HomeMy WebLinkAboutEDA AGN 05-14-07 Special
590 40th Avenue N.E" Columbia Heights, MN 55421-3878 (763) 706-3600 TOO (763) 706-3692
Visit Our Website at: www.ci.columbia-heights.mn.us
EDA COMMISSIONERS
Don Murzyn JI'.
Patricia Jindra
llruce Kclzcnberg
Gury L. Peterson
Bruce Nawrocki
130bby Willimlls
TammcraDiehm
CITY OF COLUMBIA HEIGHTS
ECONOMIC DEVELOPMENT AUTHORITY
SPECIAL MEETING
6:30 P.M., MONDAY, MAY 14, 2007
CITY HALL, CONFERENCE ROOM 1
AGENDA
1. CALL TO ORDER/ROLL CALL
2. PLEDGE OF ALLEGIANCE
3. DISCUSSION ITEM
A. Adopt Resolution 2007-10, Contract for Private Redevelopment
Motion: Move to Adopt Resolution 2007-10, a Resolution Approving a
Contract for Private Redevelopment between the Columbia Heights Economic
Development Authority and the Greater Metropolitan Housing Corporation;
and furthermore, to authorize the President and Executive Director to enter
into an agreement for the same.
4. ADJOURNMENT
Walter R. Fehst, Executive Director
The EDA does not discriminate on the basis of disability in the admission or access to, or treatment or employment in, its
accommodation will be provided to allow individuals with disabilities to participate in all EDA services, programs, and
activities. Auxiliary aids for handicapped persons arc available upon request when the request is made at least 96 hours in
advance. Please call the Deputy City Clerk at (763) 706-3611 to make arrangements (TDD 706-3692) for deaf or hearing
impaired only.
H:\EDAAgenda2007\May 14, 2007 Special
THE CITY OF COLUMBIA HEIGHTS DOES NOT DISCRIMINATE ON THE BASIS OF DISABILITY IN EMPLOYMENT OR THE PROVISION OF SERVICES
EQUAL OPPORTUNITY EMPLOYER
COLUMBIA HEIGHTS ECONOMIC DEVELOPMENT AUTHORITY (EDA)
Meeting of May 14, 2007
AGENDA SECTION: Business Items ORIGINATING DEPARTMENT: EDA EXECUTIVE
NO.3 DIRECTOR
APPROVAL
ITEM: Adopt Resolution 2007-10, BY: Robert Streetar BY:
Approving a Contract for Private DATE: May 8, 2007
Redevelopment
The purpose of this memorandum to ask Commissioners to consider redeveloping the
residential property located at 4141 Jefferson Street, in partnership with Greater
Metropolitan Housing Corporation (GMHC), from its current state as a vacant and
burned out single-family home to two new single-family for-sale homes.
Property Background
The home, which was built in 1924, was subject to a fire on August 17, 2005. It has
remained in a burned out state since that time. The lot measures 80' x 129' and is
comprised of two legally conforming single-family lots, with the existing house
occupying the north lot. Please find attached photos of the lot and structure.
The property was recently foreclosed and placed for sale for $120,000 by the owner,
AMC Mortgages Services. The land and improvements are assessed at $152,700, and
the just land is assessed at $91,600 for pay 2008. After extensive discussions the
owner has agreed to reduce the sale price to the EDA to $86,000, which is $5,600 or
6.1 % lower than the County's assessed land value.
Redevelopment Project
The GMHC would demolish the existing home and build two new single-family for-sale
homes. Each home would be two-stories, and 1,650 square feet in size, with three
bedrooms and two and one half bathrooms, and similar to those the GMHC built on
Second Street in 2004. Both of these homes would sell for a target price of $235,000.
Demolition would tentatively begin in June, with construction occurring over the next 90
to 120 days. Marketing would begin simultaneously with demolition. The table provides
a quick look at the results of redeveloping this property.
# Of Single - Family Homes
Property Value
Property Tax
'Approximate
Before
1
$157,700
$1,544
After
2
*$470,000
*$4,752
Chanqe
1
*$317,300
*$3,208
The cost to acquire the property, demolish the existing structure, and construct two new
homes is estimated to be $535,050. The sale of both homes would generate $470,000
of revenue. Subsequently, in order to successfully redevelop the property, the project
requires $65,050 of funding assistance to make the project feasible. The assistance
could come from Fund 226 - Special Projects that currently has a balance of just over a
$100,000.
1
Comprehensive Plan
By facilitating the redevelopment of this property, the EDA would be implementing two
goals of the Housing component of the Comprehensive Plan. These goals and their
corresponding action steps are listed below.
Goal: Promote and preserve the single-family housing stock as the community's
strongest asset.
. Action Step: The City will acquire and demolish the most seriously deteriorated
single-family homes and work with the private sector to develop appropriate
replacement housing.
. Action Step: The City will acquire and assemble residential lots, as opportunities
arise, for the purpose of developing infill housing.
Goal: Provide a variety of life cycle housing opportunities within the community.
. Action Step: The City will foster partnerships with the private sector to help
diversify housing in the community.
Development Contract
To redevelop this property the EDA would need to approve a development contract with
the GMHC. The contract stipulates that the EDA will assign the purchase agreement,
between the EDA and AMC Mortgage Services, to the GMHC on or before the day of
closing estimated to be no later than May 25, 2007. The GMHC will purchase the
property from AMC Mortgage Services for $86,000. GMHC will demolish the current
structure and build two new single-family for sale homes and sell them each for a target
price of $235,000. Once construction is completed the EDA will provide up to $65,050
of funding assistance.
Summary
In summary, the EDA is presented with an opportunity to remove a vacant and blighted
home and replace it with two new single-family for-sale homes with target sales prices
of $235,000. To accomplish this task the City would partner with the GMHC as the
homebuilder as well as provide financial assistance to the GMHC to make this
redevelopment feasible. This redevelopment would implement the goals of the
Comprehensive Plan and result in a much-needed physical improvement to the
neighborhood. Please find attached a copy of the development agreement.
Recommendation
Staff recommends the EDA approve the contract for private redevelopment between the
EDA and the Greater Metropolitan Housing Corporation.
Recommended Motion
Move to approve Resolution 2007-10, a Resolution approving a Contract for Private
Redevelopment between the Columbia Heights Economic Development Authority and
the Greater Metropolitan Housing Corporation; and furthermore, to authorize the
President and the Executive Director to enter into an agreement for the same.
2
Attachments
EDA ACTION:
3
COLUMBIA HEIGHTS ECONOMIC DEVELOPMENT AUTHORITY
RESOLUTION NO. 2007-10
RESOLUTION APPROVING
REDEVELOPMENT BETWEEN
DEVELOPMENT AUTHORITY
HOUSING CORPORATION
A CONTRACT FOR PRIVATE
THE COLUMBIA HEIGHTS ECONOMIC
AND GREATER METROPOLITAN
BE IT RESOLVED By the Board of Commissioners ("Board") of the Columbia Heights
Economic Development Authority ("Authority") as follows:
Section I. Recitals.
1.01. The Authority has determined a need to exercise the powers of a housing and
redevelopment authority, pursuant to Minnesota Statutes, Sections. 469.090 to 469.108 ("EDA
Act"), and is currently administering the Downtown CBD Redevelopment Project ("Redevelopment
Project") pursuant to Minnesota Statutes, Sections 469.001 to 469.047 ("HRA Act").
1.02. The Authority and the Greater Metropolitan I-lousing Corporation (the
"Redeveloper") have proposed to enter into a Contract for Private Redevelopment (the "Contract"),
setting forth the terms and conditions of redevelopment of certain property within the
Redevelopment Project located at 4141 JelIerson Strcet (the "Redevelopment Property").
1.03. Pursuant to the Contract, the Redeveloper will be assigned that certain Purchase
Agreement between the Authority and AMC Mortgage Services, for the sale of 4141 Jefferson
Street (the "Redevelopment Property"). Pursuant to the Contract, the Redeveloper will purchase the
Redevelopment Property, divide the property into two lots and construct two single-lamily homes
with a target price of $235,000 each.
1.04. The activities of the Authority under the Contract implement housing goals and
action steps of the City's Comprehensive Plan: "Promote and preserve the single-lamily housing
stock as the community's strongest asset by acquiring and demolishing the most seriously
deteriorated single-family homes and work with the privatc sector to develop appropriate
replacement housing, and by acquiring and assembling residential lots, as opportunities arise, for the
purpose of developing infilllots." and "Provide a variety of life-cycle housing opportunities within
the community, by lostering partnerships with the private scctor to help diversiJy housing in the
community."
1.05. The Board has reviewed the Contract and finds that the execution thereof and
performance of the Authority's obligations thereunder further the goals of the Comprehensive Plan
and are in the best interests of the City and its residents.
Section 2. Authoritv Approval: FlIliher Proceedings.
2.01. The Contract as presented to the Board is hereby in all respects approved, subject to
modifications that do not alter the substance of the transaction and that are approved by the
310837vl MTN CL205.41
President and Executive Director, provided that execution of the documents by such officials shall
be conclusive evidence of approval.
2.02. The President and Executive Director are hereby authorized to execute on behalf of
the Authority the Contract and any documents referenced therein requiring execution by the
Authority, and to carry out, on behalf of the Authority its obligations thereunder.
2.03. Authority and City staff are authorized and directed to take all actions to implement
the Contract.
Approved by the Board of Commissioners of the Columbia Heights Economic Development
Authority this 14th day of May 2007.
