: 2 -2 -11 Customer Approval: .‘ , Date: , v 1 CCH Change Order #7 Page 1