President- Gary 1. Peterson
ATTEST:
Executive Director- Walter R. Fehst
310837v1 MTN CL20j.41
2
t
ul
~
~
o
VI
l-
It
lli
h
2(;1-
-
::r
-
-:r-
FRoNt
~\-J'
'.'JY
,;.,\~'
tf~~f:.{';/t;
~',i:.(..";,};:;
:1f'i;~~~:
:::'~'~ '~~:.:
v;';.
'I.,
Coft-R46f.
EXECUTION COPY
CONTRACT
FOR
PRIVATE REDEVELOPMENT
By and Between
COLUMBIA HEIGHTS ECONOMIC DEVELOPMENT AUTHORITY
COLUMBIA HEIGHTS, MINNESOTA
and
GREATER METROPOLITAN HOUSING CORPORATION
Dated as of: May 14,2007
This document was drafted by:
KENNEDY & GRAVEN, Chartered (MTN)
470 US Bank Plaza
200 South Sixth Street
Minneapolis, Minnesota 55402
Telephone: (612) 337-9300
31085Sv2 MTN CL20S-41
PREAMBLE
Section 1.1.
Section 2.1.
Section 2.2.
Section 3.1.
Section 3.2.
Section 3.3
Section 3.4
Section 3.5
Section 3.6.
Section 3.7.
Section 3.8.
Section 3.9.
Section 4.1.
Section 4.2.
Section 4.3.
Section 4.4.
Section 5.1.
Section 5.2.
Section 5.3.
310855v2 MTN CL205-41
TABLE OF CONTENTS
............................................................................................................................1
ARTICLE I
Definitions
Definitions......................................................................................................... .2
ARTICLE II
Representations and Warranties
Representations by the Authority.......................................................................4
Representations and Warranties by the Redeveloper.........................................4
ARTICLE III
Acquisition and Conveyance ofPropelty
Status of Redevelopment Property.....................................................................6
Terms .... ............................................................ ........................... ...... ......... .......6
Authority Assistance..........................................................................................6
Title.......................................................................................7
Place of Document Execution............................................................................ 7
Business Subsidy............................................................................................... 7
Environmental Conditions................................................................................. 7
Look-Back Participation....................................................................................8
Records .............................................................................................................. 9
ARTICLE IV
Construction of Minimum Improvements and Public Improvements
Construction of Minimum Improvements and Public Improvements ...............8
Construction Plans.............................................................................................8
Completion of Construction...............................................................................9
Celtificate of Completion..................................................................................9
ARTICLE V
Insurance
Insurance......................................................................................................... .11
Subordination.................................... ...... ..................................... ...... ...... ...... ..12
Qualifications................................................................................................ ...12
1
Section 6.1.
Section 6.2.
Section 7.1.
Section 8.1.
Section 8.2.
Section 8.3.
Section 9.1.
Section 9.2.
Section 9.3.
Section 9.4.
Section 9.5.
Section 10.1.
Section 10.2.
Section 10.3.
Section 10.4.
Section 10.5.
Section 10.6.
Section 10.7.
Section 10.8.
Section 10.9.
Section 10.10.
Section 10.11.
EXHIBIT A
EXHIBIT B
310855v2 MTN CL205-41
ARTICLE VI
Taxes
Right to Collect Delinquent Taxes...................................................................13
Review of Taxes............................................................................................. .13
ARTICLE VII
Financing
Mortgage Financing........................................................................................ .14
ARTICLE VIII
Prohibitions Against Assigmnent and Transfer;
Indemnification
Representation as to Redevelopment ...............................................................15
Prohibition Against Redeveloper's Transfer of Redevelopment Property and
Assigmnent of Agreement ...............................................................................15
Release and Indemnification Covenants ..........................................................16
ARTICLE IX
Events of Default
Events of Default Defined ...............................................................................18
Remedies on Default....................................................................................... .18
No Remedy Exclusive......................................................................................19
No Additional Waiver Implied by One Waiver ...............................................19
Attorney Fees.................................................................................................. .19
ARTICLE X
Additional Provisions
Conflict ofInterests; Authority Representatives Not Individual1y Liable.......20
Equal Employment Opportunity ......................................................................20
Restrictions on Use......................................................................................... .20
Provisions Not Merged With Deed..................................................................20
Titles of Articles and Sections .........................................................................20
Notices and Demands..................................................................................... .20
Counterparts.................................................................................................... .21
Recording.... .......................... .......... ... .............................. ........................ ....... .21
Amendment.................................................................. .......... ... ..................... ..21
Authority or City Approvals ............................................................................21
Termination ... ...... ....... .................................... ...... ........................ ................... .21
Legal Description of Redevelopment Property
Purchase Agreement
II
EXHIBIT C
EXHIBIT D
310855v2 MTN CL205-41
Concept Materials for Redevelopment Property
Certificate of Completion
iii
CONTRACT FOR PRIVATE REDEVELOPMENT
THIS AGREEMENT, made on or as of the 14th day of May, 2007, by and between
COLUMBIA HEIGHTS ECONOMIC DEVELOPMENT AUTHORITY, COLUMBIA
HEIGHTS, MINNESOTA, a public body corporate and politic (the "Authority"), established
pursuant to Minnesota Statutes, Sections 469.090 to 469.1081 (hereinafter referred to as the
"Act"), and GREATER METROPOLITAN HOUSING CORPORATION ("GHMC"), a
Minnesota non-profit corporation (the "Redeveloper").
WITNESSETH:
WHEREAS, the Authority was created pursuant to the Act and was authorized to transact
business and exercise its powers by a resolution of the City Council of the City of Columbia
Heights ("City"); and
WHEREAS, the City and the Authority (as successor to the Housing and Redevelopment
Authority in and for the City of Columbia Heights) have undeliaken a program to promote
redevelopment of land which that is characterized by blight and blighting factors within the City
pursuant to Minnesota Statutes, Sections 469.001 to 469.047 (the "HRA Act"); and
WHEREAS, pursuant to the Act and the I-IRA Act, the Authority is authorized to
undertake celiain activities to facilitate the redevelopment of real Redevelopment Property by
private enterprise; and
WHEREAS, the Authority believes that the redevelopment of the Redevelopment
Property pursuant to this Agreement, and fulfillment generally of this Agreement, are in the vital
and best interests of the City and the health, safety, morals, and welfare of its residents, and in
accord with the public purposes and provisions of the applicable State and local laws and
requirements under which the Project has been undeliaken and is being assisted.
NOW, THEREFORE, in consideration of the premises and the mutual obligations of the
parties hereto, each of them does hereby covenant and agree with the other as follows:
ARTICLE I
Definitions
Section 1.1. Definitions. In this Agreement, unless a different meaning clearly appears
from the context:
"Act" means the Economic Development Authority Act, Minnesota Statutes, Sections
469.090 to 469.108, as amended.
"Agreement" means this Agreement, as the same may be from time to time modified,
amended, or supplemented.
"Authority" means the Columbia Heights Economic Development Authority, or any
successor 01' assign.
"Authority Representative" means the Executive Director of the Authority, 01' any person
designated by the Executive Director to act as the Authority Representative for the purposes of
this Agreement.
"Business Day" means any day except a Saturday, Sunday, legal holiday, a day on which
the City is closed for business, 01' a day on which banking institutions in the City are authorized
by law 01' executive order to close.
"Certificate of Completion" means the certification provided to the Redeveloper, 01' the
purchaser of any part, parcel 01' unit of the Redevelopment Property, pursuant to Section 4.4 of
this Agreement.
"City" means the City of Columbia Heights, Minnesota.
"Construction Plans" means the plans, specifications, drawings and related documents on
the construction work to be performed by the Redeveloper on the Redevelopment Propelty
which a) shall be as detailed as the plans, specifications, drawings and related documents which
are submitted to the appropriate building officials of the City, and (b) shall include at least the
following for each building: (1) site plan; (2) foundation plan; (3) basement plans; (4) floor plan
for each floor; (5) cross sections of each (length and width); (6) elevations (all sides); (7)
landscape plan; and (8) such other plans 01' supplements to the foregoing plans as the Authority
may reasonably request to allow it to ascertain the nature and quality of the proposed
construction work.
"County" means the County of Anoka, Minnesota.
"Event of Default" means an action by the Redeveloper listed in Article IX of this
Agreement.
310855v2 MTN CL205-41
2
"Holder" means the owner of a MOltgage.
"Minimum Improvements" means the division of the Redevelopment Propetty into two
lots and the construction of a single family home on each lot with associated amenities.
"Mortgage" means any mortgage made by the Redeveloper which is secured, in whole or
in pmt, with the Redevelopment Property and which is a permitted encumbrance pursuant to the
provisions of Article VIII of this Agreement.
"Redevelopment Property" means the Redevelopment Property so described on Exhibit
A.
"Redeveloper" means Greater Metropolitan Housing Corporation or its permitted
successors and assigns.
"State" means the State of Minnesota.
"Tax Official" means any County assessor; County auditor; County or State board of
equalization, the commissioner of revenue of the State, or any State or federal district comt, the
tax court of the State, or the State Supreme Court.
"Termination Date" means the date the Authority or City issues the Certificate of
Completion.
"Transfer" has the meaning set forth in Section 8.2(a) hereof.
"Unavoidable Delays" means delays beyond the reasonable control of the party seeking
to be excused as a result thereof which are the direct result of war, significant weather conditions
such as floods, tornadoes, or the like, terrorism, strikes, other labor troubles, fire or other
casualty to the Minimmll Improvements, litigation commenced by third parties which, by
injunction or other similar judicial action, directly results in delays, or acts of any federal, state
or local governmental unit (other than the Authority in exercising its rights under this
Agreement) which directly result in delays. Unavoidable Delays shall not include delays in the
Redeveloper's obtaining of permits or governmental approvals necessary to enable construction
of the Minimum Improvements by the dates such construction is required under Section 4.3 of
this Agreement.
310855v2 MTN CL205-41
3
ARTICLE II
RePl'cscntations and Warrantics
Section 2.1. Representations bv the Authoritv. The Authority makes the following
representations as the basis for the undertaking on its part herein contained:
(a) The Authority is an economic development authority duly organized and existing
under the laws of the State. Under the provisions of the Act, the Authority has the power to enter
into this Agreement and carry out its obligations hereunder.
(b) The activities of the Authority are undertaken to foster the redevelopment of
certain real Redevelopment Property which for a variety of reasons is presently underutilized, to
eliminate current blighting factors and prevent the emergence of fmther blight at a critical
location in the City, to create increased tax base in the City, to stimulate fmther development in
the City as a whole.
Section 2.2. Representations and Warranties by the Redeveloper. The Redeveloper
represents and warrants that:
(a) The Redeveloper is a non-profit corporation duly organized and in good standing
under the laws of the State of Minnesota, is not in violation of any provisions of its articles of
incorporation or the laws of the State, is duly authorized to transact business within the State, has
power to enter into this Agreement and has duly authorizcd the execution, delivery and
performance ofthis Agreement by proper action of its governing body.
(b) Upon acquisition of the Redevelopment Propelty, the Redeveloper will cause the
Minimum Improvements to be constructed in accordance with the terms of this Agreement and
all applicable local, state and federal laws and regulations (including, but not limited to,
environmental, zoning, building code and public health laws and regulations).
(c) The Redeveloper has received no notice or communication from any local, state
or federal official that the activities of the Redeveloper or the Authority may be or will be in
violation of any environmental law or regulation (other than those notices or communications of
which the Authority is aware). The Redeveloper is aware of no facts the existence of which
would cause it to be in violation of or give any person a valid claim under any local, state or
federal environmental law, regulation or review procedure.
(d) The Redeveloper will cause the Minimum Improvements to be constructed in
accordance with all local, state or federal energy-conservation laws or regulations.
(e) The Redeveloper will obtain or cause to be obtained, in a timely manner, all
required permits, licenses and approvals, and will meet, in a timely manner, all requirements of
all applicable local, state and federal laws and regulations which must be obtained or met before
the Minimum Improvements may be lawfully constructed.
310855v2 MTN CLZ05-41
4
(f) Neither the execution and delivery of this Agreement, the consummation of the
transactions contemplated hereby, nor the fulfillment of or compliance with the terms and
conditions of this Agreement is prevented, limited by or conflicts with or results in a breach of,
the terms, conditions or provisions of any corporate restriction or any evidences of indebtedness,
agreement or instrument of whatever nature to which the Redeveloper is now a party or by which
it is bound, or constitutes a default under any of the foregoing.
(g) The Redeveloper shall promptly advise the Authority in writing of all litigation or
claims affecting any part of the Minimum Improvements and all written complaints and charges
made by any governmental authority materially affecting the Minimum Improvements or
materially affecting Redeveloper or its business which may delay or require changes in
construction of the Minimum Improvements.
310855v2 MTN CL205-41
5
ARTICLE III
Acquisition and Convevance of Property
Section 3.1. Status of Redevelopment Property The Authority has entered into that
certain Purchase Agreement and Counter Offer between the Authority and AMC Mortgage
Services (the "Seller") dated May 8, 2007 (the "Purchase Agreement"), for the sale of the
Redevelopment Property to the Authority for the sale price of $86,000, attached as Exhibit B. At
or before closing on the Purchase Agreement (the "Closing"), the Authority will assign the
Purchase Agreement and the Redevelopment Property to the Redeveloper.
Section 3.2. Terms. (a) At or before Closing, the Authority shall assign all its right, title
and interest in the Purchase Agreement to the Redeveloper. At Closing, the Redeveloper will
tender the sale price to the Seller and otherwise comply with the requirements of the Purchase
Agreement.
(b) Redeveloper shall, if required by the City, at its cost, prepare and obtain approval
by the City of a plat of the Redevelopment Propeliy in accordance with City ordinances and
procedures, to create two parcels or lots, upon which will be constructed a single family home on
each parcel or lot (the "Minimum Improvements"), such parcel or lot having the approximate
size and configuration shown in the concept materials (the "Concept Materials") attached as
Exhibit C hereto, provided to staff of the Authority, with the construction of the Minimum
Improvements governed by Article IV of this Agreement.
(c) The closing on conveyance of the Redevelopment Propeliy from the Seller to the
Redeveloper pursuant to the assignment of the Purchase Agleement by the Authority to the
Redeveloper, shall occur on or before May 25, 2007, or at such other date as the patiies hereto a6'ree
in writing ("Closing").
(d) The Redeveloper shall pay the Seller $86,000 for the purchase of the Redevelopment
Properly at Closing.
Section 3.3. Authority Assistance. (a) In order to facilitate construction of the Minimum
Improvements which will achieve approved goals and objectives of the Authority, the Authority
will undertake to pay $65,050 of the cost of acquisition of the Redevelopment Propeliy (the
"Authority Assistance").
(b) The Authority Assistance shall be provided to the Redeveloper upon satisfaction
ofthe following conditions precedent:
(i) No Event of Default under this Agreement or event which would
constitute such an Event of Default but for the requirement that notice be given or that a
period of grace or time elapse, shall have occurred and be continuing;
(ii) Redeveloper has submitted, and the Authority has approved, Construction
Plans for the Minimum Improvements in accordance with Atiicle IV hereof; and
310855v2 MTN CL205-41
2
(iii) Redeveloper has completed construction of the Minimum Improvements
and been issued the Celiificate of Completion as provided in Section 4.4. of this
Agreement.
Section 3.4. Title. (a) The Redeveloper and Authority understand that Redeveloper has
reviewed and approved the state of title to the Redevelopment Propeliy at the Redeveloper's sole
cost and expense, and as described in the Title Commitment provided by AMC Mortgage Services
to the Authority (the "Commitment").
(b) The Authority shall take no actions to encumber or otherwise adversely
affect title to the Redevelopment Propeliy.
Section 3.5. Place of Document Execution, Deliverv and Recording. (a) Unless
otherwise mutually agreed by the Authority, the Seller and the Redeveloper, the execution and
delivery of all deeds, documents and the payment of the purchase price shall be made at the
location provided for Closing under the Purchase Agreement and as agreed by the parties.
(b) The Deed shall be in recordable form and shall be promptly recorded in
the proper office for the recordation of deeds and other instnunents pertaining to the
Redevelopment Property.
(c) The closing costs shall be allocated and paid as set fOlih in the Purchase
Agreement.
Section 3.6. Business Subsidv. The patiies agree and understand that the financial
assistance under this Agreement that benefits the Redevelopment Property does not constitute a
business subsidy pursuant to Minnesota Statutes Section 1161.993, subd. 3, clause (7) (the
"Business Subsidy Act") because the assistance is to accomplish redevelopment of the
Redevelopment Property, and is assistance for housing. The Redeveloper releases and waives
any claim against the City and the Authority and their respective goveming body members,
officers, agents, servants and employees thereof arising from application of the Business Subsidy
Act to this Agreement, including without limitation any claim that the Authority failed to comply
with the Business Subsidy Act with respect to this Agreement.
Section 3.7 Environmental Conditions. (a) The Redeveloper acknowledges that the
Authority makes no representations or warranties as to the condition of the soils or
environmental conditions on the Redevelopment Property or the fitness of such Redevelopment
Property for construction of the Minimum Improvements or any other purpose for which the
Redeveloper may make use of such Redevelopment Propeliy, and that the assistance provided to
the Redeveloper under this Agreement neither implies any responsibility by the Authority or the
City for any contamination of the Redevelopment Property nor imposes any obligation on such
patiies to participate in any cleanup of such Redevelopment Propeliy. The Redeveloper is
purchasing the Redevelopment Property in an "as is" and "with all faults" condition and as
pursuant to the Purchase Agreement.
310855v2 MTN CL205-41
3
(b) Without limiting its obligations under Section 8.3 of this Agreement the
Redeveloper further agrees that it will indemnify, defend, and hold harmless the Authority, the
City, and their governing body members, officers, and employees, from any claims or actions
arising out of the presence, if any, of hazardous wastes or pollutants existing on or in the
Redevelopment Property and the activities of any contractor or agent of the Authority in
conducting its activities on the Redevelopment Property.
Section 3.8 Look-Back Participation. The parties agree that the Redeveloper intends to
sell the homes constmcted on the Redevelopment Property for the target price of $235,000 each
(the "Target Price"). If a home is sold for a purchase price in excess of the Target Price (the
"Excess Profit"), the Excess Profit shall be split equally by Redeveloper and the Authority. In
addition, if Redeveloper's development expenses are less than $535,050 (the "Development
Profits") (the projected acquisition, demolition and construction costs of the Redeveloper (the
"Redevelopment Costs"), such Development Profits shall be split equally by Redeveloper and
the Authority. The total Look-back Pmticipation of the Authority (collectively, one-half of the
Excess Profits and one-half of the Development Profits) shall not exceed the amount of
Authority Assistance ($65,050). The Redeveloper shall provide documentation sufficient in the
judgment of the Authority to verify the Redeveloper's Redevelopment Costs and sale price of
each home. The Authority shall not be responsible for any deficit incurred by the Redeveloper in
the acquisition, construction or sale of the Minimum Improvements. The provisions of this
Section 3.8 shall survive the conveyance of the Deed for the Redevelopment Property, the
Certificate of Completion for any portion of the Minimum Improvements and the subsequent
conveyance of any deed thereofto a subsequent purchaser.
Section 3.9. Records. The Authority or its representatives shall have the right at all
reasonable times after reasonable notice to inspect, examine and copy all books and records of
Redeveloper relating to construction of the Minimum Improvements.
310855v2 MTN CL205-41
4
ARTICLE IV
Construction of Minimum Improvements and Public Improvements
Section 4.1. Construction of Minimum Improvements and Public Improvements. The
Redeveloper agrees that, upon acquisition of the Redevelopment Property, it will construct or
cause construction of the Minimum Improvements on the Redevelopment Property, in substantial
conformance with the Redeveloper's pro forma submitted to the staff of the Authority and the
approved Construction Plans, and at all times while Redeveloper owns the Redevelopment
Property, will operate and maintain, preserve and keep the respective components of the
Minimum Improvements or cause such components be maintained, preserved and kept with the
appurtenances and every part and parcel thereof, in good repair and condition.
Section 4.2. Construction Plans. (a) Before commencement of construction of the
Minimum Improvements the Redeveloper shall submit to the Authority the Construction Plans.
The Construction Plans shall provide for the construction of the Minimum Improvements and
shall be in conformity with this Agreement and all applicable State and local laws and
regulations. The Authority Representative will approve the Construction Plans in writing if: (i)
the Construction Plans conform to the terms and conditions of this Agreement; (ii) the
Construction Plans conform to the goals and objectives of the Redevelopment Plan; (iii) the
Construction Plans conform to all applicable federal, state and local laws, ordinances, rules and
regulations; (iv) the Construction Plans are adequate to provide for construction of the Minimum
Improvements; (v) the Construction Plans do not provide for expenditures in excess of the funds
available to the Redeveloper from all sources (including Redeveloper's equity) for construction
of the Minimum Improvements; and (vi) no Event of Default has occurred. Approval may be
based upon a review by the City's Engineer and Building Official of the Construction Plans. No
approval by the Authority Representative shall relieve the Redeveloper of the obligation to
comply with the terms of this Agreement or of the Redevelopment Plan, applicable federal, state
and local laws, ordinances, rules and regulations, or to construct the Minimum Improvements in
accordance therewith. No approval by the Authority Representative shall constitute a waiver of
an Event of Default. If approval of the Construction Plans is requested by the Redeveloper in
writing at the time of submission, such Construction Plans shall be deemed approved unless
rejected in writing by the Authority Representative, in whole or in part. Such rejections shall set
forth in detail the reasons therefore, and shall be made within 15 days after the date of their
receipt by the Authority. If the Authority Representative rejects any Construction Plans in whole
or in part, the Redeveloper shall submit new or corrected Construction Plans within 15 days after
written notification to the Redeveloper of the rejection. The provisions of this Section relating to
approval, rejection and resubmission of corrected Construction Plans shall continue to apply
until the Construction Plans have been approved by the Authority. The Authority
Representative's approval shall not be umeasonably withheld, delayed or conditioned. Said
approval shall constitute a conclusive determination that the Construction Plans (and the
Minimum Improvements to be constructed in accordance with said plans) comply to the
Authority's satisfaction with the provisions of this Agreement relating thereto.
310855v2 MTN CL205-41
5
(b) If the Redeveloper desires to make any material change in the Construction Plans
after their approval by the Authority, the Redeveloper shall submit the proposed change to the
Authority for its approval. If the Construction Plans, as modified by the proposed change,
conform to the requirements of Section 4.2 of this Agreement with respect to such previously
approved Construction Plans, the Authority shall approve the proposed change and notify the
Redeveloper in writing of its approval. Such change in the Construction Plans shall, in any
event, be deemed approved by the Authority unless rejected, in whole or in pmt, by written
notice by the Authority to the Redeveloper, setting fOlth in detail the reasons therefor. Such
rejection shall be made within 15 days after receipt of the notice of such change. The
Authority's approval of any such change in the Construction Plans will not be unreasonably
withheld.
Section 4.3. Completion of Construction. (a) Subject to Unavoidable Delays, the
Redeveloper must commence construction of the Minimum Improvements by July I, 2007 and
must substantially complete construction of the Minimum Improvements by December 31, 2007.
All work with respect to the Minimum Improvements to be constructed or provided by the
Redeveloper on the Redevelopment Property shall be in substantial conformity with the
Construction Plans as submitted by the Redeveloper and approved by the Authority and the City.
If the Redeveloper is making substantial progress with respect to the redevelopment project, and
is unable to meet one or more of the above-referenced deadlines, the Authority and the
Redeveloper shall negotiate in good faith for a reasonable period to extend the time in which
necessary action(s) must be taken or occur, the lapse of which time would otherwise constitute a
default under this Agreement.
(b) The Redeveloper agrees for itself, its successors and assigns, and every successor in
interest to the Redevelopment Property, or any part thereof, that the Redeveloper, and such
successors and assigns, shall promptly begin and diligently prosecute to completion the
redevelopment of the Redevelopment Property through the construction of the Minimum
Improvements thereon, and that such construction shall in any event be commenced and
completed subject to Unavoidable Delay within the period specified in this Section 4.3 of this
Agreement. Subsequent to conveyance of the Redevelopment Propelty, or any part thereof, to
the Redeveloper, and until construction of the Minimum Improvements has been completed, the
Redeveloper shall make reports, in such detail and at such times as may reasonably be requested
by the Authority, as to the actual progress ofthe Redeveloper with respect to such construction.
Section 4.4. Certificate of Completion. (a) Promptly after substantial completion of the
Minimum Improvements in accordance with those provisions of the Agreement relating solely to
the obligations of the Redeveloper to construct the Minimum Improvements (including the dates
for completion thereof), the President and Executive Director of the Authority shall furnish the
Redeveloper with a Celtificate of Completion in substantially the form attached as Exhibit D.
Such certification shall be a conclusive determination of satisfaction and termination of the
agreements and covenants in the Agreement with respect to the obligations of the Redeveloper,
and its successors and assigns, to construct the relevant component of the Minimum
Improvements and the dates for the completion thereof. Such certification mId such
determination shall not constitute evidence of compliance with or satisfaction of any obligation
310855v2 MTN CL205-41
6
of the Redeveloper to any Holder of a Mortgage, or any insurer of a Mortgage, securing money
loaned to finance the Minimum Improvements, or any part thereof.
(b) The Certificate of Completion provided for in this Section 4.4 of this Agreement
shall be in such form as will enable it to be recorded in the proper office for the recordation of
deeds and other instruments pertaining to the Redevelopment Property. If the President and
Executive Director of the Authority shall refuse or fail to provide any certification in accordance
with the provisions of this Section 4.4 of this Agreement, the Authority shall, within thirty (30)
days after written request by the Redeveloper, provide the Redeveloper with a written statement,
indicating in adequate detail in what respects the Redeveloper has failed to complete the
Minimum Improvements in accordance with the provisions of the Agreement, or is otherwise in
default, and what measures or acts it will be necessary, in the opinion of the Authority, for the
Redeveloper to take or perform in order to obtain such certification.
(c) The construction of the Minimum Improvements shall be deemed to be
substantially completed when the Redeveloper has received a certificate of occupancy from the
City, and all site improvements have been substantially completed as reasonably determined by
the Authority Representative.
310855v2 MTN CL205-41
7
ARTICLE V
Insurance
Section 5.1. Insurance. ( a) The Redeveloper will provide and maintain at all times
during the process of constructing the Minimum Improvements an All Risk Broad Form Basis
Insurance Policy and, from time to time during that period, at the request of the Authority,
furnish the Authority with proof of payment of premiums on policies covering the following:
(i) Builder's risk insurance, written on the so-called "Builder's Risk
Completed Value Basis," in an amount equal to one hundred percent (100%) of the
insurable value of the Minimum Improvements at the date of completion, and with
coverage available in non-reporting form on the so-called "all risk" form of policy. The
interest of the Authority shall be protected in accordance with a clause in form and
content satisfactory to the Authority;
(ii) Comprehensive general liability insurance (including operations,
contingent liability, operations of subcontractors, completed operations and contractual
liability insurance) together with an Owner's Contractor's Policy with limits against
bodily injury and Redevelopment Property damage of not less than $1,000,000 for each
occurrence (to accomplish the above-required limits, an umbrella excess liability policy
may be used);
(iii) Automobile liability insurance to cover claims for damages because of
bodily injury or death of any person or Redevelopment Property damage arising out of
the ownership, maintenance or use of any motor vehicle of not less than $1,000,000; and
(iv) Workers' compensation insurance, with statutory coverage.
(b) All insurance required in Article V of this Agreement shall be taken out and
maintained in responsible insurance companies selected by the Redeveloper which are
authorized under the laws of the State to assume the risks covered thereby, and shall name the
Authority, the City and any Mortgagee as an additional named insured thereunder. Upon
request, the Redeveloper will deposit amlUally with the Authority policies evidencing all such
insurance, or a celtificate or certificates or binders of the respective insurers stating that such
insurance is in force and effect. Unless otherwise provided in this Article V of this Agreement
each policy shall contain a provision that the insurer shall not cancel nor modify it in such a way
as to reduce the coverage provided below the amounts required herein without giving written
notice to the Redeveloper and the Authority at least thitty (30) days before the cancellation or
modification becomes effective. In lieu of separate policies, the Redeveloper may maintain a
single policy, blanket or umbrella policies, or a combination thereof, having the coverage
required herein, in which event the Redeveloper shall deposit with the Authority a celtificate or
celtificates of the respective insurers as to the amount of coverage in force upon the Minimum
Improvements.
3\0855v2 MTN CL205-4\
8
(c) The Redeveloper agrees to notify the Authority immediately in the case of
damage exceeding $100,000 in amount to, or destruction of, the Minimum Improvements or any
portion thereof resulting from fire or other casualty. In such event the Redeveloper will
forthwith repair, reconstruct and restore the Minimum Improvements to substantially the same or
an improved condition or value as it existed prior to the event causing such damage and, to the
extent necessary to accomplish such repair, reconstruction and restoration, the Redeveloper will
apply the net proceeds of any insurance relating to such damage received by the Redeveloper to
the payment or reimbursement of the costs thereof.
The Redeveloper shall complete the repair, reconstmction and restoration of the
Minimum Improvements, whether or not the net proceeds of insurance received by the
Redeveloper for such purposes are sufficient to pay for the same. Any net proceeds remaining
after completion of such repairs, constmction and restoration shall be the Redevelopment
Propelty of the Redeveloper.
(d) The Redeveloper and the Authority agree that all of the insurance provisions set
fOlth in this Article V shall terminate on the Termination Date.
Section 5.2. Subordination. Notwithstanding anything to the contrary contained in this
Article V, the rights of the Authority with respect to the receipt and application of any proceeds
of insurance shall, in all respects, be subj ect and subordinate to the rights of any lender under a
Mortgage approved pursuant to Article VII of this Agreement.
Section 5.3. Qualifications. Notwithstanding anything herein to thc contrary, the patties
acknowledge and agree that:
(a) Upon transfer of the Redevelopment Propelty or portion thereof to another person
or entity, the Redeveloper will remain obligated under Section 5.1 hereof relating to such pOltion
transferred, unless the Redeveloper is released from such obligations in accordance with the
terms atld conditions of Section 8.2(b )- (d) hereof.
310855v2 MTN CL205-41
9
ARTICLE VI
Taxes
Section 6.1. Right to Collect Delinquent Taxes. The Redeveloper acknowledges that the
Authority is providing financial assistance in furtherance of the redevelopment described in this
Agreement, and that part of the consideration for such assistance is the improvement of tax base
in the City. To that end, the Redeveloper agrees for itself, its successors and assigns, in addition
to the obligation pursuant to statute to pay real estate taxes, that it is also obligated by reason of
this Agreement to pay before delinquency all real estate taxes assessed against the
Redevelopment Property and the Minimum Improvements. The Redeveloper acknowledges that
this obligation creates a contractual right prior to the Termination Date to sue the Redeveloper or
its successors and assigns to collect delinquent real estate taxes and any penalty or interest
thereon and to pay over the same as a tax payment to the county auditor. In any such suit, the
Authority shall also be entitled to recover its costs, expenses and reasonable attorney fees.
Section 6.2. Review of Taxes. The Redeveloper agrees that prior to the Termination
Date, it will not cause a reduction in the real Redevelopment Propelty taxes paid in respect of the
Redevelopment Propelty tlu'ough: (A) willful destruction of the Redevelopment Property or any
part thereof; or (B) willful refusal to reconstruct damaged or destroyed Propelty pursuant to
Section 5.1 of this Agreement. The Redeveloper also agrees that it will not, prior to the
Termination Date, apply for a deferral of Redevelopment Propelty tax on the Redevelopment
Property pursuant to any law, or transfer or permit transfer of the Redevelopment Property to any
entity whose ownership or operation of the Redevelopment Property would result in the
Redevelopment Propelty being exempt from real estate taxes under State law (other than any
pOltion thereof dedicated or conveyed to the City or Authority in accordance with this
Agreement).
310855v2 MTN CL205-41
10
ARTICLE VII
Financing
Section 7.1. Mortgage Financing. (a) The Redeveloper shall obtain one or more
commitments for financing which, together with committed equity for such construction, is
sufficient for payment of the Construction Costs for the Minimum Improvements. Such
commitments may be short term financing, long term mortgage financing, a bridge loan with a
long term take-out financing commitment, or any combination of the foregoing.
(b) In the event that there occurs a default under any Mortgage obtained by the
Redeveloper pursuant to Section 7.1 of this Agreement, the Redeveloper shall cause the
Authority to receive copies of any notice of default received by the Redeveloper from the holder
of such Mortgage. Thereafter, the Authority shall have the right, but not the obligation, to cure
any such default on behalf of the Redeveloper within such cure periods as are available to the
Redeveloper under the MOltgage documents. In the event there is an event of default under this
Agreement, the Authority will transmit to the Holder of any MOltgage a copy of any notice of
default given by the Authority pursuant to Article IX of this Agreement.
(c) In order to facilitate the securing of other financing, the Authority agrees to
subordinate its rights under this Agreement provided that such subordination shall be subject to
such reasonable terms and conditions as the Authority and Holder mutually agree in writing.
310855v2 MTN CL205-41
II
ARTICLE VIII
Prohibitions Aeainst Assienment and Transfer; Indemnification
Section 8.1. Representation as to Redevelopment. The Redeveloper represents and
agrees that its purchase of the Redevelopment Property, and its other undertakings pursuant to
the Agreement, are, and will be used, for the purpose of redevelopment of the Redevelopment
Property and not for speculation in land holding.
Section 8.2. Prohibition Against Redeveloper's Transfer of Redevelopment Propertv and
Assignment of Agreement. The Redeveloper represents and agrees that prior to issuance of the
Certificate of Completion for the Minimum Improvements:
(a) Except as specifically described in this Agreement, the Redeveloper has not made
or created and will not make or create or suffer to be made or created any total or partial sale,
assignment, conveyance, or lease, or any trust or power, or transfer in any other mode or form of
or with respect to this Agreement or the Redevelopment Property or any part thereof or any
interest therein, or any contract or agreement to do any of the same, to any person or entity
(collectively, a "Transfer"), without the prior written approval of the Authority's board of
commissioners. The term "Transfer" does not include (i) encumbrances made or granted by way
of security for, and only for, the purpose of obtaining construction, interim or permanent
financing necessary to enable the Redeveloper or any successor in interest to the Redevelopment
Propelty or to construct the Minimum Improvements or component thereof; (ii) any lease,
license, easement or similar arrangement entered into in the ordinary course of business related
to operation ofthe Minimum Improvements; or any (iii) sale of a single family home constituting
a pOltion of the Minimum Improvements to a purchaser who will occupy such home as the
purchaser's principal place of residence.
(b) If the Redeveloper seeks to effect a Transfer prior to issuance of the Certificate of
Completion, the Authority shall be entitled to require as conditions to such Transfer that:
(i) any proposed transferee shall have the qualifications and financial
responsibility, in the sole and reasonable judgment of the Authority, necessary and
adequate to fulfill the obligations undertaken in this Agreement by the Redeveloper as to
the portion ofthe Redevelopment Property to be transferred; and
(ii) Any proposed transferee, by instrument in writing satisfactory to the
Authority and in form recordable in the public land records of Anoka County, Minnesota,
shall, for itself and its successors and assigns, and expressly for the benefit of the
Authority, have expressly assumed all of the obligations of the Redeveloper under this
Agreement as to the portion of the Redevelopment Propelty to be transferred and agreed
to be subject to all the conditions and restrictions to which the Redeveloper is subject as
to such pOltion; provided, however, that the fact that any transferee of, or any other
successor in interest whatsoever to, the Redevelopment Propelty, or any part thereof,
shall not, for whatever reason, have assumed such obligations or so agreed, mId shall not
(unless and only to the extent otherwise specifically provided in this Agreement or agreed
31 0855v2 MTN CL205-41
12
to in writing by the Authority) deprive the Authority of any rights or remedies or controls
with respect to the Redevelopment Property, the Minimum Improvements or any part
thereof or the construction of the Minimum Improvements; it being the intent of the
parties as expressed in this Agreement that (to the fullest extent permitted at law and in
equity and excepting only in the manner and to the extent specifically provided otherwise
in this Agreement) no transfer of, or change with respect to, ownership in the
Redevelopment Property or any part thereof, or any interest therein, however
consummated or occurring, and whether voluntary or involuntary, shall operate, legally,
or practically, to deprive or limit the Authority of or with respect to any rights or
remedies on controls provided in or resulting from this Agreement with respect to the
Redevelopment Property that the Authority would have had, had there been no such
transfer or change. In the absence of specific written agreement by the Authority to the
contrary, such transfer or approval by the Authority thereof shall not be deemed to relieve
the Redeveloper, or any other party bound in any way by this Agreement or otherwise
with respect to the Redevelopment Propeliy, from any of its obligations with respect
thereto; and
(iii) Any and all instruments and other legal documents involved in effecting
the transfer of any interest in this Agreement or the Redevelopment Property governed by
this Article VIII, shall be in a form reasonably satisfactory to the Authority.
(c) If the conditions described in paragraph (b) are satisfied in the sole judgment of
the Authority, then the Transfer will be approved and the Redeveloper shall be released from its
obligation undcr this Agreement, as to the portion of the Redevelopment Prope1iy that is
transferred, assigned, or otherwise conveyed. The provisions of this paragraph (c) apply to all
subsequent transferors, assuming compliance with the terms ofthis Aliicle.
(d) Upon issuance of the Celiificate of Completion, the Redeveloper may transfer or
assign the Minimum Improvements and/or the Redeveloper's rights and obligations under this
Agreement with respect to such Redevelopment Property without the prior written consent of the
Authority.
Section 8.3. Release and Indenmification Covenants. (a) The Redeveloper releases from
and covenants and agrees that the Authority and the City and the governing body members,
officers, agents, servants and employees thereof shall not be liable for and agrees to indenmify
and hold harmless the Authority and the City and the governing body members, officers, agents,
servants and employees thereof against any loss or damage to Redevelopment Property or any
injury to or death of any person occurring at or about or resulting from any defect in the
Minimum Improvements or the Public Improvements, except for any such damages or injuries
directly related to the gross negligence of the Authority or the City.
(b) Except for any willful or negligent misrepresentation or any willful or wanton
misconduct or negligence of the following named parties, the Redeveloper agrees to protect and
defend the Authority and the City and the governing body members, officers, agents, servants
and employees thereof (the "Indemnified Patiies"), now or forever, and further agrees to hold the
Indemnified Parties harmless from any claim, demand, suit, action or other proceeding
310855v2 MTN CL205-41
13
whatsoever by any person or entity whatsoever ansmg or purportedly ansmg from this
Agreement, or the transactions contemplated hereby or the acquisition, construction, installation,
ownership, and operation of the Minimum Improvements.
(c) Except for any negligence of the Indemnified Patties (as defined in clause (b)
above), and except for any breach by any of the Indemnified Parties of their obligations under
this Agreement, the Indemnified Patties shall not be liable for any damage or injury to the
persons or Redevelopment Property of the Redeveloper or its officers, agents, servants or
employees or any other person who may be about the Minimum Improvements or Public
Improvements due to any act of negligence of any person.
(d) All covenants, stipulations, promises, agreements and obligations of the Authority
contained herein shall be deemed to be the covenants, stipulations, promises, agreements and
obligations of the Authority and not of any governing body member, officer, agent, servant or
employee of the Authority in the individual capacity thereof.
310855v2 MTN CL205-41
14
ARTICLE IX
Events of Default
Section 9.1. Events of Default Defined. The following shall be "Events of Default"
under this Agreement and the term "Event of Default" shall mean, whenever it is used in this
Agreement, anyone or more of the following events, after the non-defaulting party provides 30
days written notice to the defaulting party of the event, but only if the event has not been cured
within said 30 days or, if the event is by its nature incurable within 30 days, the defaulting party
does not, within such 30-day period, provide assurances reasonably satisfactory to the pmty
providing notice of default that the event will be cured and will be cured as soon as reasonably
possible:
(a) Failure by the Redeveloper or the Authority to observe or perform any material
covenant, condition, obligation, or agreement on its part to be observed or performed under this
Agreement;
(b) The Redeveloper:
(i) files any petition in bankruptcy or for any reorganization, arrangement,
composition, readjustment, liquidation, dissolution, or similar relief under the United
States Bankruptcy Act or under any similar federal or State law;
(ii) makes an assigmnent for benefit of its creditors;
(iii) admits in writing its inability to pay its debts generally as they become
due;
(iv) is adjudicated a bankrupt or insolvent;
(v) attempts a Transfer without complying with the requirements of Article
VIII of this Agreement
Section 9.2. Remedies on Default. Whenever any Event of Default referred to in Section
9.1 of this Agreement occurs, the non-defaulting party may exercise its rights under this Section
9.2 after providing thirty days written notice to the defaulting pmty of the Event of Default, but
only if the Event of Default has not been cured within said thhty days or, if the Event of Default
is by its nature incurable within thirty days, the defaulting pmty does not provide assurances
reasonably satisfactory to the non-defaulting party that the Event of Default will be cured and
will be cured as soon as reasonably possible:
(a) Take whatever action, including legal, equitable or administrative action, which
may appear necessary or desirable to collect any payments due under this Agreement, or to
enforce performance and observance of any obligation, agreement, or covenant under this
Agreement.
310855v2 MTN CL205-41
15
Section 9.3. No Remedv Exclusive. No remedy herein conferred upon or reserved to the
Authority or Redeveloper is intended to be exclusive of any other available remedy or remedies,
but each and every such remedy shall be cumulative and shall be in addition to every other
remedy given under this Agreement or now or hereafter existing at law or in equity or by statute.
No delay or omission to exercise any right or power accruing upon any default shall impair any
such right or power or shall be construed to be a waiver thereof, but any such right and power
may be exercised from time to time and as often as may be deemed expedient. In order to entitle
the Authority to exercise any remedy reserved to it, it shall not be necessary to give notice, other
than such notice as may be required in this Article IX.
Section 9.4. No Additional Waiver Implied by One Waiver. In the event any agreement
contained in this Agreement should be breached by either party and thereafter waived by the
other party, such waiver shall be limited to the patiicular breach so waived and shall not be
deemed to waive any other concurrent, previous or subsequent breach hereunder.
Section 9.5. Attornev Fees. Whenever any Event of Default occurs and if the Authority
or Redeveloper shall employ attorneys or incur other expenses for the collection of payments due
or to become due or for the enforcement of performance or observance of any obligation or
agreement on the pati of the Redeveloper or Authority under this Agreement, the non-prevailing
party in any such action agrees that it shall, within 10 days of written demand by the prevailing
patiy, pay to the prevailing patiy the reasonable fees of such attorneys and such other reasonable
expenses so incurred.
310855v2 MTN CL205.41
16
ARTICLE X
Additional Provisions
Section 10.1. Conflict of Interest: Authoritv Representatives Not Individuallv Liable.
The Authority and the Redeveloper, to the best of their respective knowledge, represent and
agree that no member, official, or employee of the Authority shall have any personal interest,
direct or indirect, in the Agreement, nor shall any such member, official, or employee participate
in any decision relating to the Agreement which affects his personal interests or the interests of
any corporation, partnership, or association in which he is, directly or indirectly, interested. No
member, official, or employee of the Authority shall be personally liable to the Redeveloper, or
any successor in interest, in the event of any default or breach by the Authority for any amount
which may become due to the Redeveloper or successor or on any obligations under the terms of
the Agreement.
Section 10.2. Equal Emplovment Opportunitv. The Redeveloper, for itself and its
successors and assigns, agrees that during the construction of the Minimum Improvements
provided for in the Agreement it will comply with all applicable federal, state and local equal
employment and non-discrimination laws and regulations.
Section 10.3. Restrictions on Use. The Redeveloper agrees that until the Termination
Date, the Redeveloper, and such successors and assigns, shall devote the Redevelopment
Property to, the operation of the Minimum Improvements for uses described in the definition of
such term in this Agreement, and shall not discriminate upon the basis of race, color, creed, sex
or national origin in the sale, lease, or rental or in the use or occupancy of the Redevelopment
Property or any improvements erected or to be erected thereon, or any patt thereof.
Section 10.4. Provisions Not Merged With Deed. None of the provisions of this
Agreement at.e intended to or shall be merged by reason of any deed transferring any interest in
the Redevelopment Property and any such deed shall not be deemed to affect or impair the
provisions and covenants of this Agreement.
Section 10.5. Titles of Articles and Sections. Any titles of the several parts, Alticles, and
Sections of the Agreement are inserted for convenience of reference only and shall be
disregat.ded in construing or interpreting any of its provisions.
Section 10.6. Notices and Demands. Except as otherwise expressly provided in this
Agreement, a notice, demand, or other communication under the Agreement by either party to
the other shall be sufficiently given or delivered if it is dispatched by registered or certified mail,
postage prepaid, return receipt requested, or delivered personally; and
(a) in the case of the Redeveloper, is addressed to or delivered personally to the
Redeveloper at 15 South Fifth Street, Suite 710, Minneapolis, MN 55402, Attn: President; and
310855v2 MTN CL205.41
17
(b) in the case of the Authority, is addressed to or delivered personally to the
Authority at 590 - 40th Avenue NE, Columbia Heights, Minnesota 55421, Attn: Executive
Director; or at such other address with respect to either such party as that party may, from time to
time, designate in writing and forward to the other as provided in this Section.
Section 10.7. Counterparts. This Agreement may be executed in any number of
counterparts, each of which shall constitute one and the same instrument.
Section 10.8. Recording. The Authority may record this Agreement and any
amendments thereto with the Anoka County recorder. The Redeveloper shall pay all costs for
recording.
Section 10.9. Amendment. This Agreement may be amended only by written agreement
approved by the Authority and the Redeveloper.
Section 10.1 O. Authoritv or Citv Approvals. Unless otherwise specified, any approval
required by the Authority under this Agreement may be given by the Authority Representative.
Section 10.11. Termination. This Agreement terminates on the Termination Date, except
that termination of the Agreement does not terminate, limit or affect the rights of any party that
arises before the date the City issues the Celtificate of Completion, or as otherwise provided
herein.
310855v2 MTN CL205-4!
18
IN WITNESS WHEREOF, the Authority has caused this Agreement to be duly executed
in its name and behalf and its seal to be hereunto duly affixed and the Redeveloper has caused
this Agreement to be duly executed in its name and behalf on or as of the date first above written.
COLUMBIA HEIGHTS ECONOMIC
DEVELOPMENT AUTHORITY
By
Its President
By
Its Executive Director
STATE OF MINNESOTA )
) ss.
COUNTY OF ANOKA )
The foregoing instrument was acknowledged before me this day of
2007, by and , the President and Executive Director
of the Columbia Heights Economic Development Authority, a public body politic and corporate,
on behalf of the Authority.
Notary Public
310855v2 MTN CL205-41
19
GREATER METROPOLITAN HOUSING
CORPORATION
By
Its
STATE OF MINNESOTA )
) ss.
COUNTY OF )
The foregoing instrument was acknowledged before me this _ day of
, 2007 by , the of the
Greater Metropolitan Housing Corporation, a Minnesota non-profit corporation, on behalf of the
corporation.
Notary Public
310855v2 MTN CL205-41
20
EXHIBIT A
Legal Description of Redevelopment Property
Lots 25 and 26, Block 43, Columbia Heights Annex to Minneapolis, Anoka County
310855v2 MTN CLZ05-41
A-I
EXHIBIT B
Purchase Agreement
310855v2 MTN CL205-41
C-I
05/07/2007 08:08
5515%0872
MARK WIEBUSCH
PAGE 02/05
EXHI'&\T B
~ (~
MORTGAGE SERVICES
Standard Counter Offer
Loan #: 0105477947
This Is a counteroffer 0 the Real Estate Purchase Contract and Receipt for Deposit dated
f:1alI,..a, 20llZ, for prop rty known as: 4141 JEFFERSON ~T NE. COLUMBIA HEIGHT~. MN
~ (the "Property" where Citv of Columhfa H<'!Ipht,; Ff)A i" refp..rred to as Buyer and
AMC Mortgage Services 15 referred to as Seller.
seller accepts the term and conditions In the contract with the following changes:
1. Sales Price shall be 86000.00.
2. Buyer's deposit shal be $ 2500.00 in the form of a cashier's check or a certified check.
3. Seller agrees to p y up to $ ll.llll. for Buyer's closing costs, which are deftned as
prepaid, nonrecurri g, and non-allowable costs.
4. Seller agrees to pa up to $ll.llll. toward repairs on the Property. Any repair amount in
excess of the stated amount shall be the sole responsibility of Buyer. No repairs shall be
started without the eller's consent.
5. Seller agrees to pay for tne tOllowing items up to but not to exceed the following
amount:
we.
6. Buyer to provide eller's agent with a Source of Funds document prior to offer
acceptance,
7. Buyer to make a rltten application loan approval within two (2) days. Buyer Is to
remove the apprais I contingency within (Ten) 10 days and have Lender's written loan
approval withlrl Tw nty (20) days after acceptance of this counteroffer. If this ;s an
all cash transactio ,_ buyer a.nr~~Q tn waivA ;tll flft;!inr.ir"u) rontin9C!neiGlIllr
8. Buyer shall r:nmplet all inspections within ~(O) days of counteroffer acceptance"
Buyer is solely resp nsible for the costs of all Inspections. Seller will not adjust the sales
price due to the find ngs of any Inspections. Seller will not pay for a property surveyor
abstract.
9. Buyer hereby elects to utilize Seller's attorney/title company/escrow company for the
purpose of issuing ti Ie insurance, In consideration thereof, Seller agrees to pay for the
Owner's title Insura ce policy. Seller will not provide a surveyor abstract. Seller will
transfer title with a 'mited or Special Warranty Deed.
10. Unless otherwise sp clfied. Buyer and Seller shall pay their own closing costs.
Buyer's Initials: (
) (
)
Seller's Initials: (
) (
)
AMC Stmldard J.,~tm(crOD6r
IJIN#SD-QI201J.2
Page J oi5
Revised 111011]005
05/07/2007 08:08
5515%0872
MARK WIEBUSCH
PAGE 03/05
r!m C
MORTGAGE SERVICES
Standard Counter Offer
Loan #, 0105477947
I1.Time is of the es ence. If the transaction does not close by May 25. 20.QZ, through
no fault of Sell~r, Slier reserves the right to cancel the transaction. In the event Seller
elects to extend th closing period, Buyer shall be charged a per diem of $100.00 until
the transaction clo es. In thA event SAiler cancels escrow for Buyer's and or F:lIlYFlr'S
Lenders nonperror ance or negligence, Buyer shall sign cancellation papers within 24
hours and forfeit Bu er's deposit to Seller.
12.Seller shall pay up to $0.00 for Section I charges listed on the termite report. The
Buyer shall pay any and all costs in excess of the stated amount,
13. The sale is subj ct to management approval of Seller. Tnis sale may be
subjected to MGI /PMI and/or investor approval.
14. The sale is continge t upon clOsing without the need for Seller to deposit funds to clo''',
If funds are require , Seller may terminate the transaction without liability or obligation
to Buyer.
1S.Addltional terms:
IU8
16. Buyer hereby hold
delivering a "Real
Seller and ~eller's
express or Implied,
acquired the Prope
Seller and Seller's Agent harmless from not completing and
state Transfer and Disclosure Statement" and aCknowledqes that
Agent have made absolutely no representations or warranties,
s to the condition of the Property. Buyer acknowledges that Seller
through foreclosure or default.
17. Buyer is aware that he Property is sold In its PRESENT, AS IS condition with all defects,
If any. seller stro gly encourages Buyer to obtain expert advice by prOfessional
inspections as to, ut not limited to, the electrical, structural, plumbing, geological,
utilities, and roof c ndition of the Property. Buyer is purchasing the Property In Its
present condition wi hout any obligation by Seller to make any changes, alterations or
repairs, Seller and Seller's Agent do not warrant the existing structure as to its
habitability or sulta llity for occup"ncy, nor that the Property meets city, counLy, ~l"l",
or federal ordlnanc s or codes. Buyer assumes all responsibility to check with the
appropriate planning authority for the Intended use. Buyer assumes all responsibility for
[luyer'. Intended u~ and agrees to hold Seller harmless as to suitability for Buyer's
intended use.
18. Buyer aCknowledges that it: i) has sufficient information regarding the PrOperty, il) is
relying on Its own e perts and not Seller or any information provided by Seller, If any;
and iii) 15 not look ng to Seller for any addlliunal information with respect to the
condition of the Prop rty.
Buyer's Initials I (
AMC Smndard GO/l"tal'(),tI~r
DIN#SD.Ol1Q0.2
) (
Seller's Initials: (
) (
)
Page 2015
.,"".. /2iV21l00J
05/07/2007 08:08
6516960872
MARK WIEBUSCH
PAGE 04/06
-
IIIII
MORTGAGE SE
C
VICES
Standard Counter Offer
Loan #: 0105477947
19. Buyer is advised th t personal property is not included In the purchase. If Seller has any
Interest in personal property at the Property, Seller agrees to give Buyer Its Interest In
the personal prope , if any, without any warranties or representations, express Or
Implied. as to the 0 nershlp or condition of the personal property. Thi< inr.h.tdes, but is
not limited to, key. garage door openers, window and wall coverings, fixtures, and
freestanding applla es, If any.
20. This instruction re laces and supersedes any and all statements concerning the
condition of the Pro erty and any "Seller's Representation<" concerning the condition of
the Property, the p rsonal property, or any matter that may be included in the original
contract. Should t ere be any discrlpancy between the original contract and this
r.nllnteroff~r. the te s of this counteroffer Ghall control,
21. The closing of thl
premises al e unc.on
nature and In its pr
transaction shall constitute Buyer's acknowledgement that the
Itlonally accepteo without representation or warranty of any kind Or
ent condition based solely on Buyer's Inspection.
22. Seller haS acquired the Property via foreclosure and may be unaware of existing title
defects and/or lien . ShOUld Seller be unable or unwilling to clear said title defects
and/or lien., Seller m~y terminate the transaction. In this event, Buyer'S sOle remedy
shall be the return 0 the earnest money deposit.
ZJ. Seller's (;nOlce of CI sing Company is to be: West Title - Minnetonka - MN
Contact:
Phone: 1952\ 252-2500
Fax:9522522505
24. Bond. and Assessm nto now ~ lien shall be p~id current by the Seller, any p~yments
not yet due are to e assumed by the buyer. Buyer and Seller agree that Taxes are to
be prorated to the c ose date.
25. Addendum A Is to si ned by the buyer and Seller and Is to be made part of this
agreement.
26. Seller will not allo
Mortgage, Argent
of their choice.
financing through company affiliate lenders; Ameriquest
artgage. Buyer to find financing through any other lender
Buyer's Initials: (
AM(,: ~/(l"da"d C:oulfrerqffl!t'
DIN#SD.OJ2rJO.l
) (
)
Seller's Initials: (
)( )
n~ViJM 12/014Q05
Page 3015
B5/B7/2007 08:08
5515950872
MARK WIEBUSCH
PAGE 05/05
"'"
IIIII
MORTGAGE S
Standard Counter Offer
Loan #: 0105477947
Seller reserves the rig t to continue to offer the Property for ""I" and accept any offer at
any time prior to recei t by Seller or Seller's Agent of a copy of this Counteroffer, accepted
and signed by Eluyer. 'Accept," as used herein, includes delivery In person, by mail, or by
facsimile.
Unless this Counteroff r is accepted on or before May 14, 2007, at 12 noon, it shall h"
deemed revoKed and t e deposit shall be returned to Buyer. Seiler'S acceptance of another
offer shall revoke this Counteroffer. This Counteroffer may be executed In two or more
counterparts, all of whi h shall constltlJtl!> one and the .ame writing.
Date'
,20__
Seller:
o The undersigned Bu er accepts the above Counteroffer, or
o The undersigned Bu er accepts the above Counteroffer with the following changes:
Date:
,20_
Buyer:
Date:
,20_
Buy!::!,:
The following is req ired only if the Buyer has made changes or amendments
abo".., Seller accepts the Swyer's chonges lu S..lIer's counterorter and agrees to sell on
the above terms and co ditions.
Dill'"
,20_
Serler;
NO REPRESENTATION S MADE AS TO THE LEGAL VALIDI1Y OF ANY PROVISION OR THE
ADE:QUACY OF ANY PR VISION IN ANY SPECIFIC TRANSACTION. A REAL ESTATE BROKER
IS THE PERSON QUALI lED TO ADVISE ON REAL ESTATE TRANSACTIONS. IF YOU DESIRE
LEGAL OR TAX ADVICE, CONSULT AN APPROPRIATE PROFESSIONAL.
A Me Slall(lc",J COIIYllf!f'i)ff~r
DlN# SlJ-mVQ-2
"ag" 4 olS
R(!',Ji,led /21O:J12I)OJ
05/07/2007 08:08
6516950872
MARK WIE8USCH
PAGE 06/06
"'"
I I I I I
MORTGAG.E S
Standard Counter Offer
Loan #: 0105477947
ADD.I;NI)UMA
FORECLOSURI!: YKUV1SlUN
Addendum to (Purchase C ntract and/or Counter Offer) dated
for the property located at 4141 JEFFERSON ST NE. COLUMBIA HEIGHTS. MN 55421.
Buyer is aware th.t Selle acquired the property that is the subjAIT 01 thlR tran.actlon by way of
loreclosure, and that Sell r is selling and Buyar Is purchasing the property in its present "As-Is"
Condition without represen .tions Or warranties of any kind or n.ture.
Buyer acknowledges for B yer .nd Buyer's successors, heirs .nd .ssignees, that Buyer has been
given a reasonable oppo unity to inspect and investigate the property and all improvements
lher~ulI, either Indepenoe tly Or through agents or Buyer's choosing, .nd that in purchasing the
property Buyer Is not rely ng on Seller, or its agents, as to the condition or s.fety of the property
and/or any improvement thereon, In<:ludlng but not limited to. electrical, plumbing, heating,
sewer, roof, air condltlonl g, if any, foundations. soils and geology, lot size or suitability of the
property .nd/or its Impro ements lor partl<:ular purposes, or th.t appliances, if any, plumbing
and/or utilities are In work ng nrnP,:f, and/or that the ImprOlJerT'll~nts are 6tructurally sound and/or in
compliance with any city, ounty, state and/or FeCferal statutes, codes or ordinances. Any reports,
repairs or work requlreCf b Buyer's lender is to be the sole responsibility of the Buyer.
Seller does not w.rrant ex sting structure as to its habltabiiity or suitability for occupancy. Buyer(s)
assumes responSibility to heck with the appropriate planning authority for intended use and hold
S~II.r ~nd Broker harmiess as to SUitability tor Buyer(s) intended use.
Mold mayor may not hay been removed or covered in the course of any r.h=!aning nr repair!n!) of
the property. The purchas r acknowledges that, if seller Or any of seller's employees, contractors,
or agents cleaned or repai d the property or remedlate Mold contamination, that seller does not
warrant thA r.:1l~ar'ling repai Or remediation. Suyer to aat:15fy themselves with their own Inspections
at the Buyer's expense an Buyer acknowledges and agrees to accept full responsibility/risk for any
matters that may result f m microscopic organisms and/or mold anCf to hold harmless, release and
indemnify seller and Ot a~ 'Iyns, investors, Selling brOKer/agent, their officers, employees, agents,
heirs, executors, admlnist ators and successors from any liability/recourse/damages (financial or
otherwise).
Buyer(s) further states th t they are relying solely upon their own inspection of subject property
and not upon any repres ntation made to them by ;my nAl"Ron whomso@ver, and IS: purchasing
subject property in the con ition In which It now is, without any obligation on the part of the Seller
to make any changes, alter tions, or repair thereto.
Sellers gives no warranties of fitness regarding such personal property that belongs to Seller that is
transferreCf as a part of the purchase,
The closing of this transa tion shall constitute as an a<:knowledgment by the Buyer(s) that THE
PREMIS~S WERE ACCEPTE WITHOUT REPRESENTATION OR WARRANTY OF ANY KIND OR NATURE
AND IN ITS PRESENT "AS I .. CONDlTION BASED SOLELY ON BUYER'S OWN INSPECTION.
Buyer
D.te
Buyer
Date
Seller
Date
Seller
Date
AMe STC1ndard Coume1'O.QCr
DINtlSlJ.()JlfJn.2
Page 3afJ
Ri!vhad , 2Iflt/~OfJ.'i
310855v2 MTN CL205-41
EXHIBIT C
Concept Materials for Redevelopment Property
C-I
EXHIBIT C
GREATER METROPOLITAN HOUSING CORPORATION - Twin Cities
15 South Fifth Street, Suite 710. Minneapolis, MN 55402
phone: (612) 339-0601. fax: 612-339-0608
e-mail: bbuelow@qmmhc.orq . website: www.gmhctc.org
Proposed for 4141 Jefferson Street
.(TWO) 2-STORY MODEL WI FULL FRONT PORCH
BUILDING FEATURES:
. 1,650 Finished S.F on the 15t and 2nd Floors
. 3 Bedroom
. 2 and Yz Bathrooms
. Full Basement, 832 S.F., 2 Egress Windows and Full Bathroom Rough-in
. Formal Dining Room
. Large Kitchen
. Oak Cabinets wi Plastic laminate Tops
. Kitchen Appliance Allowance
. Oak Interior Doors, Window Casing and Baseboard
. Large Front Porch
. Ceramic Floors and Tub Surround in Bathrooms
. High Efficiency Mechanical System
o 90% + Efficient Furnace
o Air-to-Air Exchanger
o Central Air-Conditioning
o Direct-Vent Water Heater
o Programmable Thermostat
. Low Maintenance Exterior
o Vinyl Siding
o Pre-Finished Aluminum Soffits, Facia, and Trim
o Aluminum Clad Double-Hung Windows
o Aluminum Gutters and Down Spouts
. Large Two-Car Detached Garage
. Landscaping includes new sod from street to alley
EXHIBIT C
EXHIBIT C
I
,
~
2~f
~~.i
il!,
Inl
o~~1
Ihii
.
g
~
I
~
OI>>"1IHI1AJ~JSViI
AVM3!\IOO
SnONlVUUl8
--~- -- - -- ~
----....l..-j _..1
t!l {:j :i ~~
iIi" " ~~
(! {:j ii ~~
r-;s
~;:;:,
! i......
t... ....
~
i
~~
h
1I1I
lill
II lI~i~
h k.b~
~.~ u.~*
~~~ mil
~_d.,
I
OW"iiIHIlAll/3dOlklJ.BlA
'"""""
"'...
A311V
~
~ I
Ii
-.o-SI
...
o
~.g
9;1
If! I
M
r'
.
.
~ I
21
~ .-
.-
Ii
U.
~d
Ollr;fillkUa,lOl:ldlSVJ
.l
AVM3fJOO ~
S/1ONlWllus ..
---- --.- -
L----.-~L----.i
w ;; ,~
~{:j! I~
(!~:: ~~
" h
t
,
................h.. ..................~
~
:d1--
~
~
~
"
i
.
~
lJot"'1lHl1..ut13dOU.1.1B31.\
.'3"N .l33~.lS NOS~3:1:13r
Z <f------CI
1
~
z
:2
~
J:
(!) 1"'
ill
J:
::!;
W
~
....I
0
()
u.i
:i
Iii
w
It:
I-
en
z
0
en
It:
w
LL
LL
W
-,
~
~
v
0
Z
<(
~
v
~
v
z
:'.J
n.
w
l-
ii)
I-
::;
n.
en
b
....I
EXHIBIT D
CERTIFICATE OF COMPLETION
The undersigned hereby certifies that Greater Metropolitan Housing Corporation (the
"Redeveloper") has fully complied with its obligations under Articles III and IV of that
document titled "Contract for Private Redevelopment," dated November 28, 2006 between the
Columbia Heights Economic Development Authority and the Redeveloper (the "Contract"), with
respect to construction of the Minimum Improvements in accordance with the Construction
Plans, and that the Redeveloper is released and forever discharged from its obligations to
construct the Minimum Improvements under Articles III and IV.
Dated:
,2007
COLUMBIA HEIGHTS ECONOMIC
DEVELOPMENT AUTHORITY
By
Its President
By
Its Executive Director
STATE OF MINNESOTA )
) ss.
COUNTYOFANOKA )
On this _ day of ,2007, before me, a Notary Public within and for said
County, personally appeared , to me personally known, who, being
by me duly sworn, did say that (s)he is the President of the Authority named in the foregoing
instrument; that the seal affixed to said instmment is the seal of said Authority; that said
instrument was signed and sealed in behalf of said Authority by authority of its governing body;
and said acknowledged said instrument to be the free act and deed of said
Authority.
Notary Public
310855v2 MTN CL205.41
D-l
STATE OF MINNESOTA )
) ss.
COUNTY OF ANOKA )
On this _ day of ,2007, before me, a Notary Public within and for said
County, personally appeared , to me personally known, who, being
by me duly sworn, did say that (s)he is the Executive Director of the Authority named in the
foregoing instrument; that the seal affixed to said instrument is the seal of said Authority; that
said instrument was signed and sealed in behalf of said Authority by authority of its governing
body; and said acknowledged said instrument to be the free act and deed of said
Authority.
Notary Public
310855v2 MTN CL205-41
D-2